Varation 3nd Draft Complied
-
Upload
bereket-amare -
Category
Documents
-
view
34 -
download
0
Transcript of Varation 3nd Draft Complied
Acknowledgements We, the group member of this assignment, strongly agree that realization of this term paper
will be impossible without the support of others. So it is with deep gratitude that we express
our appreciation to the following, for their contributions:
To Ato Zewdu Tefera, our adorable instructor and the provider of the assignment.
Once again we would like to pass our deep appreciation to Ato zewdu for giving us
this opportunity to work to together and to know more about the course matter.
To Addis Ababa University Civil Engineering Department, for providing the
necessary support letters for concerned offices that makes our work a lot easier.
To the staff of the Ethiopia Road Authority, Contract Administration Division, for
providing the data for this assignment. This work might have not been full without
their help.
Abstract Construction projects because of their special characteristics are susceptible and they are
subjected to the influence of many external and internal factors. A large number of project
participants because of their actions cause variations to the scope and design of the
projects. The need to make changes in a construction project is a matter of practical reality.
Even the most thoughtfully planned project may necessitate changes due to various factors.
In some cases natural causes also contribute to variation requests to construction projects.
Identification of causes of variation, effects of variation and control for variation are the
important concepts for managing variation in the construction projects. This assignment will
focus extensively on literature review to point out these causes and effects of variation in
the construction projects. The paper also specifies different measures that should be taken
to control the adverse impacts of variation on the construction industry. This literature
review also introduces the concepts of value engineering, contractual variation and
variation in works.
The regulation of variation under the MDB-FIDIC and PPA condition of contracts and the
applicable law of Ethiopia are another area that this term paper will focus in detail.
Reviewing each condition of contract and the applicable law the paper will explain clauses
or articles that are related to the concept of variation. In the meantime the similarity and
the difference of variation concepts in each condition of contract and the applicable law will
be presented.
Finally this term paper will presents a case study of three finalized road projects. The
projects are selected randomly from completion report. Based on the review of the
literature and the case studies, the paper concludes that lack of coordination among the
parties and changes in specifications by the employer are the important factors leading to
variations. The assignment also concludes that time overruns and cost escalations are the
major impact of variations in construction projects.
Key worlds: variation, construction projects, Condition of contracts, Value Engineering,
Causes, Effects, Types, Civil code, court
ABBREVIATIONS
PPA Public Procurement Agency
MDB-FIDIC Multilateral Development Bank- International Federation of
Consulting Engineer
ETB Ethiopian Birr
ERA Ethiopian Road Authority
ADB African Development Bank
FDRE Federal Democratic Republic of Ethiopia
ICB International Competitive Biddings
1. Introduction
1.1. Rationale and Purpose of the Assignment
The purpose of this assignment is to explore the concepts of variations and their
regulation under the MDB-FIDIC and PPA conditions of contract and the
applicable law of Ethiopia. Additionally the concept of variation under these laws
will be compared to show their similarity and difference in tabular form.
It is the known fact that construction projects involve different variations in their
due courses. These variations arise mainly due to the dynamic nature of the
projects and different factors that cannot be prevented from the construction
industry. Thus nature of the construction projects generates variations to the
scope and design of the projects.
Engineer has the power to make any variation orders of the form, quality or
quantity of the Works or part thereof subject to the approval of the Employer.
Such order would result in increase or decrease the quantity of any work
included in the contract. There are instances of omissions of work from the
scope. Furthermore the Engineer is empowered to change the character or
quality or kind of any such work. This may result in change the levels, lines
position and dimensions of any part of the works. At times it becomes
compulsory, on the part of the Engineer to order for additional work of any kind
necessary for the completion of the work. Further the faulty designs although the
Engineer fails to accept causes more concern, conflicts, cost and time over run.
There are cases of interferences by the Employer results in variations. This state
of affairs makes the Engineer and Contractor at tacit unease. Because of the
misunderstanding created on account of variation orders, disputes and claims
become a constant affair in the construction industry. In order to settle these
disputes and claims clauses that are related to variation are included in
construction contracts. Therefore this paper will focus on the variation concepts
that are included on construction contract (international or local) and other
applicable laws of Ethiopia. In this context, this paper attempts to find out
different causes of variations by all the project stakeholders such as Employers,
Engineers, Contractors and subcontractors, the impact of variation orders, the
problems encountered because of the variation orders and the possible
resolution to the problems and issues resulting from variation orders in the
construction contract.
Moreover this paper will focus on the comparison of variations concepts and
their regulation under the international construction contract (MDB-FIDIC), local
construction contract (PPA) and any applicable laws of the country.
1.2. Objectives
The main objectives of the paper can be summarized as follows:
1. To overview the concepts of variation in the construction industry.
2. To identify Potential Causes and Effects of Variations in the industry.
3. To identify the concepts of variations and their regulation under
different construction contracts.
4. To examine the variation concepts in the construction industry of
Ethiopia
5. To give conclusion and recommendation based on finding of the
paper
1.3. Methodology followed
To develop this paper the following procedure are conducted:
Literature review concerning the concepts of variation in the
construction projects is conducted;
Construction contracts such as MDB-FIDIC and ICB of PPA are genuinely
reviewed to find out clauses related to the subject matter, addition to
these construction contracts applicable laws of Ethiopia are viewed.
Analysis of case studies related to the subject matter are conducted to
support our discussion of the paper
1.4. Limitation of the assignment
As this assignment is meant for semester term paper, the work conducted to
develop it is not as such enough as a normal scientific research paper required.
Especially the selection of case studies are not based on the concepts of sampling
techniques and also the number construction projects that are selected for case
study are only three, that are not represent the true nature of construction
projects in the country
2. Variation in construction industry
2.1. Definition of variation
Variation in construction contracts can imply changes to the terms of the contract, changes
to the scope or character of the works. There is no single definition of what constitutes a
variation; usually most of construction contracts will contain a definition of variation by
including a “changes” clause. Such a "Changes" clause is beneficial to both the contractor
and employer as it increases the flexibility of construction contracts by providing for the
variations without the necessity for a new contract for incorporating any addition, deletion
or modification of a project requirement. Beside contractual meaning and definition of
variation there are different scholars that give the meaning and definition of variation in the
construction industry. Some of these definitions are given below
"Written authorization provided to a contractor approving a change from the original plans,
specifications, or other contract documents, as well as a change in the cost" (Means, 1991).
"It is (1) additional or modified scope of work; (2) errors and omissions in plans and
specifications; (3) changes required by governmental entities; (4) design changes; (5)
overruns or underruns in quantities; and (6) conditions impacting on schedule, the time of
completion or the method or manner of performance of the work," (Libor, n.d).
Other important issues to note on variations:-
The contractor may not make any variation without an order from the Engineer,
Such order must be in writing;
The contractor must carry out an oral order,
The contractor may confirm an oral order, and if he does so, the Engineer must
contradict it forthwith if he does not agree with it; and
Contractor should always as a matter of routine confirm any oral instruction given by
the Engineer or his staff ( Abebe Dinku, Prof.Dr.Ing)
An effective analysis of variation requires a compressive understanding of the root cause of
variation and their potential downstream effects. To manage a variation mean being able to
anticipate its effects and to control, or at least monitor the associated cost and schedule
impact. Hence identification of causes of variation, effects of variation and control for
variation are the important concepts for managing variation in the construction industry.
The detail description of these concepts are given in subsequent subtopics
2.2. Potential Causes of Variations
2.2.1. Employer related variation
The employer as the project initiator plays a major role in the construction project from
the inception to the completion phases. As a result, employers influence the likelihood
of the occurrence of variation. Employers anticipate the needs and objectives of
projects, establish the scope of works and the required quality standards. During the
construction stage, employers initiate variation due to various reasons. Some of these
are;
Change of plans or scope by Employer: Change of plan or scope of project is one of the
most significant causes of variation in construction projects and is usually the result of
insufficient planning at the project definition stage, or because of lack of involvement of
the employer in the design phase. This cause of variations affects the project severely
during the later phases.
Change of schedule by Employer: A change of schedule during the project construction
phase may result in major resource reallocation. Time has an equivalent money value. A
change in schedule means that the contractor will either provide additional resources, or
keep some resources idle. In both cases additional cost is incurred.
Employer’s financial problems: The employer of the facility may run into difficult
financial situations that force him to make changes in an attempt to reduce cost.
Employer’s financial problems affect project progress and quality.
Inadequate project objectives: Inadequate project objectives are important causes of
variation in construction projects. Due to inadequate project objectives, the engineer
would not be able to develop a comprehensive design which leads to numerous
variations during the project construction phase.
Replacement of materials or procedures: Replacement of materials or procedures may
cause major variations during the construction phase. The substitution of procedures
includes variations in application methods. Therefore, an adjustment to the original
contract value is required if there is a change in procedures.
Change in specifications by owner: Changes in specifications are frequent in
construction projects with inadequate project objectives. In a multi-player environment
like any construction project, change in specifications by the employer during the
construction phase may require major variations and adjustments in project planning
and procurement activities
Impediment in prompt decision making process: Prompt decision making is an important factor for
project success. A delay in decision making may hinder subsequent construction activities that may
eventually delay the project progress.
2.2.2. Engineer related variation
This section discusses the causes of variations that were initiated by the engineer. In
some cases, the consultant directly initiates variations or the variations are required
because the engineer fails to fulfill certain requirements for carrying out the project.
These are:
Change in design by Engineer: Change in design for improvement by the engineer is a
norm in contemporary professional practice. The changes in design are frequent in
projects where construction starts before the design is finalized. Design changes can
affect a project adversely depending on the timing of the occurrence of the changes.
Errors and omissions in design: Errors and omissions in design are an important cause of
project delays. Design errors and omissions may lead to loss of productivity and delay in
project schedule. Hence, errors and omissions in design can affect a project adversely
depending on the timing of the occurrence of the errors.
Conflicts between contract documents: Conflict between contract documents can result
in misinterpretation of the actual requirement of a project. To convey complete project
scope for participants, the contract documents must be clear and concise. Insufficient
details in contract documents may adversely affect the project, leading to delay in
project completion.
Inadequate scope of work for contractor: In a multi-player environment like
construction, the scope of work for all the players must be clear and unambiguous for
successful project completion. Inadequate scope of work for the contractor can cause
major variations that may adversely affect the project, leading to changes in
construction planning.
Technology change: Technology change is a potential cause of variations in a project.
Project planning should be flexible for accommodating new beneficial variations. This is
because the new technology can be beneficial in the project life cycle, for instance,
reducing maintenance cost of the project.
Value engineering: Value engineering should ideally be carried out during the design
phase. During the construction phase, value engineering can be a costly exercise, as
variation in any design element would initiate downstream variations to other relevant
design components.
Design complexity: Complex designs require unique skills and construction methods.
Complexity affects the flow of construction activities, whereas simple and linear
construction works are relatively easy to handle. Hence, complexity may cause major
variations in construction projects.
Inadequate working drawing details: To convey a complete concept of the project
design, the working drawings must be clear and concise. Insufficient working drawing
details can result in misinterpretation of the actual requirement of a project. Thorough
reviewing of design details would assist in minimizing variations.
Ambiguous design details: A clearer design tends to be comprehended more readily.
Ambiguity in design is a potential cause of variations in a project. This is because
ambiguity in design can be misinterpreted by project participants, leading to rework and
delay in the project completion. Eventually, this may affect the project adversely.
Noncompliance of design with government regulations: Noncompliance of design with
government regulations would render the project difficult to execute. Noncompliance
with government regulations may affect the project safety and progress adversely,
leading to serious accidents and delays in the project completion.
2.2.3. Contractor Related Variations
In some cases, the contractor may suggest variations to the project, or the variations may be
required because the contractor fails to fulfill certain requirements for carrying out the
project. These variations may be categorized into different forms, some of these are:
Lack of contractor’s involvement in design: Involvement of the contractor in the design
may assist in developing better designs by accommodating his creative and practical ideas.
Lack of contractor’s involvement in design may eventually cause variations. Practical ideas
which are not accommodated during the design phase will eventually affect the project
adversely.
Unavailability of equipment: Occasionally, the lack of equipment may cause major design
variations or adjustments to project scheduling to accommodate the replacement.
Unavailability of skills (shortage of skilled manpower): This lack can be a cause for
variations that may delay the project completion.
Contractor’s financial difficulties: Contractor’s financial difficulties may cause major
variations during a project, affecting its quality and progress.
Contractor’s desired profitability: The contractor may eventually strive to convince the
project owner to allow certain variations, leading to additional financial benefits for him.
Differing site conditions: Differing site condition can be an important cause of delays in
large building projects. The contractor may face different soil conditions than those
indicated in the tender documents. Eventually this may affect his cost estimates and
schedule adversely.
Lack of communication: Detrimental variations, which affect the projects adversely, can
usually be managed at an early stage with strong and incessant communication. A lack of
coordination and communication between parties may cause major variations that could
eventually impact the project adversely.
Lack of strategic planning: Proper strategic planning is an important factor for successful
completion of a building project. The lack of strategic planning is a common cause of
variations in projects where construction starts before the design is finalized, for instance, in
concurrent design and construction contracts.
Contractor’s lack of required data: A lack of required data may affect the contractor’s
strategic planning for successful project completion, leading to frequent disruptions during
the construction process. This is because a lack of data can result in misinterpretation of the
actual requirements of a project.
2.2.4. Other causes Variations
This section discusses the causes of variations that were not directly related to the participants.Weather conditions: Adverse weather conditions can affect outside activities in
construction projects. When weather conditions vary, the contractor needs to adjust the
construction schedule accordingly. Occasionally, this may affect the project progress
adversely, leading to delays in construction.
Safety considerations: Safety is an important factor for the successful completion of a
building project. Noncompliance with safety requirements may cause major variations in
design. Lack of safety considerations may affect the project progress adversely, leading
to serious accidents and delays in the project completion.
Change in government regulations: Local authorities may have specific codes and
regulations that need to be accommodated in the design. Change in government
regulations during the project construction phase may cause major variations in design
and construction. This can affect a project adversely depending on the timing of the
occurrence of the changes.
Change in economic conditions: Economic conditions are one of the influential factors
that may affect a construction project. The economic situation of a country can affect
the whole construction industry and its participants. Eventually, this may affect the
project adversely, depending on the timing of the occurrence of the variations.
Socio-cultural factors: Professionals with different socio-cultural backgrounds may
encounter problems due to different perceptions, and this may affect the working
environment of the construction project. Lack of coordination is common between
professionals with different socio-cultural backgrounds. Eventually, project delays may
occur that end up with vital changes in the entire project team.
Unforeseen problems: Unforeseen conditions are usually faced by professionals in the
construction industry. If these conditions are not solved spontaneously, they may cause
major variations in the construction projects. Eventually, this may affect the project
adversely, leading to reworks and delays in the project completion.
Table 2.1 below summarizes the different causes of variations and their origins
No
Causes of variation orders
Empl
oyer
Engi
neer
cont
ract
or
othe
rs
1 Change of plans or scope x
2 Change schedule x
3 Financial problems x x
4 Inadequate project objectives x
5 Replacement of materials or procedures x
6 Obstinate nature of the parties x x x
7 Change in specification x x
8 Change in design by the Engineer x
9 Errors and omission by design x
10 Conflict b/n contract document x
11 Inadequate scope of work for the contractor x
12 Technology change x
13 Value engineering x
14 Lack of coordination x
15 Design complexity x x
16 Inadequate working drawings details x
17 Inadequate shop drawings details x
18 Consultant’s lack of judgment and experience x x
19 Lack of consultant’s knowledge about available
materials and equipments
x
20 Honest wrong beliefs of consultant x
21 Consultant’s lack of required data x
22 Ambiguous design detail x
23 Design discrepancies x
24 Non- compliant design with government regulations x
25 Non- compliant design with owner’s requirement x
26 Lack of contractors’ involvement in design x
27 Unavailability of equipment x
28 Unavailability of skills x
29 Contractor’s desired profitability x
30 Differing site conditions x
31 Defective workmanship x
32 Unfamiliarity with local conditions x
33 Lack of specialized construction manager x
34 Fast track construction x
35 Poor procurement process x
36 Lack of communication x
37 Long lead procurement x
38 Honest wrong beliefs of contractor x
39 Lack of strategic planning x
40 Contractor’s lack of required data x
41 Weather conditions x
42 Health and safety considerations x
43 Change in government regulations x
44 Change in economic conditions x
45 Socio-cultural factors x
46 Unforeseen problems x
Source: Adapted from Arain and Pheng (2006)
2.3 Potential Effects of Variations
The most common effects of variation in any construction industries are identified as follow.
Delay in progress of work
Cost overrun
Need of additional professionals
Increase in overhead expenses
Delay in progress payment
Low quality of work
Low productivity
Completion schedule delay
Delay in Procurement
Rework and demolition
Logistic delay
Tarnish firm’s reputation
Poor communication between professional
Additional payment for contractor
Dispute among professionals
Now let as see each effects of vibration in depth how they affect the project.
Delay in Progress of works
Change orders by Employer during construction significantly affect the construction
progress. These changes may be changes in scope are typically requested by the employer to
modify the facility to better use or any other reasons. Sometimes the change may be at the
early stage the construction, these types of changes do not affect the construction process and
they are not as such costly. But a change made during the actual construction period highly
affects the progress of work and are expensive to the contractor.
Unforeseen conditions also initiate change order during construction period. Examples of
these unforeseen conditions would be unexpected soil conditions, the discovery of buried
material like archeological centers, treasures, precious stones, and weather conditions and
weather damage.
Errors and omissions are situations where the original plans and specifications have been
incorrectly drawn or represented. The result of this situation can be extremely costly, if not
caught soon. The contractor should be looking at the plans from the start to ensure that design
errors and omissions are minimized.
The frequency and magnitude of the change orders can be greatly reduced if a great attention
is given in areas of pre-planning, risk management and change order management.
Cost overrun
The most common effect of variations during the construction is cost overrun, change in
scope by the employer or some alteration of the design contribute a lot for cost overrun of the
project. This is because of high inflation/increased material price; additional cost incurred
during the interruption of work and so forth. Therefore, in any construction it is necessary to
allocate a contingency sum of money to overcome cost overrun because of variation.
Need of additional professionals
If there is a variation or change order in the construction process, the contractor require to
work over time or need to have additional human power to compensate the delay in the
construction process cased by the variation order or if there is a variation in a complex
projects there is a need to have additional professionals or additional human power.
Otherwise variation in a complex project affects the project significantly because there is a
time overrun in search of ne professionals.
Increase in overhead expenses
Variations require processing procedures, paper work and reviews before they can even be
implemented (O’Brien, 1998). The process and implementation of variations in construction
projects would increase the overhead expenses for all the participants concerned. Normally
these overhead charges are provided for from the contingency fund allocated for the
construction project.
Delay in payment
The Contractor will be compensated for damages incurred due to variation order for which
the employer is responsible. Actual costs will be determined by the Engineer. Actually the
employer will not be liable for damages which the Contractor could have avoided by
reasonable means, such as judicious handling of forces, equipment, or plant. The
determination of what damages the Contractor could have avoided will be made by the
Engineer.
Unless contractor has been aware of the following equation, delay in payment is a common
effect of variation order.
i. What is a Progress Payment Request?
A progress payment request is the process of asking your lender to pay your builder for part
of the work that has been completed.
The contractor and the client may have already agreed to how many payments will be made,
the gap between those payments, their amount and when they are due. The lender simply
makes sure that these payments are made when stipulated.
ii. Prior to Commencement
Before the contractors begin construction, there is a need to be provided the following
documents:
Signed building contract.
Council approved plans.
Construction certificate or Building permit or Decision notice
Builders Insurance (certificate of currency).
Builders Indemnity
You can either send these to the owner, prior to the first progress payment request or with the
first progress payment request.
With regard to the progress payment, the main cause is that the contractor will not submit or
send the progress payment requisite ahead of the commencement of the work, and this will
not give sufficient time to the owner to do so or to facilitate the payment.
iii. The First Progress Payment Request
There are often delays with the first progress payment request because in many cases, the
above documents have not been provided or have been lost by the lender.
These documents may have been supplied during loan approval; however the construction
department may not have a copy of the file from the credit department that approved your
loan.
iv. How to Request a Progress Payment
Simply fax the bank the following documents:
A signed progress payment request form (available from your lender) or a signed
letter from you authorizing payment.
A copy of the invoice from the builder.
(First progress payment only) A copy of the receipt from the builder showing that you
have paid them the funds you are required to contribute.
(Final progress payment only) Call the lender to discuss their additional requirements
prior to sending them the request.
v. Your Final Progress Payment Request
For your final progress payment request, the lender will usually send a valuer to the property
to confirm that work has been completed as per the contract & plans provided.
If there is any unfinished work then the lender will withhold payment until the work is
completed.
You may need to provide additional documents such as:
A certificate of occupancy from the council,
A copy of your building insurance with enough cover to replace the building. This
copy must also include the name of the lender, on the policy, and
Other documents as per normal, such as a progress payment request, as well as an
invoice from your builder.
Discuss these requirements with your lender prior to requesting the progress payment. You
can avoid variation order by providing all of the documents up front.
Low quality of works
If there is repeated variation order is there during the construction process, it has an adverse
effect on the quality of the work. This is because of the fact that if variation is frequent,
contractors tended to compensate for the losses by cutting corners.
Low productivity
Interruption, delays and redirection of work that are associated with variation orders have a
negative impact on labor productivity. Construction labor productivity is typically measured
as labor hours per amount of work done. Labor productivity rates and other related data are
often not tracked on construction projects with any degree of precision. As a result, it
substantiates a cause of construction delay. Labor productivity losses and establishing
entitlement to recovery for lost labor productivity often requires analysis by a qualified
construction labor productivity expert.
Labor productivity loss is some time experienced when a contractor is not accomplishing the
planned production rates because of variation order. In other words, a loss of productivity due
to variation order takes more labor and equipment to do the same amount of work for
prolonged periods to compensate for schedule delays, thereby increasing project costs. There
are many common causes for labor productivity impacts on a construction project, stemming
from owners, contractors, and construction managers.
Procurement delay
Variations which are imposed when construction is underway may require revised
procurement requests (O’Brien, 1998). Procurement delays can be frequent due to variations
that require new materials and specialized equipment. Hester et al. (1991) observed that
procurement delays were common effects of variations related to new resources for
construction projects.
Rework and demolition
As it is known error may be commuted during the construction process by the contractors or
sub contractors as a result demolition and rework are the common phenomena in construction
projects. Rework and demolition are potential effects of variations in construction, depending
on the timing of the occurrence of the variations. When the error commuted is because of the
fault of the contractor or sub contractor they are forced to re do it once again without any
compensation. This type of variation order is a potential effect for a construction delay.
Logistics delays
Because of the employer interest or unavailability of the specified materials in the market, it
forces the contractor to change the material in the contract document and to have a new
material. But material change requires variation order and certification by the Engineer.
Therefore, delays caused by material or equipment are significant effects of variation in the
construction project and the process take time for the contractor to execute the work as
scheduled.
Tarnish firm’s reputation
Variations are referred to as a major source of construction claims and disputes (Fisk, 1997;
Kumaraswamy et al., 1998). The claims and disputes may affect the firm’s reputation
adversely, leading to insolvency in severe cases. Variations also increase the possibility of
professional disputes. Conventionally, variations present problems to all the parties involved
in the construction process.
Poor safety conditions
During the construction process there is a variation in construction method, materials and
equipments, and these variations contribute a lot for poor safety conditions.
Poor communication between professionals
Variation or change order is the major cause of disputes, and the disputes are in turn affects
proper communication between professionals.
At the same time poor communication and coordination by the parties or Lack of
communication in construction business may leads to misunderstandings, conflicts and
disputes. If the owner of the project is poor in communication with parties it is a great cause
for construction delay. Hence it necessitates the owners to have effective communication
skills which are one of the significant skills with the project parties involving in construction
projects.
Additional payments for contractor
Additional payments for the contractor can be a potential effect of variations in construction
projects. Variations are considered to be a common source of additional works for the
contractor (O’Brien, 1998). Due to additional payments, the contractor looks forward to
variations in the construction project.
Disputes among professionals
Disputes among professionals are effects of frequent variations in construction projects and it
is the major causes of delays in construction projects. Frequent variation order may also leads
to misunderstandings, conflicts and disputes among professionals. Variation order by the
employer and discrepancies in contract documents will give rise to disputes between the
various parties. Furthermore, if the disputes cannot be solved smoothly or easily it can lead to
arbitration or litigation. But frequent communication and strong coordination can assist in
eliminating the disputes between professionals.
2.4 Types of variation
Variation can be broadly classified in to two:
Textual or Contractual variation and
Variation of works
Even though variation is classified as contractual or variation of works, problems concerning
variations arise in the following three areas:
1. Scope (was it a variation or was the contractor bound to do it anyway?);
2. Non-compliance with procedural requirements; and
3. Valuing the variations.
2.4.1 Contract variation
Let as first start from the definition of a contract.
As per Article 1675 of civil code “Contract is an agreement whereby two or more persons as
between themselves create, vary or extinguish obligation of a proprietary nature.”
Once again a contract of employment is a contract of service and comes into picture, when
the contractor agrees to work for and employer in return for pay.
Therefore, the employer and the contractor have to bind themselves according to the
definition or conditions of contract with some terms or contract clauses.
These terms of a contract are:
The rights and obligations which bind the parties to the contract.
Express terms of a contract (those which are explicitly agreed between the
parties, either in writing or orally) or implied terms of a contract (those which
have not been spelled out but which would be taken by the parties to form part
of the contract).
Terms are implied, for instance, because they are:
Too obvious to mention or because the parties assumed they would be incorporated at the
time the contract was entered into.
Necessary to make the contract workable. For example, that an employee employed as a
driver will hold a valid current driving license)
The custom and practice of the business or industry, i.e.: where a custom or practice has been
adopted over a period of time.
Express terms may be established by referring to various sources, particularly the written
statement of terms and conditions, the letter of appointment and written or oral statements
made by the employer and accepted by the contractor. Express terms may also be
incorporated into individual contracts by reference to other documents.
Statutory terms are those implied or imposed by an act of Parliament or Statutory
Instrument, Example: the imposition of an equality clause into an employee’s contract and
the entitlement to be paid the national minimum wage or given a minimum period of notice.
Why would employers or contractors want to vary a contract?
If a change in economic circumstances or due to a reorganization of the
business. Possible areas of change could include pay rates, hours or days
worked duties, supervisory relationships or place of work. This is mostly done
by the employer.
To bring about improvements in pay or working conditions, for instance by
requesting additional holidays, or to change the conditions so that they suit
him or her better, for example, by requesting a change from full-time to part-
time working because of domestic responsibilities.
How can contracts be varied?
An existing contract of employment can be varied only with the agreement of
both parties. Changes may be agreed on an individual basis or through a
collective agreement (i.e.: agreement between employer and contractor or their
representatives).
An employer who is proposing to change an employee’s contract of
employment should fully consult with that employee or his or her
representative(s) and explain and discuss any reasons for change.
Variations of contract can be agreed verbally or in writing. It is preferable for
any agreed changes to be recorded in writing.
Where a variation in the contract has been agreed and the changes concern
particulars which must be included in the written statement of terms and
conditions, the employer should give written notification of the change to the
employee, within a month of the change taking effect.
Notice: any change made by either the employer or contractor without out the considerations
as to how a contract is varied as discussed above and without the consent of the other party,
by deferring the terms of a contract, it is a breach of a contractual agreement between the
parties.
On the other hand a contract terms may be changed by the common agreement of the parties.
For what so ever the cases the change med by varying the contract terms or clauses is referred
to as a contractual variation.
2.4.2 Variation in works
Shortage of material in a market or unavailability of the specified construction materials at
the time of construction may initiate a change of work or variation in works. That means the
contractor is forced to replace the material which is specified on the contract document a new
material.
Design change by the consultant or by the employer may also lead to a variation in works
done by the contractor.
Whether the variation of work is within the scope of the contract will depend, firstly, on the
terms of the contract. In many cases, the documents forming the contract for variation order
are defined. Therefore, the contractual relationship between the parties is constituted by:
(a) The Formal Agreement to which these Conditions of Contract are attached;
(b) These Conditions of Contract;
(c) The Contract Particulars;
(d) The Works Description; and
(e) The other documents (if any) referred to in the Contract Particulars.
Even without such explicit provisions, it is probably true to say that the court will not confine
itself to the written agreement alone in determining the variation of work within the scope of
the contract: specifications, drawings, correspondence, etc, all form part and parcel of the
contract.
Notice: Any type of works done by the contractor with the enforcement of the employer or
the consultant or with the common consent of all the parties, but which are different type of
work form the one stated on the contractual document as a work description of the project
and the one which do not compliant with the specification and the corresponding drawings is
referred to as variation due to works.
2.5 Controls for Variation Orders
2.5.1 Design Stage Controls for Variation Orders
Review of contract documents: Since Contract documents are the main source of
information for any project reviewing of variation clauses in the contractual document is the
first to thing to do to control variation order properly. Failing to do so may cause conflicts
between contract documents which is a series problem in the project execution.
Detail design revision: Changing the design of the project highly affects the progress of the
work and it is a cause for cost overrun depending on the time of the change. That means
design variation at the initial stage it is not as such costly but design change made in the mean
time of the construction work significantly affect the project. Therefore, freezing the design is
a strong control method to avoid the problems related to variation in design.
Value engineering at conceptual phase: During the design phase, value engineering can be
a cost saving exercise, as at this stage, variation in any design element would not require
rework or demolition at the construction site. Therefore, Value engineering at the conceptual
stage is good mean of controlling variation order in the construction projects, especially after
the project is on the process.
Involvement of professionals at initial stages of project: Involvement of experienced
professionals during the design phase may assist in developing better designs. This is because
of the fact that experienced professionals contribute their creative idea form their past
experience.
Practical ideas that are not accommodated during the design phase may affect the project
adversely. Variation during the construction phase is a costly activity as it may initiate
numerous changes to construction activities.
Employer’s involvement at planning and design phase: In the planning and design phase
the employer of the project has to be consulted properly in order to avoid any design change
in the mean time of the construction process. This is done to clearly know the project
objectives by the employer from the beginning. Hence, this may help in eliminating
variations during the construction stage where the impact of the variations can be severe.
Involvement of contractor at planning and scheduling process: In the planning and
scheduling process if the contractor is involved it is better to develop better plan and
schedule. This is done to substantiate the plan and schedule prepared by the consultant.
Clearly know the project objectives by the owner from the beginning. Eventually, this may
eliminate the major variations in the later stages of the construction project where the impact
of the variations can be severe.
Thorough detailing of design: A detail design including detail drawings is more easer to
control variation order. This would also assist in identifying the errors and omissions in
design at an early stage. Eventually, thorough detailing of design can eliminate variations
arising from ambiguities and errors in design.
Clear and thorough project brief: A clear and thorough project brief is an important control
for variations in construction projects (O’Brien, 1998) as it helps in clarifying the project
objectives to all the participants. Eventually, this may reduce the design errors and non
compliance with the owner’s requirements.
Reducing contingency sum: The provision of a large contingency sum may affect the
participants’ working approaches. This is because the designer may not develop a
comprehensive design and would consequently carry out the rectifications in design as
variation orders during the later stages of the construction project. Therefore, reducing the
contingency sum would be helpful in ensuring that the professionals carry out their jobs with
diligence.
2.5.2 Construction Stage Controls for Variation Orders
Clarity of variation order procedures: knowing the procedure of variation order at the
construction phase is an important control mechanism of variation order. At the Early stage
of the project life, the procedures should be identified and made clear to all parties.
Written approvals: verbal variation order may lead the contractor at risk because there is no
way to have a legal proof to get compensation of cost for the varied work. So a good way of
controlling this type of problem is for every variation in the original price must be approved
in writing by the owner before the actual variation order is made.
Variation order scope: From the very beginning, the scope of the work has to be defined
clearly. This will help to identify variation of scope form vibration due to design
development and help to minimize the adverse effect of variation on the construction due to
change in scope of the work made after the commencement of the construction. Thus, the
effective definition of the scope of work is of paramount importance to identify and manage
variations.
Variation logic and justification: Good knowledge of a logical approach to settle vibration
order and giving appropriate justification for a given vibration helps professionals in
promoting beneficial variation and eliminating detrimental variations.
Project manager from an independent firm to manage the project: If the project manager
is from independent firm, process of decision making is not yet affected by external factors
and design discrepancies are reduced by early reviewing of the contract documents and
drawings. Thus, this helps to eliminate variations that arise due to lack of coordination among
professionals.
Restricted pre-qualification system for awarding projects: during the biding process to
select the capable/qualified contractors using a competitive selection method and a restricted
pre-qualification system for awarding projects is very crucial to control a variation order in
construction. Failing to do so may allow incapable parties to bid. This may eventually lead to
numerous problems in the later stages of a construction project.
Employer’s involvement during construction phase: Involvement of the employer during
the
Construction phase keep him aware of the ongoing activities. This also keeps the employer in
position to make prompt decision and promptly approve the variation order.
Avoid use of open tendering: Competitive open tendering usually encourages the main
contractor to price very low to win the contract, especially in bad times when they are in need
of jobs. This practice would give rise to the contractor trying to claim more to compensate for
the low price (Chan and Yeong, 1995). Avoiding the use of open tender would assist in
eliminating the risks of unfair bids. This may eventually help in eliminating variations that
may arise due to the contractor’s bidding strategy.
Use of project scheduling/management techniques: knowing the very possible effect of
variation and applying a good controlling mechanism of variation in a construction industry
is a good management skill. At the same time using the most known scheduling techniques in
construction management just like CPM, PERT and so forth will alleviate the associated cost
and schedule impact due to variation order.
Comprehensive documentation of variation order: To have the right and to keep the
options to pursue a subsequent claim or to defend against the claim, a comprehensive
documentation of variation order is very important. This will assists in tracking the effects of
the variation and claim events on time and cost. A documented source of knowledge about
previous variation orders would be helpful in making decisions concerning the appropriate
handling of variation orders.
2.5.3 Design-Construction Interface Stage Controls for Variation Orders
Prompt approval procedures: The most series problem in process of variation order is the
time elapsed between the time when the first variation order is announced and the time when
the matter is finally rejected or approved. If the decision is not implemented soon there is a
high cost overrun. To control this adverse effect of variations in the construction project a
prompt approval procedure is required.
Ability to negotiate variation: Ability to negotiate variation is the most cheaper and
effective control mechanisms of handling a variation order. Effective negotiation can
minimize the negative impacts of the variation. There are certain skills required for effective
negotiation of variation orders, i.e., the knowledge of contract terms, project details,
technology, labor rates, equipment, methods and communication skills.
Valuation of indirect effects: Consequential effects can occur later in the downstream
phases of a project. Therefore, it is essential to acknowledge this possibility and establish the
mechanism to evaluate its consequences. Indirect effects of variations can be substantial in
the downstream phases of a complex project (Fisk, 1997).Professionals should thus evaluate
the total overall effects a change may have on the downstream phases of a project, to manage
the variation order effectively.
Team effort by employer, engineer and contractor to control variation orders:
The team effort of the most comm. construction parties is very important in controlling
variation order which after the project adversely. If there is well coordination among the
parties the adverse effect due to variation order is easily managed at the early stage.
Utilize work breakdown structure: Adverse effects of variation order in construction
especially in a complex project can be easily controlled using a work breakdown structure
(WBS) and it is a power full controlling mechanisms to solve the problem related to variation
of works/activities. If a variation involves work not previously included in the WBS, it can be
logically added to the WBS and its relationship with the other WBS element can be easily
checked.
Continuous coordination and direct communication: Poor communication and
coordination by the contractor with the other parties or Lack of communication in
construction business may initiate variation because of misunderstandings, conflicts or
disputes. If the project manager develop a poor communication skill, he /she cannot manage
variation even at the early stages of construction but it can be done with due diligence in
coordination and frequent communication.
Comprehensive site investigation: site investigation during the briefing stage of
construction is very important to develop proper plan for construction activities. Therefore, a
comprehensive site investigation would help in reducing potential variations in a project.
Use of collected and organized project data compiled by employer, engineer and
contractor: Good documentation of a variation orders by the employer, consultant and
contractor a means to control a variation order because they can be used as a reference.
Knowledge-base of previous similar projects: If professionals have a knowledge-base
established on past similar projects, it would assist the professional team to plan effectively
before starting a project, both during the design phase as well as during the construction
phase, minimize and control variations and their effects.
Comprehensive analysis and prompt decision making through computerized
knowledge-based decision support system: The knowledge-based system would be helpful
in presenting a comprehensive scenario of the causes of variations, their relevant effects and
potential controls that would assist in decision making at the early stage of the variations
occurring.
2.5.3 Valuation of variations and Value engineering
Valuation of variation
All extra or additional work done or work omitted by order of the engineer shall be valued at
the rates and prices set out in the contract if, in the opinion of the Engineer, the same shall be
applicable. If the contract does not contain any rates or prices applicable to the extra or
additional work then suitable rates or prices shall be agreed upon between the engineer and
the contractor. In the event of disagreement the Engineer shall fix such rates or prices as
shall, in his opinion. Be reasonable and proper. Therefore, fix such rates or prices by the
engineer or by the client approval for price fixation for a varied work is a valuation of
variation.
Value engineering
Value Engineering is a systematic effort for analyzing the functional balance between cost,
reliability and performance of a product, project, process or service. It is conducted by the
team of multidisciplinary professionals.
The value engineering team is independent of the design team, but its members must have
experience in the particular field of the project in question. Working as an extension of the
design team, the VE team analyses the project from a function/cost standpoint, providing
alternative design suggestions that may improve performance, construction and life-cycle
costs. They may also improve construction methods or schedules, and may introduce
flexibility into operating or maintaining the project.
Benefits of value engineering
The main benefit obtained from effective value engineering is saving of the capital cost of the
project and achieving a good return from the investment.
Approach of value engineering
A value engineering study combines a technical capability with a systematic and intensive
approach to achieve creativity in identifying the lowest life cycle cost for the function
required by the owner. The focus on total life of the project is critical, making due allowance
for the impacts of the time cost of money on the one hand, and the escalating costs of labor,
fuels, power and materials on the other. As mentioned, the original design process is
(unavoidably) complex, involving many issues to be considered and reconsidered during
planning, design, value engineering and construction. The composition of the value
engineering team is therefore crucial to its success. Leadership of the team by an experienced
Certified Value Specialist is essential, and professionals with appropriate backgrounds and
experience are necessary to cover the various facets of the project.
Value engineering it conducted in three phases:
1. Pre study preparation phase
2. The project study work shop phase
3. The post work shop phase
The Pre-study Preparation phase
In this phase the owner, the designer and the value engineering team meet together to create
a common level of understanding on the project objectives, schedule of activities and so
forth. At this time there is also a review of data provided by the owner and the designer is
done by the value engineering team. During pre study phase models of appropriate capital
costs, energy costs and life cycle costs are prepared by the team leader.
The project study work shop phase
At this phase there is:
Briefing on Value Engineering
Presentation of project design by project designer
Outline of project constraints
Questions by value engineering team members for the designer
After this it is desirable for the owner and designer to invite the value engineering team on a
brief site visit. The team then proceeds with the following basic job plan, common to all
value engineering studies:
Information Phase: Further familiarization of the project by the team.
Creative Phase: The team lists creative ideas generated from its review of the project with
the aim of obtaining a large number of ideas through brainstorming and association of
creative proposals.
Judgment Phase: Creative ideas are analyzed, and the team selects the best ideas for further
development.
Development Phase: The team prepares alternative designs with capital and/or life cycle cost
comparisons of original designs and proposed alternatives. All recommendations are
supplemented with written descriptions, sketches, basic design concepts, technical
information and cost summaries.
Presentation Phase: The team presents an oral summary of its findings to the owner and the
designer, explaining the basic ideas recommended their cost-saving implications and their
attendant rationales.
The post work shop phase
On the last phase the team prepares a report for the owner, completed and submitted in a
timely manner, such that the design process may continue. The owner and designer consider
the value engineering recommendations, and jointly decide which items have merit for
implementation in a revised design.
In order to achieve a best result from the value engineering on has to consider the following
important points.
Top level commitment and support from the owner
A qualified VE team leader and experienced members
A well managed value engineering program
An appropriate project approach based on function analysis and proven methodology
Cooperation between the owner, the value engineering team and the designer, along
with empathy for the designer’s position
3. VARIATIONS AND THEIR REGULATION UNDER THE MDB-FIDIC
AND PPA CONDITIONS OF CONTRACT AND THE APPLICABLE LAW
3.1 Variations under FIDIC
The MDB-FIDIC specifies variations of contract from clause 13.1 to 13.8. According to
MDB-FIDIC variations may be initiated either by engineer or by request proposal of the
contractor at any time. The contractor is bounded by the decision of the engineer. The
engineer shall cancel, confirm or vary the instructions.
3.1.1 Right to Vary
Under MDB FIDIC clause 13.1, the engineer has the right to initiate variations by requesting
or instructing the contractor to submit a proposal for variation, also has the right to decide on
the request for variation proposed and submitted by the contractor.
The contractor shall execute any of the variations unless he/she is promptly noticed to the
engineer by stating that either the materials or goods which are required for the variation are
unavailable or such a variation causes a great difference on the progress of the work. The
engineer has the right to cancel the variation order, confirm and vary the instruction as well.
The contractor has no right to make any kind of changes, addition or omission to the progress
of the work unless told by the engineer to do so. [Sub-Clause 13.1]
3.1.2 Value Engineering
The variation request can be proposed by the contractor, if the proposal or draft by contractor
has an advantage for the client in case of:
I. If the contractor assume that it accelerate completion of construction works by
using different methods or changing sequence in construction, which provides an
advantage for the employer to be productive in short period of time.
II. Reduce the cost to the Employer of executing, maintaining or operating the
Works,
III. Improve the efficiency or value to the Employer of the completed Works, or
IV. Otherwise be of the benefit to the Employer.
For this case the contractor’s proposal can be approved by the engineer.
If the proposal is approved by the engineer, the contractor shall design it unless it agreed by
both parties. [Sub-Clause 13.2]
3.1.3 Variation Procedure
Variation works instructed by engineer’s approval for the necessary work or for the proposal
draft by contractor, the variation work will be assigned to contractor must be with formal
description. If the Engineer requests a proposal, prior to instructing a Variation, the
Contractor shall respond in writing as soon as practicable, either by giving reasons why he
cannot comply (if this is the case) or by submitting a description of the proposed work to be
performed and a program for its execution.
A variation is usually effected through an instruction from the engineer. Such instructions are
usually required to be in writing. Whether this is a pre-requisite to the contractor's right to
recover payment will depend on whether the requirement is a condition precedent. This is a
matter of interpretation of the contract. It is common enough to have provisions, as these are
here, more or less stringent, saying that no extra work shall be paid for unless it is ordered in
writing by the engineer, and if such conditions are properly made, and there is nothing
fraudulent or iniquitous in the way they are carried out, these conditions would be quite
sufficient and effectual. [Sub-Clause 13.3]
3.1.4 Payment in Applicable Currencies
There are different types of payment applicable for the construction industry, this issue is
mandatory especially for the international construction projects, because the contractor may
not be interested to participate in tender with local currency. Under MDB FIDIC Sub-Clause
13.4 applicability of payment with different types of currencies the amount payable in each of
the applicable currencies shall be specified. In order to clarify the applicability of payment
the proportions of the contract prices of the various currencies should specified , that means
the variation should be paid on the percentage proportion of the currency stated on the
contract document.[Sub-Clause 13.4]
3.1.5 Provisional Sums
Under sub-clause 13.5 of the MDB-FIDIC, it is stated that the provisional sum only are used
in whole or in part, in accordance with the engineer’s instruction. The provisional sum
includes the amount for the work done by the contractor or the sub contracting one, supplies
or the services given .whenever the contractor hires a sub contracting, the provisional sums
shall include the sum of the over head charges and profits of the contractor. The contractor
should present any relevant data like produce quotations, invoices, vouchers and accounts or
receipts when requested by the engineer. [Sub-Clause 13.5]
3.1.6 Daywork
In case of minor works, the contractor may be instructed by engineer to do day work. MDB
FIDIC clause 13.6 specify the payment to be done by the engineer by considering evidences
from vouchers, accounts & receipts for any goods buy by the contractor. This clause pressed
the contractor to give day to day accurate information to the engineer. But day work basis
should be conducted as per schedule of contract agreement. The contractor should submit an
accurate and detailed statement which includes the names, occupations and time of
Contractor’s Personnel, the identification, type and time of Contractor’s Equipment and
Temporary Works, and the quantities and types of Plant and Materials used, every day to the
engineer in order to specify the payment. The engineer should sign on the copies and return
them to the contractor. [Sub-Clause 13.6]
3.1.7 Adjustments for Changes in Legislation
According to Sub-Clause 13.7 the Contract Price shall be adjusted to take account of any
increase or decrease in Cost resulting from a change in the Laws of the Country, the judicial
or official governments will interpret such laws.
If the contractor is suffering from delays or additional cost as a result of these changes, the
Contractor shall give notice to the Engineer and shall be entitled to claim for an extension of
time for any such delay or payment of any such Cost. Notwithstanding the foregoing, the
Contractor shall not be entitled to an extension of time if the relevant delay has already been
taken into account in the determination of a previous extension of time and such Cost shall
not be separately paid if the same shall already have been taken into account in the indexing
of any inputs to the table of adjustment data. [Sub-Clause 13.7]
3.1.8 Adjustments for Changes in Cost
In the Sub-Clause of 13.8, there should be adjustment data for local and foreign currencies
included in the Schedules. If there is no such of adjustment data, the Sub-Clause shall not be
applied. But if there is such of adjustment data, the Sub-Clause applies, the amounts payable
to the Contractor shall be adjusted for rises or falls in the cost of labour, Goods and other
inputs to the Works, by the addition or deduction of the amounts determined by the formulae
prescribed in the Sub-Clause. The accepted Contract Amount shall be deemed to have
included amounts to cover the contingency of other rises and falls in costs. No adjustment is
to be applied to work valued on the basis of Cost or current prices.
The cost indices or reference prices stated in the table of adjustment data shall be used. If
their source is in doubt, it shall be determined by the Engineer. For this purpose, reference
shall be made to the values of the indices at stated dates for the purposes of clarification of
the source; although these dates (and thus these values) may not correspond to the base cost
indices.
In cases where the “currency of index” is not the relevant currency of payment, each index
shall be converted into the relevant currency of payment at the selling rate, established by the
central bank of the Country, of this relevant currency on the above date for which the index is
required to be applicable.[Sub-Clause 13.8]
3.2 Variation under PPA
The SDB for ICB of PPA specifies variation of works under section 7 in clauses 39 and 40 as
follows.
Variations
Sub Clause 39.1 of the PPA specifies that whenever the variation is produced is should
include all relevant data included and in case of lump sum contracts, it should include the
activities schedule as well, and the variation has to be prepared by the contractor. [Clause
39.1]
Payment for Variations
According to Clause 40 of PPA, The Engineer has the right to make Variation, specified
under the following sub clauses.
Sub Clause 40.1 states, both for Admeasurements and lump sum contracts, the contractor
should provide the variation request when ordered or instructed by the engineer and the
engineer shall asses the variation request within seven days period from request is done or
whenever of time duration stated before the variation is ordered.
But for the admeasurements’ contracts, if the work in the variation corresponds with an item
description in the bill of quantities and if, in the opinion of the engineer, the quantity of work
above the limit stated in sub-clause 38.1 or the timing of its execution. [Clause 40.2]
For both Admeasurements and lump sum contracts, if an engineer sees that the contractor’s
estimate is unreasonable, he/she can make a change to a contract price, based on his or her
experienced forecast. All extra or additional work done or work omitted by order of the
engineer shall be valued at the rates and prices set out in the contract if, in the opinion of the
Engineer, the same shall be applicable. If the contract does not contain any rates or prices
applicable to the extra or additional work then suitable rates or prices shall be agreed upon
between the engineer and the contractor. In the event of disagreement the Engineer shall fix
such rates or prices as shall, in his opinion. Be reasonable and proper. [Clause 40.3, Clause
40.4, Clause 40.5]
3.3 Variation under Applicable Law (civil code)
In the applicable law of Ethiopia (civil code), Variation of Contract is described in section 3
as follows:
According to the applicable law, Variation of Contract could be done:-
By the contracting parties, contractual variation, the contracting parties, in principle, are
free to create & vary their contractual agreement[Art. 1764,2]; or
By the Court, judicial variation, (as an exception Contracts may get their effect through
judicial variation, by way of exception, however. Judicial variation of Contracts, as
opposed to variation of Contract by the parties, is regulated by the applicable law. Under
the applicable law, the court may vary the terms of the contract under the following
circumstances.
Where it is expressly provided by law
Where a special relationship between the contracting parties exists
[Art. 1663, Art. 1764, 1 and Art. 1766]
By arbitration a third party, the parties may prefer to get a decision by the arbitrator
relating to the variations, especially on the economic basis of their contract. [Art. 1765]
Where one of the contracting parties is a state or of public institutions:
Power of the court to vary contracts, in case of Administrative Contract due to official
decision, Bringing the performance of the contract by the Contractor more onerous or
Impossible
This concept is important in relation to construction contract of public works nature.
Judicial variation may apply, for ex., in case of Administrative Contracts. Therefore,
the provisions of the Title of this Code relating to "Administrative contracts" (Art.
3191-3193).shall be applied [Art. 1767. and Art.3131.]
Where it is partially impossible to perform the contract
The court may reduce the obligations of the parties, either the employer or the contractor,
whenever the performance of the other one is partially impossible and the contract has no any
legal background to terminate it. [Art. 1768.]
Table similarity and differences of the MDB-FIDIC & the PPA Conditions of Contract with respect to variation
No
Considerations Similarity Differences
1 Definition of variation According to MDB-FIDIC ‘ “Variation” means any change to the Works, which is instructed or approved as a variation under Clause 13 [Variations and Adjustments]”.( Sub-Clause 1.1.6.9) According to PPA” A “Variation” is an instruction given by the Engineer, which varies the Works.” (Sub-clause 1.1) Both of condition of contracts defined variation as varied work.
In the case of PPA condition of contracts variation is defined as only instructed by the Engineer, but in the case of MDB-FIDIC variation may be instructed or approved according to the conditions specified clause 13 of MDB-FIDIC.
2 Constance of variation According to MDB-FIDIC sub-clause 13.1 (a) up to(f) contents of are described as follow
Changes to quantities and quality of item of works Changes to levels, positions and/or
dimensions omission of any work any additional work, Plant, Materials or
services changes to the sequence or timing of the
execution of the WorksBut in PPA there is no such clauses that defined the each variation may include
3 Right and obligation
to vary
By Engineer
Under MDB-FIDIC condition of contract the engineer has right to initiate, order, confirm and cancel the variation(sub-clause 13.1)Under PPA condition of contract the engineer has right request and asses the variations (sub-clause 40.1)
35
By Contractor
Under MDB-FIDIC condition of contract the right and the obligation of the contractor is stated (sub –clause 13.1), but in PPA anything is sated about right and obligation of the contractor
By Employer
Under MDB-FIDIC the Employer has to approve the variation order by the Engineer(Sub-Clause 3.1)Under PPA there is no any clauses that state this case
4 Value Engineering The concepts of value engineering are given in detail under MDB-FIDIC condition of contract (sub-clause 13.2), but nothing is stated under PPA
4 Procedure of variation According to MDB-FIDIC the procedure of variation begins with proposal request by the Engineer to the contractor, and then the contractor will respond this request in written form as soon as practicable. The response may be negative (if this is the case) or positive. It includes
a description of the proposed work to be performed and a programme for its execution,
modified programme of the contractor due to this variation (according to sub-clause 8.3)
the Contractor’s proposal for evaluation of the Variation
Finally the Engineer shall, as soon as practicable after receiving such proposal (under Sub- Clause 13.2 [Value Engineering] or otherwise), respond with approval, disapproval or comments. (Sub-Clause 13.3)In the case of PPA condition of contract there is no clause that state the procedure of variation
4 Currency that is applicable in variation payment, if the
MDB-FIDIC stated that the payment currency for the varied works should be based on the proportions of various currencies specified for payment of the Contract Price. (Sub-Clause 13.4)
36
contract involve various currencies
PPA also stated that “Unless otherwise stated, all payments and deductions will be paid or charged in the proportions of currencies comprising the Contract Price.” (Sub-Clause 43.3)
5 The provisional sum
6 Variation of works on Daywork basis
For minor or incidental nature of varied works both MDB-FIDIC and PPA allows execution of these works based on daywork basis. The rate of price shall be paid based on the rate valued in the contract document in both cases. (MDB-FIDIC Sub-Clause 13.6 and PPA Sub-Clause 53.1 )
7 Adjustments forChanges in Legislation
In MDB-FIDIC the contractor has the right to ask any adjustments regarding to cost and time whenever he feels that he suffers from additional cost as result of changes in the laws of the country, including introduction of new laws and modification of the existing one. But in PPA there is no clause that state this case
8 Adjustments forChanges in Cost
Sub-clause 13.8 of MDB-FIDIC and Sub-Clause 47.1 of PPA gives us the following adjustment factor
Definition of each terms are specified in the condition of the contract
37
4. Case Study of Three ERA Road Projects
4.1. General
This chapter tries to cover a case study of three finalized road projects. The projects are selected
randomly from completion report. One by one analysis of the three projects is presented as
follows.
4.2. Project 1
4.2.1. Project information
Road condition and scope of the work.
The existing road had a variable width of 6m to 7.5m and has now been rehabilitated to a 7m
width carriageway with 1.5m wide shoulders in flat and rolling terrain whilst in the hilly and
mountainous terrain the carriageway width is 6.5m with either 1m or 0.5m shoulders.
The rehabilitated pavement sections comprise of the following
35mm asphalt wearing course
40mm asphalt base or binder course
100mm crushed aggregate base course
50mm minimum depth of crushed aggregate stone base mixed with old milled existing asphalt
surfacing for leveling course.
The new pavement consists of the following
50mm asphalt wearing course
175mm to 200mm crushed aggregate base course
250mm granular sub base material
130mm to 265mm selected sub grade material
38
4.2.2. Basic contract data
a. Contract data for Construction contract
Contract Name Project 1
Type of project Road rehabilitation project
Employer ERA
Length 187Km
Notification of Contract 26 Nov 1999
Date of contract signature 28 Nov 2000
Commencement date 15 Mar 2001
Original time for completion 36 month
Original completion date 14 Mar 2004
Extension time 30.9 month
Revised completion Date 11 Jan 2007
Actual final completion date 18 Feb 2007
Type of contract Ad measurement according to
FIDIC
Original Contract Price ETB 289,838,439.05
Revised total contract amount ETB 482,117,075.20
Total Value of variations ETB 192,908,804.00
Revision of price cost ETB 59,963,756.22
Final contract price ETB 618,637,579.59
Escalation ETB 59,963,756.22
Currencies/Proportion of payments ETB 30%, Euro 70%
Contractual exchange rate 1Euro=8.46425 ETB
Funding European Development Fund
Table 3.1 contract data for project 1
b. Contract data for Consultancy service
Contract Name Project 1
39
Employer ERA
Supervisor Gauff Ingeneure GMBH & Co
KG-JBG Consulting Engineers
Date of contract signature 15 Mar 2001
Commencement date 27 Mar 2001
Original Contract Price ETB 13, 706, 739.75
Revised total contract amount ETB 28, 441, 376.42
Original time for completion 57 months
Original completion date 1 July 2005
Revised completion date 15 Oct 2005
Currencies/Proportion of payments ETB 18%, Euro 82%
Table 3.2 consultancy service contact data for project 1
4.2.3. Contract Changes and variations
Reference Description Extension of
time
Amount (ETB)
Vo 1 Additional costs for the provision and
maintenance of 4 long wheel base vehicles
and 4 double cabin pickups.
Nil 182,232.00
Vo 2 Rock core drilling at bridges b51 (Km
315) sampling and testing cores
Nil 75,944.53
Vo 3 Cleaning and de-silting of culverts Nil 184,050.00
Vo 4 Provision of gabions, steel flanges, geo
textile membrane and perforated pipes for
river training works at Km 335
Nil 1,302,231.83
Vo 5 Provision of additional Vehicles and
surveying equipment for the use of the
supervisor’s representative
Nil 933,958.96
Vo 6 Provision of additional radio equipments
for the use of the supervisor’s
Nil 120,000.00
40
representative
Vo 7 Provision of additional facilities and
equipments for the use of the supervisor’s
representative
Nil 367,328.70
Vo 8 Excavation of discharge ditches to culverts Nil 628,650.00
Vo 9 Design update and additional quantities 24.42 month 92,093,703.19
Vo 10 Omission of pavement works between km
368+872 and Km 369+187
Nil -167,465.78
Vo 11 Omission of works between Km368+872
and Km 369+187
Nil -1,320,578.80
Vo 12 Provision of four wheel drive petrol engine
air conditioned station wagons instead of
diesel engine vehicles
Nil -316,168.24
Vo 13 Revised type d1 pavement construction for
rock sub grade
Nil -547,635.75
Vo 14 Omission of pavement works between
Km314+660 and Km315+020
Nil -152,902.83
Vo 15 Additional quantities, extended period of
performance and associated costs
2.98 month 74,907,218.54
Vo 16 Omission of works between Km203+580
to Km 203+720
Nil -146,974.63
Vo 17 Omission of pavement works through
tunnel No, 1 Km 182+975 to Km 183+585
Nil -162,741.34
Vo 18 Additional quantities as a result of
unforeseen, unsuitable materials
encountered between Km 182 and Km 215
Extending period of performance and
additional associated costs
3.5 month 24,927,953.70
Total 30.9 month 192,908,804.00
Table 4.1. Variation orders at project 1
From this project we can relate and analysis the MDB-FIDIC clauses that are applicable for the
above variations. The detail is given below in the table
41
Table 4.2 Summery of
Relevant MDB-FIDIC Clauses Contract changes and variations in project-1
Sub-clause 13.1 Right
to vary, according to
this sub-clause each
variation has to
categorized under the
following units:
Sub-clause 13.1(a) Vo 4, Vo 9. Vo 15, Vo 18,
Sub-clause 13.1(b) Vo 9,Vo 13
Sub-clause 13.1(c) Vo 3
Sub-clause 13.1(d) Vo 10, Vo 11, Vo 14 and Vo 16
Sub-clause 13.1(e) Vo 1, Vo 2, Vo 4, Vo 5, Vo 6, Vo 7 and
Vo 12
Sub-clause 13.1(f)
Sub-clause 13.2 Value Engineering
In this project there is no any variations that
proposed by the contractor. All design
change are made by the Engineer
Sub-clause 13.3 variation procedure From the information we get all variations
are carried according to this sub-clause 13.3
of MDB-FIDIC
Sub-clause 13.4 Payment in Applicable
Currencies
Even if the currencies of the contract is
ETB(18%) and Euro(82%), the payment for
all variation is taken place by ETB.
4.3. Project 2
4.3.1 Project information
Road condition and scope of the work
Rehabilitation of the existing road to a standard 2 lane bitumen double bituminous
surface dressed road having 7m wide carriage way with 1.5m wide shoulders and
42
0.5m rounding on either side in flat and rolling sections and 2.5m paved shoulder and
0.5m rounding on either side in villages and small towns.
Improvement to the road side drainage system and other protective works.
Improvements, repairs and widening to the existing bridges wherever required and
also other cross drainage structures besides providing new ones.
Reconstruction of superstructure of bridges to 2 lane standards with foot paths and
modifying their substructures to the required extent.
Ancillary works such as housing and accommodation, vehicles, communication,
laboratory etc, for the use of engineer during execution.
Soil conservation and other protective measures along the road.
Road side furniture
4.3.2 Basic contract data
a. Contract data for Construction contract
Contract Name Project 2
Type of project Road upgrading project
Employer ERA
Length 120Km
Notification of Contract 12 Sept 2000
Date of contract signature 25 Oct 2000
Commencement date 7 Nov 2000
Original time for completion 912 days
Original completion date 6 May 2003
Extension time 6 May 2003 to 5 April 2004
Revised completion Date 5 April 2004
Type of contract Ad measurement
Original Contract Price ETB 223,651,990.00
Revised total contract amount ETB 227,975,527.52
Total Value of variations ETB 4,323,537.57
43
Escalation ETB 57,332,209.35
Currency and proportion of payment ETB 20%, USD 80%
Funding African Development Bank and
Federal Government of Ethiopia
Table 3.4 contract data for project 2
b. Contract data for Consultancy service
Contract Name Project 2
Employer ERA
Commencement date 14 Nov 2000
Original Contract Price USD 812,775.00 + ETB
4,219,813.00
Revised total contract amount USD 961,827.26 + ETB
5,001,102.96
Final cost of completion USD 941,582.83 + ETB
4,999,935.66
Original time for completion 13 May 2004+12 month (Defect
Liability period)
Revised completion date 30 April 2004+12 month (Defect
Liability period)
Table 3.5 contract data for consultancy for project 2
4.3.3 Contract Changes and variations
Reference Description Extension of
time
Amount (ETB)
Vo 1 Office and laboratory floor area Nil 785,145.15
44
Vo 2 Office furniture Nil 24,497.80
Vo 3 Survey Instruments Nil 209,836.68
Vo 4 Common Kitchen and wash area for
janitor staff
Nil 113,861.10
Vo 5 Office/ laboratory fittings Nil 111,712.01
Vo 6 Miscellaneous account for Engineers
office
Nil 115,000.00
Vo 7 Housing for junior staff and guest
houses
Nil 1,297,559.13
Vo 8 Office and laboratory furniture Nil 39,690.80
Vo 9 Cost of services for additional
prefabricated houses
Nil 139,087.53
Vo 10 Additional mobile radio sets Nil 28,570.00
Vo 11 Lean Concrete (M 10), stone masonry
using already stock piled stones, stone
masonry with cement mortar raito 1:3
and stone masonry with cement
maortar ratio 1:4 for which items did
not appear in BOQ
Nil 473,900.00
Vo 12 Jacking to gain access and examine
bearing of none bridge 1
Nil 40,394.55
Vo 13 Jacking to gain access and examine
bearing of none bridge 2
Nil 40,394.55
Vo 14 Clearing and refurbishing of bearing of
Bridge 3, apply epoxy paint, replace
missing nuts and applying approved
grease between sliding plates.
Nil 15,131.76
Vo 15 Clearing and refurbishing of bearing of
Bridge 4, apply epoxy paint, replace
missing nuts and applying approved
Nil 10,087.84
45
grease between sliding plates.
Vo 16 Modification work of superstructure of
bridge 5
Nil 249,976.07
Vo 17 Providing and fixing of Km sign posts Nil 57,567.60
Vo 18 Providing and fixing of guide posts Nil 553,665.00
Vo 19 Numbering of culverts Nil 20,460.00
Total Nil 4,323,537.57
Table 3.6 variation order at project 2
4.4 Project 3
4.4.1 Project Information
Road condition and scope of work
This road section has been completely rehabilitated during the execution of the project. The
existing pavement was scarified/ milled and incorporated in the new road. The level of the road
was raised over almost the full length to improve drainage conditions. The pavement
construction consists of sub-base and base course of variable thickness. Asphalt concrete is laid
in two separate layers to total thickness of 10cm. the road width is 7m carriage way with 1.5m
shoulder width each side the shoulders are sealed with a single surface treatment. Corrugated
metal pipe culverts have replaced existing culverts and additional pipe culverts were constructed.
Unpaved ditches have been constructed in rural areas where required. Existing bridges were
repaired, in one town of a by-pass was constructed, approximately 5km in length including two
new culverts the same town through road is rehabilitated to sub-base level.
3.3.2 Basic contract data
Contract Name Project 3
Employer ERA
Original Length 264.9Km
Revised Length 263.4 Km
Notification of award 25 July 1997
Date of contract signature 12 Sept 1997
46
Commencement date 15 Oct 1997
Original time for completion 36 month
Original completion date 14 Oct 2000
Extension time 12.9 month
Type of contract Ad measurement
Original Contract Price ETB 310,979,872.92
Revised total contract amount ETB 386,197,700.31
Total Value of variations ETB 75,217,827.39
Escalation ETB 17,914,749.44
Currency and proportion of payment ETB 30.29%, Euro 69.71%
Contractual exchange rate 1 Euro=8.10198 ETB
Funding African Development Bank and
Federal Government of Ethiopia
Table 3.7 contract data for project 3
3.3.3 Contract Changes and variations
Referenc
e
Description Amount (ETB)
Vo 1 Change of Vertical alignment at the Bridge approaches 1,015,763.14
Vo 2 Change of base coarse thickness town section from Km 110 1,438,656.00
Vo 3 Check points Km 23+800 and 70+700 1,119,060.27
Vo 4 Provisional of additional vehicles 1,890,519.47
Vo 5 Provision of transport stickers 30,328.20
Vo 6 Provision of thermoplastic lane markings and reflective
road studs
1,728,270.00
Vo 7 Road traffic signs 472,654.93
Vo 8 Full width sealing shoulders 296,800.00
Vo 9 Additional quantity of base course layer Km 110-Km275 5,815,584.00
Vo 10 Improvements to vertical alignment of a one town by pass 1,375,663.60
47
Vo 11 Traffic control at a river bridge 142,485.00
Vo 12 Improvement to the ring road 2,273,567.24
Vo 13 Painting of kerbed median and traffic islands 202,260.60
Vo 14 Provision of temporary additional vehicles for the
supervisor
85,500.00
Vo 15 HIV/ AIDS education campaign 324,786.00
Vo 16 Additional as –built drawings 16,583.78
Vo 17 Temporary repair of rail way crossing (Km 31+500) 13,225.10
Vo 18 Provision of road furniture materials to ERA stores 215,459.96
Vo 19 Deletion of road section from Km 10+500 to 12+160 -2,092,773.99
Vo 20 Change of vertical design Km 261+360 to Km262+790 1,633,944.80
Vo 21 Optimizing and detailing of vertical alignment of a town
section
9,148,815.17
Vo 22 Quantity changes de to finalized geometric design 3,743,905.70
Vo 23 Change of layout of town sections -620,977.85
Vo 24 Additional bus parking lay-bys for schools outside town 165,373.61
Vo 25 Provision of foot ways widening of parking lanes in town
sections
6,250,719.32
Vo 26 Additional drainage works at a town junction 927,319.52
Vo 27 Additional major and minor junctions 3,675,492.93
Vo 28 Additional minor junctions and other works 3,256,403.48
Vo 29 Provision of heavy duty parapet railing on a bridge 281,763.18
Vo 30 Partial rehabilitation of the existing one town road 684,373.41
Total 75,217,827.39
Table 3.8 variations order at project 3
48
49