Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
HINDUSTAN PETROLEUM CORPORATION LIMITED (A GOVERNMENT OF INDIA ENTERPRISE)
INVITATION TO BID (ITB)
THRU
NATIONAL COMPETITIVE BIDDING NOTICE (NCBN)
ITB No.- 8000084-HD-10129/JR dated 20/03/2009
FOR
ENGINEERING AND PROJECT MANAGEMENT
CONSULTANCY FOR RECEIPT STORAGE CUM
DESPATCH TERMINAL
OF
GURU GOBIND SINGH REFINERY
PRODUCTS EVACUATION PROJECT
(GGSRPEP)
VOLUME III
SCOPE OF WORK
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
VOLUME III
SCOPE OF WORK
A. GENERAL
B. SCOPE OF BASIC DESIGN
C. SCOPE OF DETAILED ENGINEERING
D. EPMC SERVICES IN PROCUREMENT AND MATERIALS
MANAGEMENT OF MATERIALS AND EQUIPMENTS
E. SCOPE OF PROJECT MANAGEMENT SERVICES
F. EXCLUSIONS FROM CONSULTANT’S SCOPE OF WORK
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
A. GENERAL
a) Definition of “Project” :
The word “Project” appearing in Scope of Work shall mean “Receipt Storage cum
Despatch Terminal of GGSR Products Evacuation Project” comprising of product
receipt facilities from GGSR, Storage tanks, product feeding facilities up to the booster
pumps of the pumping station of the cross country pipelines, allied facilities etc., at
Raman Mandi, Bhatinda, India unless the context otherwise requires.
b) Project Implementation Strategy :
The PROJECT IMPLEMENTATION STRATEGY developed for the Receipt Storage
cum Despatch Terminal of GGSR Products Evacuation Project, is based on a basic
philosophy that Engineering and Project Management Consultant will be appointed to
manage and control all aspects of the Project execution on behalf of Owner. The
Consultant will be responsible for all project activities to a small group of Owner’s
executives.
c) Capacity Expansion :
While designing various facilities provision shall be kept by Consultant for future
expansion.
d) Battery Limits :
The following battery limits for EPMC are applicable for the Receipt Storage cum
Despatch Terminal of GGSR Products Evacuation Project:
Raman Mandi Receipt Storage cum Deapatch Terminal will receive petroleum
products through dedicated pipelines lines from Guru Gobindh Singh Refinery
Limited. The product will be received in the storage tanks, tested an accounted for
before dispatch to the booster pumps of the pumping station that will feed the to the
cross country pipelines. The receipt and dispatch battery limits(BL) are as follows:
Start of BL: - Last delivery flange of product transfer pumps of GGSR for feeding
of petroleum products from GGSR offsite tanks to the project.
End of BL: - Inlet flange of Booster pumps of the pumping station of the project for
feeding products to the cross country pipelines.
e) Integration of facilities :
Software / hardware used for various Automation systems of the Project like Tank
Farm Management System, Terminal Automation System, fire fighting
automation system etc. shall be compatible with that of the GGSR pumping system
(for product receipt) and Turnkey Instrumentation System of dispatch pumping station
of the cross country pipelines being provided at the Raman Mandi. Coordination with
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
respective vendors/consultants of GGSR/ Despatch pumping station shall be maintained
by the vendor for ensuring compatibility of Receipt storage cum Despatch Terminal
Automation and proposed Instrumentation, SCADA & APPS System of pipelines of
GGSRPEP & that of GGSR Transfer pump house.
f) Standardisation of Equipments / Instruments :
As far as possible, Consultants for GGSR Products Evacuation Project shall endeavor
to standardize type of equipments / instruments being considered in various pipeline
stations.
g) Completion Schedule : 15 Months from the date of PO/FOA
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
VOLUME III
(SCOPE OF WORK)
B. SCOPE OF BASIC DESIGN :
1.0 - Brief project Description.
2.0 - Facilities.
3.0 - Scope of Work.
4.0 - Design Standards.
5.0 - Studies to be performed.
6.0 - Design Reviews.
7.0 - Document Requirements.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
1.0 BRIEF PROJECT DESCRIPTION
GENERAL:
HPCL proposes to construct a multi-product Petroleum Receipt Storage cum Despatch
Terminal in the eastern side of Hindustan Mittal Energy Ltd.’s (HMEL) Guru Gobind
Singh Refinery (GGSR) at Raman Mandi near Bhatinda, Punjab, India. Finished white
oil products refined by GGSR will be received, stored and dispatched from the terminal
by laying 2 cross country petroleum product pipelines from the dispatch pump station
put up within the Terminal at Raman Mandi, Bhatinda in Punjab. One pipeline
originates from Raman Mandi dispatch pump station and terminates at HPCL’s existing
Bhatinda Depot. HPCL is exploring the possibility of extending this pipeline upto
Sangrur in future. Second pipeline originates from Raman Mandi dispatch pump station
and terminates at HPCL’s existing Bahadurgarh terminal in Haryana. The refined
petroleum products proposed to be received stored and dispatched thru the pipelines
are mainly two grades of Motor Spirit, two grades of High Speed Diesel, Superior
Kerosine Oil, Aviation Turbine Fuel etc. The consultant needs to review the flexibility
of receiving storing and dispatching other petroleum products, like Naptha in future.
Owner has completed the Detailed Feasibility Study for receipt cum storage terminal at
Raman Mandi for GGSR Products Evacuation Project and has appointed EMPC for the
Despatch pump station and the cross country pipelines. The DFR reports will be made
available to the successful bidder, upon award of contract. If required, consultant to
interact with the DFR consultant for any clarification on the DFR. The same can be
taken as a basis for further review and progress of EPMC job.
2.0 FACILITIES:
The information provided below is meant for general guidance only. The facilities to be
provided shall be firmed up by Consultant with Owner during the implementation of
work.
2.1 GENERAL:
The receipt storage cum dispatch terminal project shall have all required facilities for
receipt, storage and end to end connectivity to pipeline pumping station. The terminal
facilities shall include the storage tanks, product circulating pumps, internal pipelines
for receipt and despatch, fire fighting system, automation, administrative building,
amenity building, engineering stores and warehouse, roads and drains, electrical and
motor control center, electrification, yard lighting, effluent treatment plant, Green belt,
telecommunication system etc. The brief details of the storage cum dispatch station at
Raman - Mandi are elaborated hereunder:
Storage Tanks: Atmospheric Floating roof vertical steel storage tanks, sump tanks of
various diameter and capacity are proposed to be installed in the terminals/ installation.
It is proposed to handle 7 grade of products. Total indicative storage capacity of Raman
Mandi Terminal is @ 2.6 Lakh KL.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Circulating Pumps: Circulating pumps coupled with FLP motors are to be installed in
the pump house. Pumps and pipelines of adequate capacity to be selected based on the
detailed design.
Internal Piping : All Product Piping inside the terminal, manifolds etc. with product
colour coding to differentiate among and from fire water, service water etc.
Fire fighting System: Entire installation shall be covered with fire fighting pipeline
and fire fighting system as per OISD - 117.
Automation System: The storage Terminal shall be fully automated. PLC based
automation is envisaged for terminal which shall cover automation of the oil
receipt/exchange pits, tankfarms, tank and pump valves, operation of fire fighting
system and security system. The system shall be compatible for interfacing with JD
ERP Software that is in use by the owner for product accounting.
Office and other amenity buildings: Office, security room, canteen, workers’ change
room, lab, lube godown, engineering store, MCC room, DG room, fire pump house,
product pump house& any other building/ structures are to be constructed at Raman
Mandi Marketing Terminal.
Roads and Drains: Entire installation shall be covered with roads and drains for proper
water drainage. Separate drains will be constructed for oily water, storm water surface
drains etc.
Oil Water Separator: Oil Water Separator of required capacity to be installed to treat
the effluents/ oily water as per the PCB requirement. The oily water drain shall be
exclusive, closed u/g type covering all areas handling oil where spillage is anticipated.
Electrification: Electrification system to be designed and provided as per the Central
Electricity Rules. There shall be provision of DGs of adequate capacities as standby
power source. Electrification system will consist of receipt of HT power (including
transmission lines from the nearest substation) & distribution within the terminal and
around it.
Green Belt Development: Adequate green belt to be developed in the installation as
per the requirement of the local PCBs and MOEF. Installation also to have adequate
numbers of Lawns, green patches, flower beds, trees/ bushes etc.
Communication system: Entire Receipt Storage cum Despatch Terminal shall be
covered by telecommunication system, internal and external telephone/paging system
and VHF sets. All the three systems shall be interconnected for prompt effective and
efficient communication.
Integration with Turnkey Instrumentation: At all Pumping/Tap
off/Receiving/Exchange pit stations and other places where ever Interlock logics are
required for both product pumping operations and Electric substation operations, PLC
based turnkey instrumentation systems will be installed (thru other EPMC engaged by
the owner) for pipelines. The local station controls thus installed need to be integrated
with the turnkey instrumentation system of the pipeline section.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
3.0 SCOPE OF WORK
Consultant shall deploy qualified personnel to carry out Basic/Detailed design and
Engineering of individual facilities to enable Consultant prompt action on procurement
of material / equipment and finalisation of specifications for works contracts. While
doing so, Consultant shall ensure proper integration of all Project facilities. The scope
of work shall include but not be limited to the following:
The scope of work is divided mainly under following heads but not limited to the
following:
� Conceptualization, Basic/Detail design and Engineering.
� Architectural services for Buildings, layouts, drawings & other civil works.
� Designing of Atmospheric tanks to API-650 and IS 803 standards, internal
pipelines, various buildings, mechanical structures, electrical equipments site
grading , roads, storm water disposal, sewerage water disposal, green belt
development, fire fighting facilities.
� Designing and providing automation system, turnkey instrumentation and
communication system.
� Specifications & preparation of the material required / tenders/ MTOs
� Procurement of the material, equipments& systems
� Floating and finalizing various tenders and material requisitions
� Execution of the work orders, purchase requisition, expediting, inspection, receipt
/issue and handling of the materials and systems
� Monitoring controlling and expediting progress.
� Job Supervision, quality assurance & quality control.
� Implementation of SHE requirements for "Zero Accident".
� Implementation of all requirements pertaining to engagement of contract labour and
providing details required by the owner from time to time.
� Measurement of jobs executed, maintaining owner supplied C.T. registers in
addition to consultants own registers, prompt and timely releasing of
contractors/vendors bills for executed jobs.
� Proper co-ordination with owner , its consultant/s , suppliers, contactors, outside
agencies.
� Assist owner during the pre- commissioning & commissioning including preparing
and submissions of operational manuals.
� Closing the purchase orders, releasing final bills & submission of as built drawings
& other documents.
3.1 Basic/Detailed design and engineering:
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Consultant shall deploy qualified personnel to carry out Basic/Detailed design and
Engineering of individual facilities to enable Consultant finalize specification and take
prompt procurement/ contracting action for material / equipment and works. While
doing so, Consultant shall ensure proper integration of all Project facilities.
3.2 Preparation of process package covering the following items:
1. Design basis
2. P&IDs.
3. Process Flow Diagram.
4. Equipment list and process data sheets.
5. Instrument list and data sheets.
6. Utilities requirement and their specifications.
7. Material specifications.
8. Operation, maintenance and control philosophy
Midway through Basic Design, the Consultant shall advise Owner the requirement of
Permanent Power and Water for operating the facilities to enable owner organize the
same before or co-terminus with the facilities.
4.0 DESIGN STANDARDS
The following design standards shall be used as a minimum in the Scope of work :
4.1 Indian Standards:
Oil Industry Safety Directorate (OISD)
Tariff Advisory Committee (TAC)
Indian Boiler Regulations (IBR)
Bureau of Indian Standards (BIS)
(In case of conflict among Indian standards or with International standards, owner shall
be consulted for deviations which in Consultant’s opinion have cost impact.)
4.2 International Standards:
ANSI
ASME
ASTM
API
OCIMF
ISA
NACE
4.3 Owner supplied Standards/ Documents:
The following Owner supplied design standards/documents shall, in addition to the
above, form the basis of the work:
1. Detailed Feasibility Reports (to be used as a guide).
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
2. Petroleum Product specifications.
3. Contour Survey / Soil Investigation report for the proposed area.
4. Purchase manual/ Operation manual / QC and other manuals / circulars / stipulations /
policies , if required will be provided to the successful vendor .
5.0 STUDIES TO BE PERFORMED
The following process and engineering studies are to be performed as a part of the
Work :
1.. Internal Pipeline Size/Pump Head Optimization
2. Optimization of Drives for various pump stations including Fixed motor drive, Variable
Speed Drives, Diesel Engine Drives etc.
3. Optimization of total tankage basis owner supplied batch size.
4. Design of the tanks and foundations
5. Design of the buildings
6. Architectural drawings for various buildings
7. Design of Sewerage Disposal System
8. Design of the sheds, ware house and mechanical structures
9. Plant layout, layout of the roads, design of storm water drains, pipe culverts, ERC/IRC
etc.
10. Design of the electrical system and equipments.
11. Site grading plan, micro grading plan and beautification
12. Design for collection of oily water spillage, u/g drainage system and design of Effluent
Treatment plant to meet requirement of Pollution Control Board.
13. Fire Fighting facilities.
14. Automation plan for the tankfarms and the fire fighting system and its integration with
other automation systems that are available in the installation.
15. Green belt development plan and environmental protection plan
6.0 DESIGN REVIEW(S)
Periodical formal (every two weeks) and informal (on issuing documents, drawings,
studies, etc.) Reviews of the design work shall be required. Consultant shall provide
time and personnel to participate in these reviews.
7.0 DOCUMENT REQUIREMENTS
The following document/review requirements during the performance of the Work shall
be met:
1. Documents for Approval:
Three copies of all documents are required for Owner’s approval.
2. Drawings for approval:
Besides full size drawings, three copies of 11” x 17” shot down of each drawing shall
also be provided for Owner’s approval.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
3. Studies for Approval:
The studies listed in the section STUDIES must be submitted as draft reports and not as
notes for approval.
4. Approval Turnaround:
Owner shall have fourteen days of review to make comments or approve all documents
/ drawings.
5. Final Approved Documents & Drawings and Studies:
Eight copies of the final approved documents, full size & shot down drawings and
studies are required. Floppies/CDs and CAD diskettes shall also be provided.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
VOLUME III
(SCOPE OF WORK)
C. SCOPE OF DETAILED ENGINEERING
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
C. SCOPE OF DETAILED ENGINEERING
Consultant shall deploy separate team of qualified personnel at the location chosen as
Center of Consultant’s activities for doing Detailed Engineering work basis Basic
Design work. While doing so, Consultant shall ensure proper integration of all Project
facilities. The Detailed Engineering work should produce detailed specifications and
estimated quantity (with +/- 10% variation) for procurement of materials / equipments
and work contracts. Consultant shall endeavor to eliminate change orders. The scope of
work shall include but not be limited to the following:
STORAGE TANKS
1. Preparation of detailed design for most economical foundation system.
2. Prepare detailed design for arriving at size of steel plates required and size wise
quantity, design drawings for the tanks.
3. Specification and design for induction type cathodic protection system for the tank
bottom.
4. Sizing of inlet/outlet nozzles.
5. Design and Specifications for internal floating roof tanks.
6. Design and specification for roof drain system for floating roof tanks.
7. Design and specification for facilities required for quality check of ATF.
RECIRCULATING PUMPS
1. Data sheet specifying minimum, maximum and normal flow rates, suction and
discharge conditions, operating and design temperatures, pressures, NPSH, materials of
construction, seal type, seal fluid etc.
2. Preparation of detailed Engineering specification for recirculating.
3. MTO and MR for all the items.
ELECTRICAL
1. Preparation of electrical design basis, preparation of single line diagram covering
power, lighting, control and instrument power supply.
2. Overall circuit diagrams showing all equipment for power distribution and all essential
connections.
3. Cable schedule for Power Control and Lighting cables
4. Cable layout diagram
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
5. Motor data sheet
6. Layout of electrical equipment, routing of power cables, general lighting for
installations, Buildings and Roads.
7. Earthing scheme covering number of earthing pits, earthing grid, identification of
equipment for earthing, detailing of earthing connection.
8. Identification of process requiring interlocks, scheme for interlocks, identification of
equipments required for interlocks, etc.
9. Technical specification for circuit breakers, transformers, switch gear, UPS, panels,
cables, and all other electrical equipments.
10. Scheme and detailed technical specifications of HT/LT Power line at all locations from
Supplier’s substation upto receiving substation.
11. MTO and MR for all the items.
TELECOMUNICATION/ INSTRUMENTATION / TERMINAL AUTOMATION
1. Piping & Instrumentation diagram for the terminal and integration of the Tank farm
management, fire fighting system, communication system and other instrumentations
like the product receipt exchange pit and dispatch pumping station control room.
2. Cable schedule for Instrumentation cables.
3. Cable layout diagram.
4. Schematic drawing showing instruments.
5. Detailed technical specification of Terminal Automation System covering system
design, hardware, software, communication interface cards, Remote software, terminal
units, cables, connector, application software etc.
6. Scheme & detailed technical specification/job specification for Tank Automation
system.
7. List of all indicating instruments.
8. List of all locally/field controlled instruments & remote controlled instruments.
9. Classification and Technical specifications of all Instruments.
10. Detailed design of logic control loops, interlocks, PLC/other controls.
11. Integration of Telecommunication System and Terminal Automation System with that
of the Pump station for the cross country pipelines and oil receiving exchange pit for
receipt of product from GGSR.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
12. Identification of process requiring interlocks, scheme for interlocks, identification of
software/hardware/logics required for interlocks, etc.
13. Review of vendor design, comments & modifications and suggestions on other
available alternatives.
14. Preparation of Circuit diagrams showing all cable connections.
15. MTO and MR for all items.
ARCHITECTURAL / CIVIL / STRUCTURAL WORKS
1. Overall plot plan location wise for various above ground stations / terminals,
2. Architectural drawings for various buildings at each of the stations / terminals
3. Site grading plan and layout of roads / storm water disposal / sewage disposal at above
locations.
4. Layout for individual facilities at each of the stations including buildings (plant and non
plant).
5. Fire Fighting facilities at all stations.
6. Detailed technical specification for Plant/Non plant buildings, Equipment Foundations,
Roads, Drains, Compound wall etc.
7. Green belt development plan and environmental protection plan.
8. MTO and MR for all items.
MECHANICAL INTERNAL PIPING WORKS
1. Design and sizing of the pipelines for required boundary conditions.
2. Layout and design of piping of the terminal.
3. Design of suction piping, sizing of suction piping from the tanks to booster pumps.
4. Data sheets for all other items, accessories/spares related to above items/work.
5. Detailed technical specifications for all mechanical related items.
6. MTO and MR for all the items.
ELECTRIFICATION SYSTEM
1. Design of the electrical system as per IE rules/ OISD and SEB requirements.
2. Design and sizing of the transformer, Standby DG Sets.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
3. Design of the control gears, control panels etc.
4. Design and sizing of the cables both LT & HT.
5. Design and optimization of illumination plan and finalize for High Masts.
6. Design of the ERCs/IRS and cable trenches and building cablings.
7. Data sheets for all other items, accessories/spares related to above items/work.
8. Detailed technical specifications for all l related items.
7. MTO and MR for all the items
EFFLUENT TREATMENT PLANT.
1. Design and sizing of ETP basis designed surface runoff basis rainfall
2. Establishing BOD/COD requirement at inlet/out let of ETP conforming to requirements
of Pollution Control Board.
3. Designing & Sizing of the ETP for above and oil contenet of 10ppm or less at the final
outlet.
4. Design and sizing of the collection drains, slopes, cleaning and maintenance facilities.
5. Design of the instrumentation system for Automated function of the system
6. Detailed technical specification for all components and related items.
7. MTO and MR for all the items.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
VOLUME III
(SCOPE OF WORK)
D. EPMC SERVICES IN PROCUREMENT/
CONTRACTS OF MATERIALS,
EQUIPMENTS, WORKS AND MATERIALS
MANAGEMENT.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
D. EPMC SERVICES IN PROCUREMENT/ CONTRACTS FOR MATERIALS,
EQUIPMENTS, WORKS AND MATERIALS MANAGEMENT.
This Section details the scope of services of Consultant in procurement/ contracting of
Materials, Equipments and Works. This also details scope of the consultant in Materials
Management of the project.
Consultant shall provide procurement/contracting services for all Materials, equipments
and Works for all components required for completion of the project. Consultant also
shall provide materials management services for all Materials and Equipments required
for the project completion.
The scope shall include but not be limited to:
1. Developing detailed procurement/ contracting procedures inconformity with CVC
stipulations, Systems and Procedures and Limits of Authority Manual of the owner and
in conjunction with the Owner.
2. Establishing vendor lists.
3. Preparing of NIT, Bid Qualification Criteria and floating of tender enquiries.
4. Follow-up for bids, Techno Commercial review and evaluation of responses.
5. Recommendation of supplier.
6. Approval of Supplier Drawings/Designs.
7. Monitoring the procurement progress.
8. Expediting and Inspection.
9. Ensuring proper transportation, logistics and material management.
10. Maintaining the material inventory, consumption statement, MIV / MRV etc.
11. Controlling material inventory and consumption of contractor supplied critical items
like structural/ reinforcement steel, Cement, cables and fittings etc.
12. Reconciliation statement & handing over of the surplus.
13. Insurance claim.
Procurement Procedure:
A detailed procurement procedure shall be prepared immediately after award of
contract submitted to Owner for approval. The procurement procedure shall incorporate
all changes made necessary as a result of contractual agreement between Consultant
and Owner, or as a result of specific requests made by Owner. In general the
procurement procedure should be in line with the Existing Purchase policies, CVC
guide lines and procedures of the owner. Owner's purchase policy, procedures will be
shared with consultant upon award of contract.
Quality Assurance:
Consultant shall review and participate in approving the quality assurance program
will focus on the vendor’s compliance with applicable quality control measures. Such
elements as vendor qualification surveys, provision of correct and complete
documentation to the vendor, inspection and testing during fabrication and production,
monitoring material handling and control procedures of the vendor and proper
handling, storage and shipping of equipments after manufacture are significant aspects
of the quality assurance program. Consultant shall conduct audit of vendors to
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
continually ensure that they are complying with the quality assurance requirements as
stipulated in procurement documents and as approved by the consultant. The consultant
shall actively participate in quality control and ensure that the work confirms to
quality requirements.
Vendor List:
A vendor list is to be prepared for supply of Materials and Equipments in consultation
with HPCL. This list will be based on Consultant’s experience with Indian and
worldwide vendors. Wherever feasible, the endeavor shall be to include as many Indian
vendors as possible. The vendor list is to be submitted for approval by Owner. The
vendor list is to be submitted for approval by Owner.
Warranties and Guarantees :
Consultant shall obtain from the vendors, the best possible warranties and guarantees
covering workmanship and materials for the benefit of Owner and will take all steps to
ensure that such warranties and guarantees are enforced.
Sourcing of Materials and Equipments :
Indian sources of supply shall be solicited for material based on the Owner approved
vendor list. Any decision to purchase materials outside India for reasons of schedule
conflict, lack of competitive pricing or critical nature of the materials will be subject to
Owner’s review and concurrence.
A detailed breakdown of sources of supplies is to be prepared after award of contract.
Cost Estimate:
Consultant shall prepare item wise cost estimate for each material requisition (MR).
This cost estimate will form the basis for comparison of bids and negotiations, if
required.
Inquiries:
A central procurement team is to be assigned by the Consultant in India to manage and
conduct the purchase of all equipments and materials.
Tender Inquiries are intended to be prepared and floated for, but not limited to,
following major materials / equipments for direct procurement (following list is
indicated and changes may undergo depending upon requirements)
- Steel plates
- Product and hydrant Pipes, internal lining ete., if any for the fire hydrant lines.
- Fire Fighting engines, foam systems as applicable and fire fighting materials
and utilities etc.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
- All types of valves including Pressure & Flow Control Valves, Surge Relief
Valves and Safety Valves.
- All types of Pump sets, including Process / Fire fighting pump sets etc.
- Strainers, filters, water separators etc.
- Induction type Cathodic protection systems for the tank bottoms including
TRUs, Battery Banks, Battery chargers
- All HT & LT electrical equipments like Transformers, Switch Boards,
Capacitor banks, Power & Lighting Distribution Boards, DG sets, Motors,
Circuit breakers, Contactors, Relays, etc.
- All Fire fighting equipments like Hydrants, Monitors, Hose pipes, Nozzles,
Hose boxes, Fire Extinguishers, Water gel, Fire suits etc.
- Oil water separator
Inquiries shall, generally, be issued to sufficient number of vendors on two bid basis, so
as to ensure receipt of competitive bids from them or from more acceptable vendors,
unless the number of vendors on the approved vendor list is specifically limited or
where a sole source is stipulated in the Project specifications.
Public/Global Tenders shall be invited in case of insufficient number of approved
vendors (less than min. 6 nos) or for specialized items / equipments for procurement
tenders/works whose value is over Rs.300 Lakhs . With out any prejudice to the above,
Owner reserves the right to decide the nature of tenders to be floated for various
procurement items/work contracts and consultant shall abide by the Owner’s decision.
Bids will be solicited directly from manufacturers except where trade practice in
specific geographical locations necessitate the use of distributorships.
All requests for quotations shall be prepared in English and shall contain the
requirement that formal proposals also be submitted in English.
Inspection by Consultant or a duly authorized third party on behalf of Consultant will
be indicated on all inquiry documents.
Quotation Evaluation :
Consultant shall techno-commercially evaluate the Bids to assess the bid’s compliance
with the technical specifications and commercial terms and conditions.
Consultant shall ensure that all information received from vendors of either a
commercial or technical nature will remain confidential and will not be disseminated to
unauthorized persons.
Consultant shall prepare technical evaluation sheet indicating comparison between
specification of materials/equipments required and offered by various vendors clearly
bringing out technically acceptable and not acceptable deviations with reasons thereof.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
The commercial evaluation sheet shall include, but not be limited to, the following
information:
a. Requisition and item number.
b. Equipment or tag number.
c. Brief description of equipment or materials.
d. Quantity.
e. Shipping arrangements.
f. Comparison of delivery promise with required delivery date.
g. Escalation, if applicable.
h. Quotation validity.
i. Terms of payment.
j. List of exceptions to Terms and conditions.
As deemed necessary by Consultant, pre-award meetings shall be scheduled with
vendors to ensure that all aspects of the inquiry and proposal have been properly
interpreted and evaluated.
Consultant shall, during negotiations with vendors, finalize startup assistance and
maintenance services where required.
Purchase Recommendations :
At the conclusion of the techno-commercial evaluation phase, an evaluation sheet shall
be prepared by consultant and submitted to Owner for approval before opening price
bids. On receipt of Owner’s approval, Consultant shall open Price bids in the presence
of Owner’s representatives as necessary and shall prepare price evaluation sheet. The
consultant shall submit recommendations for placement of order on the selected vendor
on the basis of price evaluation. Upon approval of purchase recommendations by
Owner, a Draft Purchase Order (DPO) including Purchase Requisition (PR) shall be
submitted by Consultant to Owner for releasing Purchase Order on the successful
vendor.
DPOs will include a statement that the equipment concerned is subject to inspection
and the Owner’s representatives will have access to the supplier's work, including
access to their sub- supplier's works, during all stages of manufacturing/testing.
When purchased equipment or materials are subject to technical changes covered by
requisition revisions, or monetary or delivery changes resulting from technical
revisions, suitable recommendations for issuing a “ Change Order” shall be given
promptly to update the current purchase order information. All vendor claims for extra
costs shall be reviewed and justified by Consultant, but approved by Owner. Consultant
to ensure avoidance of such claims with due care during the tender preparation.
Review/Approval of Supplier Data/Drawings/Design :
Consultant shall ensure expeditious submission of data/drawings/designs by the
supplier and review the same within 10 days of receipt at Consultant’s office.
Incompleteness of data submitted by supplier shall be clearly brought out by
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Consultant. Consultant shall endeavor to finalize and approve the
data/drawings/designs submitted by suppliers in the shortest possible time but not later
than 20 days from the date of receipt of first submission. Any delay beyond 20 days in
finalization and approval of submissions made by supplier shall be brought to the notice
of Owner, along with reasons for the same.
Expediting and Inspection:
The proper control of purchased materials includes both expediting and inspection of
materials throughout the manufacturing cycle. Consultant shall perform (or assign to
agreed third party like Lloyds, BV and DNV) inspection and expediting of materials
supplied from Indian and foreign sources.
The objective of this material control effort is to ensure continuous progress in the
fabrication or manufacture of equipment and materials, and to ensure that such
fabrication of manufacture is accomplished in accordance with the technical
requirements and specifications of the project. Accordingly, inspection shall be
performed by Consultant or Consultant appointed organizations approved by Owner
and statutory bodies in accordance with data sheets, drawings, and specifications
incorporated in the commitment documents transmitted to the vendor. Expediting of all
purchase orders, including all revisions or amendments thereto, for this project shall
continue from the time of commitment until the material or equipment has been
shipped.
Expediting reports will reflect the expediter’s assessment of the order status and in the
event of problem areas, the actions taken, suggested or required. Consultant shall be
responsible for anticipating problems and taking corrective action.
In the event of delivery slippage by a vendor, a report shall be issued detailing the basis
for the slippage and advising the action the vendor is taking to improve the revised
delivery promise.
Whether the supplier’s shop is visited periodically or not, the supplier will be required
to submit to the expediting department weekly progress / status schedules covering both
engineering and manufacturing progress.
Vendor data shall be expedited immediately. Detailed schedules for receipt of
engineering information from the vendor should be established, based on the requisition
requirements and in keeping with engineering schedule requirements.
Consultant shall review all “routine data” and “ priority data”. Priority data shall be
specified, procured, handled and distributed expeditiously. Vendor information shall be
designated as priority data only when vendor’s engineering efforts are contingent upon
receipt of that information. Priority data shall be reviewed by Consultant and returned
to the vendor within Ten days of receipt.
Delivery updates and other pertinent expediting information shall be provided for
inclusion in a monthly Material Status Report. Any significant delivery slippage shall
be highlighted and the remedial action noted allowing Consultant to evaluate potential
scheduling problems.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Inspection reports shall be issued upon each visit to a shop. This will ensure resolution
of any noted problems.
When the volume of work placed in a vendor’s shop dictates, or when extensive
problems have been encountered, a resident full-time inspector shall be assigned to the
shop to ensure his attendance during all phases of fabrication or manufacture and timely
resolution of problems.
Where required by Consultant, the noted materials or parts of equipment items and base
material shall be verified utilizing specialized equipment that will ensure the chemical
composition of the material is correct as stipulated for the intended service.
Consultant to assist HPCL to get insurance claim of any accident. Consultant to extend
their services for inspection of repairs or replaced material etc.
Materials Management
Consultant shall be responsible to Owner for materials management for goods
purchased from various suppliers, including steel plates. Consultant shall keep proper
custody of goods and report losses / damages / shortages, if any, to the Owner
immediately on noticing the same. Owner will provide necessary security personnel for
stores / stackyards at Owner’s cost, who will report to the Consultant’s stores
manager.
The scope of Materials Management Services to be provided by Consultant shall
include, but not be limited to, the following :
Free Issue Materials:
1. Receive equipments / materials from suppliers and certify their invoices for payment.
2. Inspect the condition of goods received and issue ‘goods receipt vouchers’ to suppliers /
transporters.
3. Maintain a register of suppliers covering all equipments and materials distinguishing
between manufacturers / stockists / supply houses.
4. Provide a unified materials coding system including catalog structure and compatibility
with other systems.
5. Prepare and submit reports every 15 days indicating the stores on hand, goods in transit,
goods issued to contractors and balance goods to be received as per respective purchase
orders .
6. Maintain stores at site to properly store all the equipment / material and certify bills of
handling contractors and transporters. The space for storing equipment / material and
the office space for stores manager / assistant shall be provided by Owner. Cost of all
labor for handling material / equipment in the stores and cost of transportation of
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
materials from delivery point to stores shall be to Owner’s account for which
service contract shall be finalized by the consultant in consultation with the owner.
7. Issue material for construction to contractors and prepare ‘goods issue vouchers’
thereof.
8. Receive unused material returned by contractors and prepare ‘goods returned vouchers’
thereof.
9. Prepare reconciliation statements to enable Owner to check and take over the balance
stores.
10. Separate material/equipment utilization statements (with value) for jointly identified list
of capital asset items to be submitted at the end of the project to facilitate Owner do
proper capitalization of assets.
Material in scope of contractors Supply :
The consultant shall monitor and control receipt and consumption of key materials in
the scope of contractors supply like Structural steel, reinforcement steel, cements,
cables and fittings etc.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
VOLUME III
SCOPE OF WORK
E. SCOPE OF PROJECT MANAGEMENT
SERVICES :
Article 1. Scope of Project Management Services - Overview.
Article 2. Preparation of Work contracts.
Article 3. Quality Management.
Article 4. Project Implementation Procedure.
Article 5. Cost Control.
Article 6. Project Planning and Control.
Article 7. Progress Measurement.
Article 8. Management Control and Reporting Structure.
Article 9. Inspection.
Article 10. Engineering.
Article 11. Construction.
Article 12. Health, Safety and The Environment.
Article 13. Commissioning, Startup and Performance tests.
Article 14. Acceptance.
Article 15. Initial Operation and Training.
Article 16. Documentation.
Article 17. Assistance in Arbitration.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
ARTICLE 1
SCOPE OF PROJECT MANAGEMENT SERVICES - OVERVIEW
In addition to providing the engineering, procurement services for the Materials and
Equipments described in the EPMC Services in Procurement and Materials
Management of Materials and Equipments, Consultant shall establish a team for the
Engineering and Project Management Services containing all the necessary skills and
disciplines needed for professional management of the Project on behalf of Owner.
Members of the team shall be located in such places as are most appropriate for the
efficient management of the Project. The Central Project Management office shall be
located in India by Consultant.
In addition to the location In India chosen by Consultant as the center of its activities, it
is envisaged that staff will be deployed at the Project Site at Raman Mandi, Bhatinda,
Punjab for efficient management of construction activities at site.
In general, Consultant shall act on behalf, and report to, and be responsible for,
managing the overall Project in detail and directing various contractors and others on
behalf of Owner, for taking or recommending all appropriate action to complete the
Project on time with quality and within budget. The following indicate the minimum
activities the Project Management Services are likely to comprise which include,
without limitation:
a. Preparation of Anticipated Final Cost (AFC) of Project value within six months of
Notification.
b. Draw out detailed specification, exact estimation of quantities , preparation and issue
of tender documents , tender evaluation and recommendation of award and
administration of such other contracts as are needed for the Project;
c. Preparation of item wise cost estimate for each ITB.
d. Administration/ implementation, on behalf of Owner, of all contracts placed for
execution of the Project;
e. Timely release of “Approved For Construction Drawings” to enable contractors to
maintain agreed schedule of work;
f. Coordination of the activities of various contractors engaged by Owner for the
engineering, procurement and construction of the Project to assure effective project
execution particularly at points of interface between respective contractor’s activities;
g. On behalf of Owner and in response to communications from other contractors
involved in the Project, interpretation of technical requirements set forth in the various
contracts and issuance of such interpretation for the guidance of the other contractors;
h. Monitoring, appraising and reporting to Owner on the cost estimation and cost control
performance and scheduling, and schedule control performance of all contractors;
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
i. Development and maintenance of an appropriate system for control of documents
relating to the Project including drawings, specifications, letters, memoranda and other
administrative records but particularly those certificates, operating and other manuals
and other documentation to be retained for maintenance, operational or statutory
reasons by Owner on completion of the Project ;
j. Monitoring, controlling, appraising and reporting to Owner on the quality and safety
aspects of engineering design and construction by all contractors involved in the
Project;
k. On behalf of Owner administering changes in the scope of other contractors and
reporting on the same to Owner ;
l. Monitoring, controlling, appraising and reporting to Owner on procurement activities
by all contractors, including transportation, import into India and inventory control;
m. Receiving and reviewing invoices and administering/certifying payment to other
contractors involved in the Project;
Owner has established a number of objectives and priorities to guide Consultant and
other contractors in implementation of the Project. These are set out in various
provisions of this Section, and cover:
� Safety in construction and operations;
� Governing laws and regulations;
� Completion schedule;
� Use of Owner’s resources;
� Enhancement of national skills;
� Implementation of regulations for engaging contract labour.
� Public relations.
Consultant shall ensure that its own activities and those of all contractors,
subcontractors and suppliers employed on the Project comply in full with these
objectives and priorities.
ARTICLE 2
PREPARATION OF ITB FOR WORK CONTRACTS
The Basic Design and Detailed Engineering work done by Consultant should lead to
developing a Design package comprehensive enough for inviting contract bids for
various works for GGSR Evacuation project. Midway through the Detailed Engineering
work, Consultant shall prepare draft Invitation To Bid (ITB) for respective work
contracts/ Services and submit the same for Owner’s approval. The basic inquiry
principles like type of contract, bidding limit dates, conditions of payments and various
other controlling parameters will have previously been proposed to Owner and approval
obtained prior to issuance of final ITBs.
ITBs are intended to be prepared for, but not limited to, the following works.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
- Tankage Construction works
- Internal Pipeline works at Terminal
- Electrical / Instrumentation works pertaining terminal
- Terminal Automation works
- Compound wall, gates and watch towers
- Roads, culverts and Drainage works
- Site Grading works
- Effluent Treatment Plant
- Communication system.
- HT / LT power line laying works from Supplying Substation to
receiving transformer
- Bore wells, water supply lines and make-up water for fire fighting.
- Miscellaneous services for any surveys etc..
The estimates of above bids shall be based on detailed rate analysis / recently placed
purchase orders. Consultant to submit detailed item-wise rate analysis to HPCL
1. Pre qualification of Contractors :
Consultant shall prepare document for pre-qualification of bidders and obtain approval
of Owner for the same. The pre-qualification criteria shall be published in Newspapers
for estimated contract values exceeding INR 300 lakhs for inviting bids from
prospective bidders meeting the pre-qualification criteria. The pre-qualification
document shall be so developed by the Consultant that it will facilitate rapid and sound
evaluation in order to allow Consultant to select the required number of bidders.
Consultant shall obtain Owner’s approval for sending tender inquiry to the pre-qualified
bidders.
Alternately, ITBs shall be given to the respondents of NIT to enable them submit
Prequalification Documents and bids together in one step. Consultant shall evaluate
Prequalification Documents and obtain Owner’s approval for opening / evaluating
Techno-Commercial bids of pre-qualified bidders.
For estimated contract value less than INR 300 Lakh, Limited tender inquiry shall be
floated by Consultant to contractors drawn from Consultant’s vendor list and approved
by Owner.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
2. Preparation of ITBs :
Based on the Detailed Engineering, Consultant shall propose draft ITBs for work
contracts/ Services and upon approval of the same by Owner, release the same to pre-
qualified bidders. The ITB shall contain detailed technical specifications and terms &
conditions to facilitate submission of unambiguous bids. Consultant shall structure the
ITBs to include but not limited to the following:
- Instructions to Bidders.
- Scope of work
- Conditions of contract.
- Engineering/ Technical specifications and drawings (which will include but not
be limited to) depending upon their applicability for respective ITBs.
� Project design data (Hydrographic, Geotechnical and Meteorological), soil
bearing, battery limit conditions, etc.
� General engineering standards, specifications, codes and local customs
regulations and/or agency requirements.
� Process flow diagrams (PFDs) where ever applicable.
� Process description.
� Preliminary plot plans and layout.
� Process and instrumentation diagrams (P&IDs).
� Equipment lists.
� Technical data sheets of equipment and machinery.
� List of materials / equipments included in contractor’s scope.
� Specification of supply items included in contractor’s scope.
� Instrument lists.
� Detailed specifications of works.
� Electrical one-line diagrams.
� Safety instruction and basic design data for fire fighting.
� Job procedure instructions.
� Environmental considerations.
� Preliminary Drawings to enable the bidder to quote.
- Bill of quantities (BOQ).
- Schedule of Rates (SOR).
- Construction specification.
- Construction time schedule with resource deployment.
- Testing and inspection requirements.
- Commissioning procedure.
- Acceptance procedure.
The ITB will also stipulate that the contractors shall provide the following with their
proposal for evaluation:
- List of participating local contractor(s) and supplier (s).
- Detailed execution plan.
- Manpower plan and manpower requirements.
- Quality Assurance and Control Procedure.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
- Confirmation of codes, standards, regulations and local customs and/or agency
requirements.
- Commissioning plan.
The ITB will specify a comprehensive training program for the Owner’s personnel
pertaining to Turnkey Instrumentation, Automation System etc. to be able to operate
and maintain the Project facilities. This training program will be provided by the
contractors and will be organized under the guidance of the Consultant. A description
of the procedure to be complied with for the appraisal of bids and bid tabulation shall
also be provided.
The selection criteria proposed by the Consultant shall:
- ensure that the bids are in compliance with the requirements set out in the ITB.
- prepare the quantifiable economic elements to be considered to compare the
bids on the same bases, for instance; rate for modifications, cost of delays in the
schedule, costs involved by conditions of payment, rate, rate of exchange for
price comparisons, etc.
The selection criteria thus developed shall be approved by Owner.
3. Evaluation of Bids :
The evaluation of bids against each ITB shall be done in five stages as described below:
First Stage:
After unpriced bids are opened, the Consultant shall check that the required documents
have actually been supplied and duly signed, that the period of validity is correct and
that the bids as a whole are correct. If necessary, the bidders shall have to supply, as
soon as possible, any clarifications and/ or additional information requested.
Second Stage : Techno-commercial evaluation of unpriced bids.
The detailed review shall concern:
- Scope of services and supply.
- Compliance with the technical requirements set out in the project specification.
- Compliance with individual layout drawings proposed with the general layout
plan.
- Compliance with general specifications, codes and standards proposed in the
ITB.
- Compliance with commercial and general terms and conditions.
- Concurrent commitments.
- Compliance with Acceptance Procedure.
Third stage: The Consultant shall submit detailed evaluation sheet of unpriced bids to
owner clearly specifying the technical and commercial acceptability/non-acceptability
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
of offers. Upon approval by Owner, the price bids of technically and commercially
acceptable parties shall be opened by Consultant.
Fourth stage:
Detailed review of price bids.
- Basic price including break-up in INR and respective Foreign Currency, quoted
against BOQ in the SOR.
- Unit rates.
- Delivered Cost.
Fifth stage :
After completion of price evaluation, a purchase recommendation shall be submitted to
Owner. Upon decision by Owner on bidder with whom negotiations are to be done, the
Consultant shall assist Owner in this process.
4. Draft Agreement / Draft Purchase Order
Upon approval of purchase recommendations by Owner, the Consultant shall submit
Draft Agreement / Draft Purchase Order to Owner.
ARTICLE 3
QUALITY MANAGEMENT
Consultant has overall responsibility to Owner for quality management throughout the
Project. Consultant shall prepare an integrated overall Quality Assurance Program
(QAP) which satisfies recognized international standards approved by Owner e.g. ISO,
BS, ASME, OISD, ASTM, API etc.
Consultant shall have an established quality management organization which shall be
responsible for monitoring, controlling and auditing compliance with the QAP
throughout the whole Project. The organization shall comprise sufficient numbers of
suitably trained and qualified staff to ensure that all requirements of the QAP are
satisfactorily implemented by the Contractors.
The QAP shall cover, but shall not be limited to:
a. Verification and approval of methods used and documentation produced during
engineering and construction work;
b. Inspection, handling and identification of equipment and materials, and proper
documentation ;
c. Planning , agreement of methods, and techniques, supervision, inspection, acceptance
tests and proper verification and acceptance of documentation during construction
work;
d. Field inspection and testing procedures;
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
e. Consultant to assist HPCL in filling insurance claim, if any. Consultant shall provide
services for ascertaining repair cost and consultant to carry out inspection for repair of
material or replacement.
f. Operating, maintenance and training manuals.
Consultant shall prepare for Owner’s approval and execute a program of quality audits
for its own, and contractors’ activities. Such program shall be submitted as part of the
QAP for Owner’s approval. Owner shall have the option to provide representatives to
participate in any quality audits carried out on the Project.
Owner reserves the right, with due notice, to carry out audits of Consultant’s activities
for compliance with QAP.
ARTICLE 4
PROJECT IMPLEMENTATION PROCEDURE
The Project Implementation Procedure shall include, but shall not be limited to the
following:
a. Consultant’s organization at different phases including organograms and relationships
with Owner and all other contractors involved in the Project.
b. The overall management information system and interface philosophy to be used in the
Project.
c. Consultant’s co-ordination procedure including numbering of correspondence, contact
persons, correspondence format and system, administration of instructions and reports,
design review and technical data, project cost control and reporting, planning
monitoring and progress reporting, estimating, invoicing and accounting, document
control, safety review procedures, punch listing, field inspecting and testing
acceptances.
d. List of reports to be submitted by Consultant to Owner. Formats of these reports and
timetable for issues.
e. Co-ordination procedures for contracts including procedures between contractors,
Owner and Consultant.
f. Procedures for:
- HSE implementation and control mechanism zero accident.
- Safety and technical audits.
- Quality management at various stages.
- Construction supervision, inspection and quality control.
- Schedule control.
- Cost control.
- Document control and handover to Owner.
- Others.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
g. Plans for monitoring and controling contractors’ activities at each stage.
h. Summary Project schedule.
i. Forms to be used in the Project
j. A document detailing the information systems strategy for the complete facilities shall
be developed in conjunction with Owner & contractors and shall detail the following:
- the information systems used within the contractors with which electronic data is to be
exchanged both during the Contract and on hand over of the facilities in each contract;
- the information systems that Owner and Consultant intend to use both during the
Project with a timetable for their proposed use;
- a program for the downloading of electronic information from the contractors to both
Owner’s information systems and those of the Consultant;
- detailed specifications of the data to be exchanged and the media format to facilitate the
exchange;
- the individuals responsible for the execution of the data exchange within the
contractors, Consultant and Owner;
Consultant shall critically review and obtain approval from Owner for the above Project
Implementation Procedure within two months of contract award. Within the first week
of the contract, Contractor shall issue interim procedures sufficient to cover the first
three month of activities by all parties.
ARTICLE 5
COST CONTROL
Consultant shall provide a comprehensive control service using a Work Breakdown
Structure (WBS) which is compatible with job control and planning requirements, and a
Cost Breakdown Structure (CBS) which is compatible with Owner’s accounting code
structure. All coding structures are to be subject to approval by Owner. Consultant shall
ensure that all WBS used by other contractors are similarly compatible. Consultant
shall consolidate all cost control and estimating information from contractors and
suppliers for presentation and reporting to Owner.
1. Coding Structures:
Consultant shall ensure that:
(a) The WBS is designed on a hierarchical basis to permit roll up of data from the
job control or work pack level to summary level for reporting purposes. At the
work pack level jobs will be controlled using Cost Time Resource (CTR)
schedule;
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
(b) The CBS is designed on a hierarchical basis to permit roll up of data to an
approved summary level for reporting.
Summary and intermediate reporting levels for WBS and CBS are to be common to all
other contracts.
2. Reporting:
The following reports are to be generated by Consultant for Owner on the basis of its
own observations and reports received from other contractors and suppliers of long lead
items:
Cost Reports: Consultant is to provide monthly, a comprehensive cost report set out in
accordance with WBS/CBS. The cost report is to be summarized to an intermediate
level into logical Project areas for other contracts and supply items and then
summarized further into a top level management reporting summary. These reports
shall show the following information as a minimum requirement:
(a) Initial control estimate;
(b) Current control estimate;
(c) Expenditure to date (Value of work done);
(d) Estimate to complete;
(e) Anticipated final cost (“AFC”);
(f) Over/under of AFC against current control estimate;
(g) Expenditure this period;
(h) Commitment to date (approved requisition value);
(i) Commitment this period;
(J) Value of invoices paid.
Contract and Commitment Reports : Consultant shall prepare and submit to Owner
at monthly intervals a listing of all major contracts stating AFC, commitment, claims
outstanding and progress status.
Consultant shall submit, with the monthly cost report, total project commitment
curves plotting actual commitment against planned commitment.
Change Order Reports: Consultant shall prepare and submit to Owner at monthly
intervals, a listing of all Change Orders placed on other contractors setting out the
status and value of each Change Order.
Anticipated Final Cost : Consultant shall regularly review the AFC of the Project.
The implications of these reviews shall be discussed with Owner prior to the monthly
input into Consultant’s reporting system. Explanation of variances, shall be provided
on a monthly basis.
3. Expenditure:
Consultant shall maintain within its record of expenditure, all in accordance with the
WBS/CBS, the following information:
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
(a) Expenditure ( the value of work done and materials received to date);
(b) Phasing of expenditure forecasts;
(c) Value of invoices paid;
(d) Details of retentions;
(e) Explanation of variance between planned and actual expenditure.
Consultant shall submit with the monthly cost report total project expenditure curves
showing actual expenditure plotted against planned expenditure.
4. Cash Flow and Payment Schedule:
To assist Owner in meeting monthly commitments, Consultant shall prepare and update
a monthly payment schedule. Consultant shall certify and recommend to Owner the
progress payment for the other contractors, and suppliers.
5. Asset Register:
Consultant shall compile and update monthly an asset register including cost of each
asset for the complete Project for hand over to Owner on completion of the Project.
Consultant shall submit quarterly reports indicating assets completed during the period
and on cumulative basis and cost thereof.
6. Diary of Events:
Consultant shall maintain a Chronological Diary of Events recording all major
milestone achievements. This shall be appended to monthly reports.
7. AFC Estimate:
Any changes or developments in strategy over the life of the Project will be reflected in
updates to the AFC estimate.
ARTICLE 6
PROJECT PLANNING, MONITORING AND CONTROL
The Consultant’s responsibilities in terms of project planning, monitoring and control
are twofold. First, the Consultant shall ensure that the other contractors develop and
maintain a comprehensive planning, progress monitoring and control service as
required by contract. Second, the Consultant shall operate a similar service, at summary
level, that interacts directly with systems used by the contractors and provides the
vehicle for informing Owner of all aspects of Project scheduling, progress and control.
The service shall incorporate modern systems and techniques for the acquisition,
analysis and presentation of data. The Consultant shall ensure that the service is
compatible with similar service on the Project and that programs and progress charts
align with the approved WBS for the Project in such a manner as to facilitate the
establishment of a clear, hierarchical path from detail to summary level.
The principal objective of the planning service is to provide an effective work planning
and control system. This shall be achieved by the preparation of programs that display a
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
coordinated work approach and which are adequately resourced and scheduled within
specified milestones and key dates. Physical progress against work packages shall be
measured and reported, highlighting trends and actions required to maintain or improve
progress. Future activities shall be reviewed in advance of execution to ensure
sufficient data and resources are available to maintain the project schedule.
1. Project Master Schedule:
Consultant shall submit to Owner for approval prior to award of the contract, a Project
Master Schedule that shall clearly identify all project milestones and targets and reflect
the Consultant’s Tender Schedule. Subsequent to approval by Owner the schedule shall
be used as the management control schedule for the Project and shall be updated and
issued monthly. The schedule shall be developed as a summary critical path network
and be presented as a logic-linked bar chart. It shall show work package man-hours,
major resources, interrelationships, major dependencies, critical activities and key
events, consistent with the WBS at project summary level.
The master schedule shall define in appropriate detail the sequence and timing of work
packages and activities by which the services shall be performed and by which progress
shall be monitored. Where necessary it shall identify all key interactions, reviews and
approvals between suppliers and the other contractors, outside agencies, and third
parties to ensure uninterrupted progress to timely Project completion. In line with the
project WBS, the master schedule shall be updated using details generated at lower
level in terms of physical progress achieved, remaining duration and forecast
completion.
An essential part of the schedule submission shall be a Cost/Time/Resource (CTR)
activity catalog, prepared to an agreed format, showing scheduled start and finish dates,
resource requirements, dependencies and deliverables as a minimum.
2. Other Contractors’ Programs:
Within six weeks of other contract awards, the Consultant shall review and approve the
control programs produced by the contractors, and all requisite support documentation
including manpower profiles, progress curves, deliverable registers and procurement
schedules. Before final approval, the Consultant shall advise Owner regularly of the
progress made in producing these documents to the required standard.
For the purpose of reporting, Consultant shall prepare and maintain a set of tabulations
that adequately summarize the detailed registers produced by the other contractors.
These shall include information or design deliverables, procurement of
materials/equipment, construction procedures and design holds.
3. Interface Schedule:
Within eight weeks of Contract award, Consultant shall issue, for approval by Owner, a
schedule which details information required by the Project as a whole, from Owner
between contracts, from outside agencies or third parties. Schedule implications of the
interfaces shall be clearly demonstrated.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
4. Trend Reports:
Consultant shall highlight and give early warning of trends to result in deviations from
Project activities/schedules/cost, identifying the reason, and reporting the appropriate
remedial actions taken to Owner.
5. Exception Reports:
Consultant shall provide a report itemized in conjunction with the master schedule
declaring any activities behind program at each update and defining contract discipline,
delay to the Project and reason for the delay.
ARTICLE 7
PROGRESS MEASUREMENT
Achieved progress shall be based on a detailed physical assessment of work done, in
percentage terms, and summated to contract and project summary level, using assigned
weightages, Consultant shall be responsible for making sure that the physical progress
measured is a fair reflection of work status and that summations are accurately
calculated.
1. Progress “S” Curves:
For reporting purposes, Consultant shall maintain a composite set of progress S curves
and tabulations that show, by major element, planned, achieved and forecast figures.
2. Manpower Histograms and Man-hour Tabulations:
For reporting purposes, Consultant shall maintain a composite set of manpower
histograms and man-hour tabulations that show, by major element, planned and actual
figures.
3. Updating:
At monthly intervals during the life of the Project, Consultant shall update all summary
progress documents using, where necessary, detailed figures produced by the other
contractors. Consultant shall update the project master schedule monthly using a
superimposed time now line that indicates slippage to each element of the Project and
to the Project as a whole.
ARTICLE 8
MANAGEMENT CONTROL AND REPORTING STRUCTURE
This Article describes Consultant’s responsibilities with respect to management control,
co-ordination and reporting of the Project Scope of Work. Proven computer systems
shall be used to assist with these functions, and agreed coding structures shall be used
to integrate service functions and ensure compatibility of contract and Project systems.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
1. WBS:
The WBS is a Project model providing a framework for management of the scope. The
model shall be used to define the Project in a manner that facilitates the integration of
all functions and progress assessment at detail and summary levels. Deliverables and
services to be provided under the various contracts and by third parties shall be
assigned to work packages and, at a more detailed level, Cost/Time/Resource (“CTR”)
activities. Proposed work packages and CTRs shall form the essential structure of the
Project and control programs and their breakdown will depend on the other contractors
work organization and methods.
2. Coding Structure:
The Project coding structure shall be developed by the Consultant within two weeks of
award and include work package, CTR, discipline, area and system.
3. CTR Activities:
CTRs shall be used to plan and control the execution of services under the various
contracts and, where necessary, in other areas of the Project. It shall be the Consultant’s
responsibility to ensure that the other contractors submit CTR catalogs as required by
contract, and that the following information is included on each CTR sheet as a
minimum:
(a) Code and description;
(b) Reference to inputs required to perform the activity;
(c) Output deliverables generated as a product of the CTR;
(d) Reference to other CTRs which are dependent on the completion of the current
activity;
(e) Estimate of man-hours and cost by discipline for the CTR at both detail and
summary level;
(f) Work package and program reference;
(g) Scheduled start and finish dates.
4. Reports :
The following lists the reports to be provided as part of the Consultant’s services:
Weekly Report: At the end of each week during the Project, Consultant shall report to
Owner by facsimile transfer or telex. The essential information in the report shall be:
(a) Main events, problem areas and remedial actions during the week;
(b) Information and decisions urgently required by other contractors.
Monthly Report : Consultant shall prepare a comprehensive monthly progress report
with a cutoff on the last Friday of each month. The report shall be delivered to Owner
within six working days following the cut-off. The format and content of the report
shall be agreed with Owner and, as a minimum, contain the following information:
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
(a) A summary statement on the Project, highlighting Problem areas and remedial
actions ( with their impact on schedule/cost analyzed through computer
schedule network vis-a-vis alternatives available); achievements made during
the month shall be itemized and compared against the plan;
Summary planned/achieved/forecast figures for design, procurement and
construction along with detailed statements required under (b), (c) & (d) given
below:
(b) A statement on design, covering progress, highlighting targets achieved,
deviations from schedule and actions proposed. Significant additional work or
rework resulting in change orders shall also be noted and an indication given of
any schedule delays;
(c) A Statement on procurement referring to material /equipment control schedules
and indicating activities that have slipped or become critical;
(d) A statement on construction, citing achievements in the period, with an
explanation of deviations from the program, problems encountered and remedial
actions. This shall cover status of the work relative to the program, including
variations and subcontracts;
(e) Cost report;
(f) QA report;
(g) A statement on services covering:
- Planning and scheduling;
- Change control;
- Contracts;
- Finance;
- Computing;
- Administration;
- Organization;
- Stock control;
- Safety performance and accident statistics.
(h) Graphical and tabular section containing:
- Updated project master schedule;
- Progress S curves for design and construction showing planned and
achieved figures for the various contracts;
- Manpower histograms for design procurement and construction showing
planned and actual figures for various contracts;
- Summary tabulations showing the status of deliverables/drawings,
procurement of materials, equipment and procedures;
- Interface matrix showing data urgently required by other contractors.
5. Project Systems:
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Consultant shall monitor the other contractors’ project information systems throughout
all phases of the other contracts to ensure compliance with the overall Project systems
strategy detailed in other areas of this ITB and shall monitor the delivery and integrity
of electronic data between the other contractors, Consultant and Owner.
6. Numbering Systems:
Within one month of contract award, Consultant shall develop and issue all definitive
numbering and identification systems which shall be reviewed and approved by Owner.
Compliance of the other contractors with all mandatory numbering and identification
systems shall be monitored and controlled by the Consultant. Any cases of non-
compliance shall be resolved by the Consultant.
ARTICLE 9
INSPECTION
Consultant shall familiarize itself with any statutory, insurance or code requirements for
certification. Where inspection is required, it will be carried out by
Consultant/Consultant approved organizations who meet the approval of Owner and
statutory bodies. Certification of certain selected items of equipment and materials is
likely to be required.
Consultant shall audit other contractors to ensure the effectiveness of procedures for
assuring that all manufacturers, fabricators, suppliers and construction subcontractors
comply with the inspection requirements for the production of materials and equipment
and for construction.
Before mechanical completion is agreed, Consultant shall ensure that other contractors
carry out inspection of the facilities in their respective contracts to check that erected
facilities are complete, and conform to approved flow diagrams, construction drawings,
manufacturer’s prints, and specifications.
ARTICLE 10
ENGINEERING
1. Engineering standards:
In addition to the design standards for Basic Design and Detailed Engineering work set
forth elsewhere in this ITB, the engineering standards to be used during the various
contracts will be issued prior to award of these contracts. Consultant shall keep these
standards in constant review as the Project Progresses. Any amendments found
necessary to the standards shall be justified to and discussed with Owner before
implementation, and Consultant shall maintain and update the standards and ensure all
work is carried out to updated standards. Any non-conformances to standards shall be
fully documented and a register thereof maintained. The final updating of the standards
shall be made prior to commissioning for handover to, reference and ongoing use by the
operational site.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
2. Detailed Engineering:
Consultant shall ensure that all specification, drawings and requisitions are produced in
a timely manner in accordance with contract.
Consultant shall review and approve, on behalf of Owner the drawings/designs
submitted by contractors pertaining to the design facilities included in the contractors’
scope. Consultant shall endeavor to approve designs/drawings submitted by various
contractors in the shortest possible time but not later than 30 days. Any delay beyond
30 days shall be brought to the notice of Owner, along with reasons.
Consultant shall ensure compliance with all statutory rules and regulations, in particular
national regulations concerning environmental protection, Department of Factories and
Pollution Control Boards etc.
Consultant shall critically review and evaluate any request by contractors for changes to
the scope of contract, keep Owner fully apprised of reasons, acceptability or otherwise,
and recommend a course of action for each event.
Consultant shall submit brief weekly engineering reports to Owner describing the work
of the current week and problems encountered with solutions arrived at or planned and
any anticipated problems with proposed solutions. The report will also include:
- List of documents received for review;
- List of documents approved or found unacceptable.
Consultant shall submit its own monthly detailed and confidential report to Owner
which shall include:
- Staffing by contractors with comments on the adequacy in number and
qualification;
- Report on contractors’ general activities and engineering status;
- Actual performance expressed as percentages complete by area as well as
overall compared with those planned by the contractors.
ARTICLE 11
CONSTRUCTION
Consultant shall manage and supervise other contractors’ activities at site and
coordinate with contractors, such that the construction of the Project is carried out by
the contractors according to the procedures and quality assurance program agreed
between Owner, Consultant and the contractors.
Consultant shall be deemed to have full knowledge of the applicable codes and
standards, laws and regulations, safety rules and regulations, regulations for contract
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
labour, local conditions and environmental aspects in Punjab and India, and shall
comply with the requirements thereof where applicable.
Consultant shall assign construction specialists at site to ensure that the Project is built
according to the time schedule and to approved codes and standards, specifications and
drawings. These activities shall include, but not be limited to, the following:
I. review and recommend to Owner on the adequacy of contractors’ supervisory
personnel, and craftsmen in terms of qualifications and numbers;
II. Coordinate the activities of contractors and these respective subcontractors to ensure
that their work plans are such that the subcontractors avoid interference with one
another;
III. Consultant shall monitor and control the approved construction plan on monthly basis.
If any time lag is observed in the progress, consultant to analyze & advice party for
additional steps to be taken to boost the job progress and make recommendations to
owner on any action to be taken to maintain schedule.
IV. Review and recommend regularly on contractors’ allocation of manpower and
construction equipment;
V. review and approve, on Owner’s behalf, contractors’ work methods, with special
emphasis on safety and quality ;
VI. review and approve the procedures proposed by contractors for the inspection by
Consultant of each item of construction work and the witnessing by Consultant of each
construction activity in so far as inspection and witnessing are required;
VII. Supervise, inspect and certify that quality of the contractors’ work to ensure that all
work is adequate for the purpose intended, is in accordance with good engineering and
construction standards and practices, drawings and specification, and is in accordance
with the quality assurance program and conforms with the contract provisions;
VIII. Monitor and control quality of the contractors work and documentation.
IX. Lead, monitor and control SHE at work place by the contractor to ensure Zero accident
site.
X. ensure that adequate records are maintained, so that expediting for rectification is made
easy and systematic;
XI. review and certify the contractors’ claims. Certify and recommend to Owner on the
progressive payments of the work according to the work completed;
XII. On behalf of Owner supervise and agree with contractors on a phased completion
program, to facilitate a logical, mechanical completion program.
XIII. Closing the all open purchase orders / work orders / contract to close project sites.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
XIV. review contractors’ detailed proposals for the startup and the conduct of the
performance tests, and advise Owner and the contractor accordingly to ensure that all
the activities will be carried out in a safe and efficient manner.
XV. supervise close-out of contractors’ work and certify and make recommendations to
Owner on the acceptance of construction completion certificates, mechanical
completion certificates, provisional acceptance certificates and final acceptance
certificates for the Project, by plant system unit and block as relevant;
XVI. report immediately about any use of materials not in accordance with the drawings,
specification and contract, and supervise its removal from job site;
XVII. supervise all works required for modifications requested or approval by Owner in
accordance with the Project procedures;
XVIII. Carry out HAZOP studies and ensure that actions have been taken based on as-built
documentation;
XIX. Review and recommend safety and labour relations procedures prepared by other
contractors in line with all applicable codes, regulations and Owner requirements.
Monitor safety and labour relations and take action on behalf of Owner on all problems,
violations and inquiries;
XX. inspect and record site activities and oversee that documentation is kept up-to-date and
in first rate condition in preparation for completion of the Project. Consultant shall
ensure that all as- built drawings for the Project are recorded correctly and compiled
and submitted by the contractors as stated in the contract. Consultant shall submit the
same to Owner after approval
XXI. Maintain CTE Registers
ARTICLE 12
COMMISSIONING, STARTUP AND PERFORMANCE TESTS
1. Mechanical Completion
At a date prior to mechanical completion to be agreed with Owner, Consultant shall
recommend to Owner for approval of the operating manual prepared by Consultant.
Consultant shall review and recommend for approval the program, and supervise the
mechanical completion work performed by contractors. Upon successful completion of
mechanical completion work, Consultant shall review and recommend approval of
construction completion certificate documentation.
Consultant shall approve as required all procedures, plans, schedules and necessary
certification for construction completion by the other contractors. The construction
completion of individual sections of the Project shall be programmed in accordance
with the overall commissioning plan.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Consultant shall ensure that all necessary personnel from equipment suppliers are called
to attend the pre-commissioning activities as provided for in the equipment purchase
orders.
Consultant shall prepare for approval by Owner and implement all necessary
procedures to ensure safety of personnel working on construction activities at the same
time as field inspection, testing and commissioning is in progress.
Consultant shall supervise contractors’ work such that phased mechanical completion
and commissioning takes place as determined by Owner’s business needs.
2. Commissioning and Startup:
Commissioning and startup is to be carried out by Owner with assistance from other
contractors.
Upon Owner’s approval of the mechanical completion of the work, and when it is
deemed suitable by Owner, the commissioning work may commence according to the
plans and schedules prepared by Consultant.
Consultant shall form and organize a start-up team to supervise and monitor the
commissioning, startup, performance test and initial operation of the facilities
consisting of representative of Owner operating personnel, equipment suppliers,
Consultant and contractors and shall ensure that the contractors provide sufficient
numbers of skilled labor that is needed to complement the Owner startup personnel and
to perform activities which include the running or operation of equipment, necessary
adjustments and hot alignment checks and the running of component parts as unified
system. This shall also include a demonstration of the operability of spare equipment.
Consultant shall ensure that the contractors provide sufficient manpower, special tools
and spare parts necessary for the commissioning activities.
Consultant shall ensure that the commissioning activities will, as a minimum include:
- Compliance of pre-commissioning audit by OISD / HPCL
- Operational tightness testing and Pneumatic testing.
- Pre-startup inspections by governmental bodies.
- No load test of rotating equipment
- Filling of lubricants.
- equipment operation to make vibration, governor trip, and safety device checks,
and other required operating tests and adjustments.
- hot alignment checks and running of component parts as a unified system.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
- adjustments and replacements of mechanical seals, packing and accessories, as
required.
- flushing, blowing, chemical cleaning & air cleaning.
- installation of temporary screens, strainers, and blinds.
- necessary purge operations, including installation of temporary purge piping,
hoses or equipment connections.
- checking of bores of orifice plates and installing these plates after flushing
operations.
- functional check on all instruments and controllers, instrument calibrations with
standard test.
- equipment and all required adjustments and control point settings.
- check all instrument loops for proper functioning.
- checks on pipe hangers, supports, and guides for hot/cold settings and necessary
adjustments.
- checking and recording positions of all valves.
- conduct simulation runs to allow run-in operational testing of the equipment.
-- Tank roof floatation with water / product.
- Commissioning checks of tanks as per OISD
- Commissioning of Fire Engines & Fire Alarm System
- conduct simulation runs to allow run-in operational testing of the OWS.
- DG Set Commissioning
Consultant shall organize and ensure that all defects and deficiencies found during the
course of commissioning are rectified by the respective contractors.
Consultant shall supervise and monitor all commissioning and startup activities and all
performance test runs which will be carried out by the contractors. All performance test
results shall be reviewed and certified by Consultant and subsequently recommended
for Owner’s acceptance.
Consultant shall report to Owner on a weekly basis on the progress and status of
commissioning and startup work.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Consultant shall ensure that all commissioning records and log sheets are properly
collated and submitted to Owner as part of contractors’ mechanical completion
certificate approval documents and provisional acceptance documents as relevant.
3. a) Factory Acceptance Tests:
Consultant shall witness the Factory Acceptance Tests in the premises of contractor for
terminal automation etc. which will be carried out by the respective contractors.
b) Site Acceptance Tests:
Respective contractors shall carry out the Site Acceptance Tests of terminal automation
etc. which shall be witnessed by Consultant at site.
ARTICLE 13
ACCEPTANCE
1. Construction Completion Certificate:
Consultant shall review submittals from contractors for construction completion as
defined in the respective contract and advise Owner on approval and issue of
construction completion certificate to the contractors. Consultant will be responsible for
all punch listing to allow recommendation of construction completion certificate.
2. Mechanical Completion Certificate:
Consultant shall review submittals from contractors for mechanical completion as
defined in the contract and advise Owner on approval and issue of certificates of
mechanical acceptance. Consultant shall review the certificates of mechanical
completion issued and advise Owner when the various parts of the Project are ready to
start up and are in accordance with contract and specification.
3. Provisional Acceptance:
Consultant shall prepare and recommend approval of certificates of provisional
acceptance when requested by the contractors and recommend their issuance when the
commissioning work, start up and test runs of the Project have been carried out
successfully, and the performance test results are to the satisfaction of Owner in
accordance with the contract and specification.
4. Final Acceptance:
Final acceptance for the facilities defined in contract shall be issued by Owner on
request from contractors at the expiry of the defects liability period of one year, in
accordance with respective contract.
5. Provisional Acceptance of Consultant’s Work:
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Provisional acceptance of Consultant’s work occurs when the last contractor’s
provisional acceptance certificate is approved by Owner.
6. Final acceptance of Consultancy Work:
Final acceptance of Consultant’s work occurs at the expiry of the defects liability
period of one year of the last contractor in accordance with the contract if there is no
deficiency in Consultant’s or contractors’ work.
ARTICLE 14
INITIAL OPERATION AND TRAINING
During the engineering and construction of the Project, Consultant shall prepare
programs and schedules and perform initial operation and training services which shall
include, but not be limited to the following:
a) assist Owner’s personnel in familiarizing with vendor’s and contractor’s drawings and
specifications and in familiarizing with lines and equipment check lists.
b) prepare programs for recruiting and training the necessary Owner supervisory and
operating/ maintenance personnel to start up, operate and maintain MDPL. Actual
training itself shall be conducted by others. In preparing the overall training plans,
Consultant shall identify suitable resources to assist Owner in training its staff.
ARTICLE 15
HEALTH, SAFETY AND THE ENVIRONMENT
It is Owner’s objective policy to ensure that potential health and safety factors and
environmental effects are assessed for all products, projects and activities and
acquisitions. For projects, this is implemented by staged audits of health, safety and
environmental aspects from concept stage to post commissioning in order to determine
any shortcomings or noncompliance.
The specific requirements include:
Project Safety Review: A formal project safety review is to be carried out by Owner
and integrated across the various contracts. The Owner’s review team will require data,
input from key personnel from the other contractors and access to all locations being
used by contractor, subcontractors and suppliers. Consultant shall make all necessary
arrangements for such reviews as required by Owner and shall ensure that contractors
make available such data, personnel and locations as are required. Consultant shall
ensure that all recommendations and findings from safety reviews are implemented by
contractors in a timely manner.
Environmental Impact Assessment (“EIA”) : Consultant shall ensure that all
recommendations resulting from the EIA/RA studies, on approval by Owner, are
implemented by contractors.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
HAZOP Reviews: Consultant shall provide a team, subject to Owner’s approval, for
carrying out HAZOP study and shall ensure that all recommendations and findings are
implemented by contractors in a timely manner.
Health, Site Safety and Security: Consultant shall be responsible, on behalf of Owner
for ensuring a high standard of occupational health and site safety management and for
ensuring the requirements for health, safety and security to be maintained by
contractors, subcontractors and other personnel working at the site. Consultant shall
compile the safety requirement on contractors.
The purpose of these safety requirements shall be to prevent any accidents, incidents or
events that could result in injury or fatality to personnel from contractor’s,
subcontractor’s, Consultant, Owner or third parties and/or damage or destruction to
contractor’s or Owner’s property, equipment and materials. The requirements shall be
intended to supplement any government authority of India, state, municipal, local or
other regulations applicable at the Site which Consultant shall be obliged to enforce on
behalf of Owner. Consultant shall agree with Owner representative at site any
variations between these requirements.
Consultant shall monitor, control and report fortnightly to the owner and ensure that
the above requirements are fully adhered to.
1. Site Safety Organization:
Consultant is to appoint a safety officer with appropriate staff support whose
responsibility is to monitor all safety activities on the job site and report his
findings to Consultant. The safety officer shall make periodic safety inspections of the
job site on a schedule that will provide ongoing coverage. The inspections should be
made jointly with the superintendents of the contractors responsible for ongoing work
in the areas to be inspected. Any infractions or poor safety practices uncovered by these
inspections shall be promptly corrected. Safety requirements shall be enforced on the
entire supervisory organization of the contractor and subcontractors. Each location shall
require enforcement of approved safety rules and procedures by contractors and
subcontractors.
2. Site Safety Planning :
Prior to award of construction subcontracts or start of Site work, Consultant shall plan
job safety requirements in conjunction with contractors giving due consideration to :
(a) Owner’s/Consulant’s safety requirements;
(b) Location of job site(s);
(c) Type, background and quality of labor resources, and anticipated training
program;
(d) Nature of the construction work, types of hazards anticipated and hazard
prevention methods;
(e) Inspection, testing and commissioning activities overlapping with construction,
including training and implementation of permit to work systems;
(f) Construction equipment and materials to be used;
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
(g) Minimizing the number of subcontractors or crafts working in any one area at
the same time;
(h) Personal protective clothing and equipment requirements must be established,
and orders placed for timely delivery to job site of such equipment. Consultant
will ensure that contractors execute obligations in this area.
3. Site Safety Manual:
Prior to start of work at each job site, Consultant shall publish and distribute a safety
manual approved by Owner to cover safety activities. The manual shall be published in
both English and Hindi, and in other languages if workers do not know these
languages.
The design of the manual shall permit easy communication of its contents to all
personnel, recognizing language and literacy conditions at the job site.
All Owner’s, Consultant’s and contractors supervisory personnel are to be issued a
copy of the manual. Further distribution of the manual, or specific sections, shall be
determined dependent upon the needs of the adopted construction strategy and
organization.
The contents of the manual shall include, as a minimum the following:
(a) Owner’s & Consultant’s safety organization, philosophy and responsibilities;
(b) Owner’s & Consultant’s safety requirements;
(c) The general safety rules applicable to the job site;
(d) Near miss accident report;
(e) Once a month safety audit;
(f) The requirements, availability and provision of personal protective clothing and
equipment for specific activities that will occur at job site;
(g) Traffic regulations at the work Sites;
(h) Requirements and standards for use of scaffolding/ladders;
(i) Requirements for grounding electrical construction equipment and tools;
(j) Type, availability and responsibility for use of fire fighting equipment;
(k) Work permit procedures;
(l) Procedures to be followed when an accident, injury or fire occurs;
(m) Simple procedures to be followed by entire contractor’s organization should a
major accident occur;
(n) Control of access to site;
(o) Consultant will issue updated and revise booklets prior to commencing
commissioning activities as new hazards arise and new working procedures are
required.
4. Safety Activities:
Consultant shall ensure contractor, subcontractors carry out their activities in
accordance with the safety plan throughout the course of the construction of the project
to inculcate and maintain safety awareness among their employees.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
Each workmen/employee, prior to beginning work, shall be given a safety orientation
course. Consultant shall be responsible for arranging and providing such and ensuring
consistency of knowledge and understanding across all and work groups. All personnel
must be fully knowledgeable of the potential hazards involved in the work they
supervise and the safe practices to be followed in their work.
5. Accident Investigation and Reporting:
Any accident or incident resulting in a lost time injury, death, or damage to property or
equipment is to be investigated by Consultant. Every incident shall be documented
promptly after the incident including the results of investigation and recommendations
for preventive action. Consultant shall also ensure that all necessary publicity is given,
within the site, to ensure further incidents do not occur. This investigation and report
shall not preclude any similar investigations and reports required by governmental
regulation, but may be handled concurrently with them.
Consultant shall maintain safety performance and accident statistics records for the
whole site in conformance to an agreed international standard or system to be approved
by Owner. Updated safety performance and accident statistics shall be included in
Consultant’s every monthly report.
6. Health Program:
The Consultant is to appoint an occupational health manager with appropriate
staff whose responsibility will be to monitor all occupational health activities on the
work site and his findings to the Consultant. This role could be coupled with that of the
safety manager.
The occupational health manager will be responsible for:
- formation of health organization;
- preparation and submission to Owner of a health program;
- promotion of health education at the work site and analysis;
- investigation and reporting of hazards and incidents on the Site.
Additionally, the occupational health manager shall make periodic inspections of the
Site, with specific reference to :
- Sanitation;
- layout of temporary and permanent installations;
- provision of adequate medical personnel, facilities, equipment and supplies;
- implementation of measures for dealing with injuries /illness .
ARTICLE 16
DOCUMENTATION
Consultant shall ensure all documentation and engineering data are delivered in a
timely manner. The quality and technical integrity of this information shall be
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
monitored to ensure compliance with the Quality Assurance Program. The delivery
mechanism shall be the responsibility of Consultant i.e. The electronic media use,
indexes, sizes and number of copies of soft copy and hardcopy, etc.
Consultant shall also be responsible for modifying the documentation and data
requirements to reflect any existing and new statutory requirements from both
government and certifying authority sources.
Consultant to handovers the required number of soft/hard copies of following, but not
limited to, design basis, process package, tenders (MR &PR), drawing, layouts,
operating manual, single line diagram, P & IDs, hazop study etc. to HPCL.
Consultant shall be responsible for production of the operating manual(s). This will
include scheduling for the preparation of the materials making up the operating
manuals. It shall also include the review of drafts of the material in conjunction with
Owner. Regular progress meetings shall be held at the appropriate time to ensure
completion, commissioning and operation.
ARTICLE 17
ASSISTANCE IN ARBITRATION
Consultant shall ensure that the issues related to various contracts are settled amicably
with the contractors/suppliers. Consultant shall provide necessary assistance to the
owner and prepare suitable replies to address the claims / grievances / disputes of the
contractors / suppliers, as and when they arise.
Despite the above, if any contractor/supplier imposes Arbitration proceedings on
HPCL, the consultant shall be responsible for providing necessary assistance to HPCL
in connection with these proceedings from the date of award of EPMC contract upto a
period of 3 years beyond the date of completion of the project. The rates quoted by the
consultant shall be all inclusive and such cost of providing assistance for the arbitration
proceedings to be borne by the consultant.
Hindustan Petroleum Corporation Limited GGSR Products Evacuation Project
UNPRICED
VOLUME III
SCOPE OF WORK
F. EXCLUSIONS FROM SCOPE OF WORK
The following activities are specifically excluded from the Consultant’s Scope of Work:
a) Sanction / Release of Power and Water both for operational and construction purposes
including liaising with supply authorities.
b) Obtaining approvals, clearances and permits from statutory bodies including liaising
with these bodies.
c) Acquiring land for putting up Project facilities.
d) Obtaining Customs clearances for imported materials / equipments.
e) Arranging transportation from port to sites for imported materials / equipments.
f) Taking Insurance policies for Project materials / equipments, lodging claims and
liaising for realization of claims. However, assessment of loss is in consultant’s scope.
g) Participation in Arbitration proceedings.
h) The costs towards press advertisements of NIT/bid invitation which shall be borne by
Owner and paid directly at actuals to the agency on submission of the bills of the
agency by the Consultant to Owner.
k) Consultant shall process the Contractor’s bills till certification of the same. Owner shall
process and effecting payment to Contractors basis Consultants certification.
Top Related