REQUEST FOR PROPOSAL FOR A CONSULTANT … RFP 05-2017.pdf · for a domestic water tank reservoir...
Transcript of REQUEST FOR PROPOSAL FOR A CONSULTANT … RFP 05-2017.pdf · for a domestic water tank reservoir...
REQUEST FOR PROPOSAL 1 of 86 COVER PAGES
SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
REQUEST FOR PROPOSAL FOR A CONSULTANT APPOINTMENT TO PROVIDE A DESIGN
FOR A DOMESTIC WATER TANK RESERVOIR AND REPLACEMENT OF UNDERGROUND
WATER RETICULATION PIPELINE AT KIMBERLEY AND EAST LONDON AIRPORTS
Bid Number: : KIM05/2017
Document Issue Date : 25 OCTOBER 2017
1ST COMPULSORY
BRIEFING & SITE
INSPECTION SESSION
: 3rd November 2017 @ 11:00 CAT AT KIMBERLEY
AIRPORT
2ND COMPULSORY
BRIEFING & SITE
INSPECTION SESSION
: 6th NOVEMBER 2017 @ 11:00 CAT EAST LONDON
AIRPORT
TENDER CLOSING DATE ,
TIME & VENUE
: 20TH NOVEMBER 2017 @ 11 H00 AT KIMBERLEY
AIRPORT
REQUEST FOR PROPOSAL 2 of 86
INDEX
Definitions
Section 1: Instructions to Bidders
1.1 Access to RFP documents
1.2 Submission of bid documents
1.3 Alternative Bids
1.4 Late Bids
1.5 Clarification and Communication
1.6 Compulsory Briefing Session
1.7 Bid Responses
1.8 Disclaimers
1.9 Validity period
1.10 Confidentiality of information
1.11 Hot-Line
Section 2: Submission of Bid
2.1 Terms and Conditions of RFP
2.2 Bidding Arbitration Provision
2.3 RFP Acceptance
2.4 Response Format and Content
2.5 Further Obligations on Award
2.6 Disclaimers
Section 3: Background, Purpose, and Scope of RFP
3.1 Background
3.2 Purpose of this Tender
3.3 Scope of Work
REQUEST FOR PROPOSAL 3 of 86
Section 4: Preference (B-BBEE) and Price
4.1 Preference Points Claims
4.2 Adjudication Using a Points System
4.3 Award of Business where Bidders have scored equal points overall
4.4 Points awarded for Price
4.5 Points awarded for B-BBEE status level contribution
Section 5: Evaluation Criteria
5.1 Evaluation criteria
5.2 Stage 1 – Mandatory Requirements
5.3 Stage 2 – Pre- Qualification
5.4 Stage 3 – Functionality
5.4 Stage 4 – Price and B-BBEE
Section 6: Other Returnable Documents
6.1 Other Returnable Documents
6.2 Validity of Submitted Proposal
Appendices
Appendix A Declaration form
Appendix B Declaration of forbidden practices form
Appendix C Acceptance of RFP terms and conditions
Appendix D Company profile, executive summary and organogram
Appendix E Joint Venture (JV) Agreement (If applicable)
Appendix F Valid Tax Clearance Certificate
Appendix G B-BBEE Declaration Form
Appendix H B-BBEE Verification Certificate
REQUEST FOR PROPOSAL 4 of 86
Appendix I CV ’s of directors of the bidding entity
Appendix J Company Experience and References.
Appendix K Company Profile and Schedule of Bidder Experience
Appendix L Certificate of Incorporation
Appendix M Draft Service Agreement (NEC3 PSC)
REQUEST FOR PROPOSAL 5 of 86
DEFINITIONS
1.1 “B-BBEE” means broad-based black economic empowerment as defined in section 1 of the
Broad -Based Black Economic Empowerment Act;
1.2 “B-BBEE status level of contributor” means the B-BBEE status received by a measured
entity based on its overall performance using the relevant scorecard contained in the Codes
of Good Practice on Black Economic Empowerment, issued in terms of section 9(1) of the
Broad-Based Black Economic Empowerment Act;
1.3 “Black Designated Groups” has the meaning assigned to it in the codes of good practice
issued in terms of section 9(1) of the Broad-Based Black Economic Empowerment Act;
1.4 “Black People” has the meaning assigned to it in the codes of good practice issued in terms
of section 9(1) of the Broad-Based Black Economic Empowerment Act;
1.5 “Broad-Based Black Economic Empowerment Act” means the Broad-Based Black
Economic Empowerment Act 53 of 2003);
1.6 “Designated Group” means:
1.6.1 Black Designated Groups;
1.6.2 Black People;
1.6.3 Women;
1.6.4 People with disabilities; or
1.6.5 Small enterprises, as defined in section 1 of the national Small Enterprise Act 102 of 1996;
1.7 “Consortium or Joint Venture” means an association of persons for the purpose of
combining their expertise, property, capital, efforts, skill and knowledge in an activity for the
execution of a contract;
1.8 “EME” means an exempted micro enterprise in terms of the codes of good practice issued in
terms of section 9(1) of the Broad-Based Black Economic Empowerment Act;
1.9 “Functionality” means the ability of tenderer to provide goods or services in accordance with
specifications as set out in the tender documents;
1.10 “Military Veteran” has the meaning assigned to it in section 1 of the Military Veterans
Act 18 of 2011;
1.11 “People with disabilities” has the meaning assigned to it in section 1 of the
Employment Equity Act, 55 of 1998;
1.12 “Person” includes a juristic person;
1.13 “PPPFA” means the Preferential Procurement Policy Framework Act 5 of 2000 and
its Regulations published on 20 January 2017;
1.14 “Price” means all applicable taxes less all unconditional discounts;
1.15 “QSE” means a qualifying small business enterprises in terms of the codes of good
practice issued in terms of section 9(1) of the Broad-Based Black Economic Empowerment
Act
1.16 “Rand Value” means the total estimated value of a contract in South African currency,
calculated at the time of bid invitations, and includes all applicable taxes and excise duties;
1.17 “Rural Area” means:
1.17.1 a sparsely populated area in which people farm or depend on natural resources including
villages and small towns that are dispersed through the area; or
1.17.2 an area including a large settlement which dee ds a on migratory labour and remittances
and govern social grants for survival, and may have a traditional land tenure system;
REQUEST FOR PROPOSAL 6 of 86
1.18 “Total Revenue” bears the same meaning assigned to this expression in the Codes
of Good Practice on Black Economic Empowerment, issued in terms of section 9(1) of the
Broad-Based Black Economic Empowerment Act and promulgated in the Government
Gazette on 9 February 2007;
1.19 “Township” means an urban living area that any time from the late 19th century until
27 April 1994, was reserved for black people, including areas developed for historically
disadvantaged individuals post 27 April 1994;
1.20 “Trust” means the arrangement through which the property of one person is made
over or bequeathed to a trustee to administer such property for the benefit of another
person;
1.21 “Trustee” means any person, including the founder of a trust, to whom property is
bequeathed in order for such property to be administered for the benefit of another person;
and
1.22 “Youth” has the meaning assigned to it in section 1 of the National Youth
Development Agency Act 54 of 2008
All terms not defined herein have the meanings assigned to them in the PPPFA.
REQUEST FOR PROPOSAL 7 of 86
1. SECTION 1: INSTRUCTIONS TO BIDDERS
1.1. Access to RFP Documents:
Tender documents are available on www.etenders.gov.za. Kindly download, print and
complete for submission
No Tender documents will be issued from ACSA offices.
1.2. Submission of bid documents
The envelopes containing bid documents must have on the outside, the bidder’s return
address, the full description of the tender, tender number and the details of the Tender
Management Office/Procurement department where the bid will close. The documents must
be signed and completed by a person who has been given authority to act on behalf of the
bidder.
The bottom of each page of the bid documents must be signed or stamped with the
bidder’s stamp as proof that the bidder has read the tender documents. Bid documents
must be submitted on or before 11AM on 20th of November 2017 using the following
method(s):
Hand delivery:
The bid document must be delivered to the Tender Management Office located at the
address below and must be addressed as follows:
1.2.1. Tender box:
Tender Ref: KIM05/2017 Kimberley ACSA Offices 1st Floor Administration Building Compton Peterson Rd
Kimberley 8301
1.2.2. Email submissions:
No email submissions will be accepted only hand delivered documents will be
accepted
Proposals must be in duplicate (an original printed copy and a printed copy of the
original) The original copy will be the legal and binding copy, in the event of
discrepancies between any of the submitted documents; the original copy will take
precedence.
REQUEST FOR PROPOSAL 8 of 86
1.3. Alternative Bids
As a rule, ACSA only accepts bids which have been prepared in response to the tender
invitation. However, for this tender alternative bids will be accepted provided the alternative bid
is accompanied by the original bid response which materially complies with the specifications
of this tender invitation. The alternative bid will only be considered where the bidder has
submitted together with its alternative bid, an offer which materially complies with the
requirements of this tender. Alternative bids will also be evaluated using the pre-determined
evaluation criteria stipulated in this tender document.
1.4. Late Bids
BIDS WHICH ARE SUBMITTED AFTER THE CLOSING DATE AND TIME WILL NOT BE
ACCEPTED.
1.5. Clarification and Communication
Name: Mr Linda Mathebula
Designation: Buyer
Tel: 011 723 2624
Email: [email protected]
1.5.1. Request for clarity or information on the tender may only be requested until 15th of
November 2017 at 16H00. Any responses to queries or for clarity sought by a bidder
will also be sent to all the other entities which have responded to the Request for
Proposal/Quotation/Information invitation.
1.5.2. Bidders may not contact any ACSA employee on this tender other than those listed
above. Contact will only be allowed between the successful bidder and ACSA Business
Unit representatives after the approval of a recommendation to award this tender.
Contact will also only be permissible in the case of pre-existing commercial relations
which do not pertain to the subject of this tender.
REQUEST FOR PROPOSAL 9 of 86
1.6. Compulsory Briefing Sessions
The first compulsory briefing and Site Inspection session will be held on 3rd of November 2017 at 11H00 AM. The session will be held at the following location:
Kimberley Airport
Administration Building First Floor
Compton Peterson Rd
Kimberly Northern Cape
8301
The second compulsory briefing and site inspection session will be held on 6th November 2017
at 11H00AM The sessions will be held on the following location.
Tender Management Office:
1st Floor Terminal Building
66 Settlers Way
East London 5201
Bid Responses
Bid responses must be strictly prepared and returned in accordance with this tender document.
Bidders may be disqualified where they have not materially complied with any of ACSA’s
requirements in terms of this tender document. Changes to the bidder’s submission will not be
allowed after the closing date of the tender. All bid responses will be regarded as offers unless
indicates otherwise. No bidder or any of its consortium/joint venture members may have an
interest in any of the other bidder/joint venture/consortium participating in this bid.
1.7. Disclaimers
It must be noted that ACSA reserves its right to:
1.7.1. Award the whole or a part of this tender;
1.7.2. Split the award of this tender;
1.7.3. Negotiate with all or some of the shortlisted bidders;
1.7.4. Award the tender to a bidder other than the highest scoring bidder where objective criteria allow;
1.7.5. To reject the lowest acceptable tender received; and/or
1.7.6. Cancel this tender.
REQUEST FOR PROPOSAL 10 of 86
1.8. Validity Period
1.8.1. ACSA requires a validity period of hundred and Twenty (120) business/working days
for this tender
1.8.2. During the validity period the prices which have been quoted by the bidder must remain
firm and valid. It is only in exceptional circumstances where ACSA would accommodate
a proposal to change the price.
1.9. Confidentiality of Information
1.9.1. ACSA will not disclose any information disclosed to ACSA through this tender process
to a third party or any other bidder without any written approval form the bidder whose
information is sought.
1.9.2. ACSA will not disclose the names of bidders until the tender process has been
finalised.
1.9.3. Bidders may not disclose any information given to the bidders as part of this tender
process to any third party without the written approval from ACSA. If the bidder requires
consulting with third parties on the tender, such third parties must complete
confidentiality agreements, which should also be returned to ACSA with the bid.
1.10. Hot – Line
ACSA subscribes to fair and just administrative processes. ACSA therefore urges its clients,
suppliers and the public to report any fraud or corruption to:
Airports Company South Africa TIP-OFFS ANONYMOUS
Free Call: 0800 00 80 80
Free Fax: 0800 00 77 88
Email: [email protected]
REQUEST FOR PROPOSAL 11 of 86
SECTION 2: SUBMISSION OF PROPOSAL
2.1 Terms and Conditions of RFP
2.1.1 This RFP is open to all bidders, registered and duly authorised to operate in South Africa.
Any bids received after the bid submission date and time will not be considered by ACSA
2.1.2 Except where specifically provided for in this RFP, a bidder may make no changes to its
bid after the closing date and time.
2.1.3 ACSA reserves the right to award the contract based on the bid submission received from
a bidding entity subject to ACSA’s terms and conditions.
2.1.4 ACSA or their duly appointed representatives shall be the sole adjudicators of the
acceptability and or feasibility of the bids. The decision shall be final and except as required
by law or otherwise, no reason for the acceptance or rejection of any bid will be furnished.
2.1.5 Should the bid be awarded on the strength of information furnished by a bidder, which
information is proved to have been incorrect, in addition to any other legal remedy it may
have, ACSA may at any time during the life of the contract:
2.1.5.1 Recover from the relevant bidder all costs, losses or damages incurred by it because of the
award and/or
2.1.5.2 Cancel the award of the bid and/or contract and claim any damages, which it may have
suffered or will suffer because of having to make less favourable arrangements.
2.1.5.3 The Bidder shall be liable to pay for losses sustained and/or additional costs or expenditure
incurred by ACSA because of cancellation. ACSA shall furthermore have the right to
recover such losses, damages or additional costs by way of set off against monies due or
which may become due to the Bidder in terms of the said contract.
2.1.6 All representations, agreements or arrangements arising from bids submitted in terms
hereof (including any negotiations that follow) shall not be binding on ACSA, its officers,
employees or agents unless reduced to writing and signed by a duly authorised
representative of ACSA.
2.1.7 ACSA reserves the right to amend the terms and conditions of this RFP at any time prior to
finalisation of the contract between the parties and shall not be liable to any bidder or any
other person for damages of whatsoever nature which they may have suffered because of
such amendment. All bids are submitted at the entire risk of the bidder.
2.1.8 ACSA reserves the right to postpone the closing date for submission of bids or to withdraw
the RFP at any time without giving rise to any obligation for the responsibility for any loss
or financial damage which may be incurred or suffered by any bidder.
REQUEST FOR PROPOSAL 12 of 86
2.1.9 In the case of a joint venture or partnership between bidders, evidence of such joint venture
must be included with the bid submission, either in the form of a Joint Venture Agreement
and a joint SANAS accredited BBBEE Certificate. All the members of the joint venture must
in writing nominate a member(s) of the joint venture to complete and sign the RFP on behalf
of the joint venture. This written authority must be signed by the duly authorised members
of the joint venture and be submitted with the bid.
2.1.10 Bidders must ensure that all information submitted by them in their Bids is complete,
accurate and fairly represents the information communicated. Bidders must further ensure
that, irrespective of the weighting (if any) ascribed to any criterion; the Bid contains all
information relevant to an evaluation of that criterion. Any information which is incomplete,
inaccurate, ambiguous, unfairly represented or conditional may result in the Bid being
disqualified or adversely evaluated. Bidders must immediately notify ACSA in writing should
they become aware that any information stated in the Bids is or may be inaccurate for
whatever reason, including due to a subsequent change in circumstances.
2.1.11 After submitting a Bid, no Bidder may make any changes in the composition of its
consortium and / or shareholding before the final date and time for the submission of the
Bids without the prior written approval of ACSA. Full details of any such intended change
must be notified in advance, in writing, to ACSA for consideration. ACSA reserves the right
to reject or accept such change, whether conditionally or unconditionally. ACSA reserves
the right to disqualify any Bidder which makes or attempts to make any change to the
composition of its consortium other than in accordance with the aforesaid provisions.
2.2 Binding Arbitration Provision
2.2.1 It is a condition of participation in this RFP process between the bidder and ACSA that should
any dispute or difference arise between the parties, this shall be resolved by a single Arbitrator
2.2.1.1 Concerning the purported or effect of the RFP documents or of anything required to be done
or performed there under;
2.2.1.2 Concerning any aspect of the RFP process to anything done or decided there under: or
2.2.1.3 Concerning the validity of the award of the RFP to any bidder or the failure to award same to
any Bidder, then such dispute or difference shall be finally resolved by arbitration.
2.2.2 Such arbitration shall be by a single arbitrator who shall be -
2.2.2.1 Selected by agreement between the parties, or failing such agreement nominated on the
application of any party by the Arbitration Foundation of Southern Africa (AFSA); and
REQUEST FOR PROPOSAL 13 of 86
2.2.2.2 The arbitrator shall have power to review and revise any certificate, opinion, decision,
requisition or notice relating to all matters in dispute submitted to him/her and to determine all
such matters in the same manner as if no such certificate, opinion, decision, requisition or
notice had been issued.
2.2.3 Upon every or any such reference, the costs of an incidental to the reference and award shall
be at the discretion of the arbitrator, who may determine the amount of the costs, or direct
them to be taxed as between attorney and client or as between party and party and shall direct
by whom and to whom and in what manner they shall be borne and paid.
2.2.4 The award of the arbitrator shall be final and binding on the parties and any party shall be
entitled to apply to the Courts to have such award made an order of court.
2.2.5 Save as set out in this clause, the arbitration shall be conducted in accordance with the rules
of the Arbitration Foundation of Southern Africa for Commercial Arbitrations.
2.2.6 The arbitration shall be held in Johannesburg in the English language.
2.2.7 However, nothing in this clause shall preclude any party to the arbitration from seeking
interlocutory relief in any court having jurisdiction pending the institution of a review or other
appropriate proceedings for legal redress.
2.2.8 Such arbitration shall be commenced and concluded within 30 days of the dispute having
noted.
2.3 RFP Acceptance
2.3.1 ACSA reserves the right to reject: -
2.3.1.1 Incomplete bids;
2.3.1.2 Late bids;
2.3.1.3 Conditional bids; and
2.3.1.4 Bids that are non-compliant with the procedural and administrative requirements.
2.3.2 This RFP implies neither obligation to accept the highest or any bid nor any responsibility for
expenses or loss, which may be incurred by any bidder in preparation of his bid.
2.3.3 Bidders may include with their bids any descriptive matter, which, if referred to in the RFP, will
form part of the RFP. In case of any discrepancy, however, the issued RFP and supporting
documents and information completed therein by the bidder will be considered as the valid
and binding bid.
2.3.4 Notwithstanding any other provision in this document, no ACSA employee or any person
related to or associated with an ACSA employee may (individually or through a corporate
REQUEST FOR PROPOSAL 14 of 86
vehicle which includes a company, close corporate, trust, partnership etc.) submit a bid for
consideration in this tender process unless interest is declared and approved as per
Delegated Level of Authority.
2.4 Response Format and Content
2.4.1 Please organise proposals in separately tabbed/ indexed sections with labels that correspond
to the sections that have been outlined in the Index of this RFP document.
2.4.1.1 The bid document must be ring-bound or submitted in an arch lever file.
2.4.1.2 Please keep sections sequential.
2.4.1.3 Provide a concise response in provided spaces.
2.4.1.4 Wherever a table is provided, please title your section tab to match the RFP section in
which the table appears.
2.4.1.5 Use the table format provided for your responses, and maintain the sequence and
reference numbers in the table.
2.4.1.6 Please submit the bid documents in the format requested.
2.4.2 ACSA may, in its sole discretion and from time to time, extend the date or dates by
when the Successful Bidder is required to comply with the above terms.
2.4.3 ACSA shall have the right to withdraw, with immediate effect or with effect from any
reasonable future date nominated by it, in writing, the award of a Bid and to cancel any
contract consequent thereon if:
2.4.3.1 ACSA becomes aware of any fact or circumstance (including facts or circumstances
which arise after the award of the Bid) which, in ACSA’s sole and bona fide opinion,
would have rendered the Bid subject to disqualification had such fact or circumstance
arisen prior to the award and been known to ACSA at the time of the award;
2.4.3.2 The award of any Bid or conclusion of a Service Agreement is subsequently set aside
by any order of court, arbitration award or other binding agreement, award or finding,
whether such order, agreement, award or finding arises from contested proceedings
or an agreed settlement of any dispute;
2.4.4 Should ACSA elect to withdraw the award, the Successful Bidder’s Bid shall be
disqualified from further consideration by ACSA and ACSA shall proceed further as
may be appropriate, about the remaining Bids.
2.4.5 No Bidder shall have any right of recourse against ACSA because of the withdrawal of
REQUEST FOR PROPOSAL 15 of 86
a Bid award and / or cancellation of any Commercial Agreement by ACSA pursuant to
this Clause 2.4.
2.5 Further Obligations on Award
Unless expressly stated otherwise, the following warranties are given as at the date
on which a Bid is submitted to ACSA, as at the date on which any Bid is awarded and
for the period between those dates. The Bidder warrants to ACSA except as fully and
fairly disclosed to ACSA in writing in the Bid, that:
2.5.1 The information furnished by the Bidder is complete, accurate, unconditional and fairly
presented;
2.5.2 It will be able to allocate the appropriate resources to the scope of works as required
of this opportunity in order to be able to commence with the project within 30 days of
award.
2.6 Disclaimers
2.6.1 The information contained in the RFP or otherwise provided to Bidders, whether orally
or in writing (collectively “the RFP Documents”) was obtained from several sources
and is offered in good faith for the guidance of the Bidders only;
2.6.2 Any estimates and projections provided involve significant elements of subjective
judgement and analysis which may or may not be correct. Bidders are cautioned that
the information presented in the RFP Documents may be inaccurate inter alia due to
human error or due to incorrect source information having been furnished to ACSA.
Further, the information referred to herein is not an exhaustive account of the statutory
requirements which may affect a Bid and shall not be regarded as a complete or
authoritative statement of relevant Law;
2.6.3 Each Bidder is obliged to become acquainted with all of the provisions of the Laws
affecting the Bid, the entering into of the agreements and fulfilment of its terms;
2.6.4 The RFP Documents do not purport to contain all of the information that may be
required by Bidders to submit an offer and any recipient of the RFP Documents should
conduct its own independent legal, financial or other analysis of the information
contained or referred to in the RFP Documents and should obtain such professional
advice as it deems necessary;
2.6.5 This RFP Document supersedes all information concerning the detail of the property
REQUEST FOR PROPOSAL 16 of 86
concerned which may have been previously communicated to the Bidder, whether
orally, in writing or otherwise;
2.6.6 Neither ACSA nor its employees, directors or advisers may make any representation
or warranty, express or implied, or accept any responsibility or liability as to the
accuracy or completeness of the information contained in the RFP Documents or any
written or oral information made available in connection with ACSA, its business
activities and / or tender opportunities and nothing contained herein is or shall be relied
upon as a promise or representation, whether as to the past or as to the future.
2.6.7 The attached agreements are drafts. The detailed and final agreements will be
completed once an award has been made and negotiations have been finalised.
2.6.8 It is recorded that while bids will be accepted based on what is proposed, no
transaction will be concluded until the necessary agreements are negotiated and
signed by ACSA and the Preferred Bidder.
2.6.9 ACSA reserves the right to request from the bidder any additional information not
requested in the bid document.
REQUEST FOR PROPOSAL 17 of 86
SECTION 3: BACKGROUND, PURPOSE AND SCOPE OF WORK
3.1 Background
Since inception in 1993, Airports Company South Africa Limited (ACSA) has transformed into
a focused, profitable and commercial enterprise that is market-driven and customer service
oriented. The principal ACSA sites comprise of major international airports namely O.R. Tambo
(ORTIA), Cape Town (CTIA) and King Shaka (KSIA). The other sites are Bram Fischer
Bloemfontein, Upington, Port Elizabeth, East London Airport, George Airport, Kimberley Airport
and the Corporate Office.
The sustained growth in traffic over the years, coupled with a creative and performance focused
management and leadership team have contributed to the Company’s excellent financial
performance over time. This has enabled the Company to transform South Africa’s airports into
world-class airports, delivering value for customers, stakeholders, shareholders and
employees.
ACSA is focused on creating and operating world-class airports measuring up to international
standards. Numerous international awards won by certain of its airports over the years confirm
that the Company has largely succeeded in this aim. This is also shown in the 2017 Skytrax
ratings for example, Cape Town achieved Best Airport in Africa with King Shaka, OR Tambo,
East London and Port Elizabeth achieving 2nd, 3rd, 6th and 10th place respectively. The World
Airport awards area global benchmark for airport excellence and are largely known as the
Passenger’s Choice Awards.
3.2 Purpose of this Tender.
The purpose of this Tender is to appoint a consulting company to provide professional services
in designing: a domestic water tank and for the replacement of water reticulation underground
pipeline at Kimberley and East London Airports
The consultant shall deliver the project in the following stages:
• Inception Report
• Preliminary Design
• Detailed Design
• Documentation
• Contract Administration and inspection
• Close-Out
REQUEST FOR PROPOSAL 18 of 86
3.4 Scope of Work
Developing a detailed design for the domestic water tank at Kimberley and East London Airport
including piping to connect to the existing water reticulation network that supplies the airport with
domestic water. The design should also cater for a booster pump station to allow for adequate supply
of water to the terminal building and the neighbouring areas. East London Airport has an existing
domestic water tank with booster pump station, however the tank capacity is not adequate to meet
the water demand during water outages. Kimberley airport is not equipped with a domestic water tank,
domestic water is supplied by the municipal line directly to the building
Developing a detailed design for the replacement of domestic water mainline reticulation at Kimberley
airport. The water reticulation pipeline shall be designed in conjunction with the domestic water tank
design to allow for a complete system.
The consultant will also be responsible for development of the tender documentation for the
implementation phase; contract administration and site inspection; and compilation of the close out
report as more detailed in the specifications below.
The design shall take into consideration the climate conditions in the different locations (i.e. corrosion
protection, use of corrosion resistant material, etc.), however standardisation in the designs shall be
key.
Note: as built drawings are not available, identification and mapping of the existing reticulation pipeline
should be taken into consideration when pricing.
REQUEST FOR PROPOSAL 19 of 86
SECTION 4: PREFERENCE POINTS AND PRICE
4.1 Preference Points Claims
4.1.1 In terms of the PPPFA and its regulations only a maximum of 20 points may be awarded for preference.
4.1.2 The 80/20 system for requirements with a Rand value of up to R50 000 000 (all applicable taxes included); and
4.1.3 The value of this bid is estimated not to exceed R50 000 000 (all applicable taxes included) and therefore the 80/20 system shall be applicable. Preference points for this bid shall be awarded as follows:
Price Points
Points for Price 80
Preference Point (B-BBEE Level) 20
Total Points for Price and B-BBEE 100
4.1.4 SANAS issued BBBEE Certificate or an affidavit in the case of Qualifying Small Enterprises and an Emerging Micro Enterprises together with the bid, will be interpreted to mean that preference points for B-BBEE status level of contribution are not claimed
4.1.5 ACSA reserves the right to require of a bidder, either before a bid is adjudicated or at any time subsequently, to substantiate any claim in regard to preferences, in any manner required by ACSA.
4.2 Adjudication Using a Points System
4.2.1 The bidder obtaining the highest number of total points will be awarded the contract, or ACSA exercises one or more of its disclaimers;
4.2.2 Preference points will be calculated after prices have been brought to a comparative basis taking into account all factors of non-firm prices and all unconditional discounts
4.2.3 Points scored will be rounded off to the nearest 2 decimal places.
4.3 Award of Business where Bidders have Scored Equal Points Overall
4.3.1 In the event that two or more bids have scored equal total points, the successful bid will be the
one scoring the highest number of preference points for B-BBEE
REQUEST FOR PROPOSAL 20 of 86
4.3.2 However, when functionality is part of the evaluation process and two or more bids have
scored equal points including equal preference points for B-BBEE, the successful bid will be
the one scoring the highest score for functionality.
4.3.3 Should two or more bids be equal in all respects, the award will be decided by the drawing of
lots.
4.4 Points Awarded for Price
The 80/20 Preference Point Systems will be applied using the following formula:
min
min180
P
PPtPs
Where
Ps = Points scored for comparative price of bid under consideration
Pt = Comparative price of bid under consideration
Pmin = Comparative price of lowest acceptable bid
4.5 Points Awarded for B-BBEE Status Level of Contribution
4.5.1 In terms of Regulation 6 (2) and 7 (2) of the Preferential Procurement Regulations, preference points must be awarded to a bidder for attaining the B-BBEE status level of contribution in accordance with the table below;
B-BBEE Status Level of Contributor
Number of Points
(80/20 system)
1 20
2 18
3 14
4 12
5 8
6 6
7 4
8 2
Non-compliant contributor 0
REQUEST FOR PROPOSAL 21 of 86
4.5.2 Bidders who qualify as an EME in terms of the B-BBEE Act must submit a sworn affidavit or
certified certificate issued by a Verification Agency accredited by SANAS stating its annual
turnover and black ownership. Where a certificate is issued, such certificate must be
accompanied by a full report.
4.5.3 Bidders who qualify as a QSE in terms of the B-BBEE Act have an option to submit a sworn
affidavit or a certified issued by a Verification Agency accredited by SANAS stating its annual
turnover and black ownership. Where a certificate is submitted, such certificate must be
accompanied by a full report.
4.5.4 Bidders other than EMEs and QSEs must submit a certified copy of their valid B-BBEE status
level verification certificate substantiating their B-BBEE rating issued by a Verification Agency
accredited by SANAS. Such certificate must be accompanied by a full report.
4.5.5 A trust, consortium or joint venture, will qualify for points for their B-BBEE status level as a legal
entity, provided that the entity submits a consolidated B-BBEE status level certificate as if they
were a group structure. Should a trust, consortium or joint venture submit separate B-BBEE
status level certificates for each entity of the trust, consortium or joint venture, then the B-
BBEE points cannot be effectively claimed or evaluated and therefore such trust, consortium
or joint venture will be regarded as non-compliant B-BBEE contributor.
REQUEST FOR PROPOSAL 22 of 86
SECTION 5: EVALUATION CRITERIA
5.1 Evaluation Criteria
5.1.1 ACSA will use a pre-determined evaluation criterion when considering received bids. The
evaluation criteria will consider the commitment made for pre-qualifying criteria/ local production and
content/ Supplier Development, objective criteria and compulsory sub-contracting/ functionality/ Price
and B-BBEE. During the evaluation of received bids ACSA will make an assessment whether all the
bids comply with set minimum requirements and whether all returnable documents/information have
been submitted. Bidders which fail to meet minimum requirements, thresholds or have not submitted
required mandatory documents will be disqualified from the tender process
5.1.2 The requirements of any given stage must be complied with prior to progression to the next
stage. ACSA reserves the right to disqualify bidders without requesting any outstanding
document/information.
5.1.3 A staged approach will be used to evaluate bids and the approach will be as follows:
Stage 1 Stage 2 Stage 3
Mandatory Requirements
Functionality Price and B-BBEE
A list of Mandatory Administrative Requirements (MAR) returnable documents must form part of the submission at the closing date and time.
The functionality/technical evaluation will be conducted by the Bid Evaluation Committee which comprises of various skilled and experienced members from diverse professional disciplines.
80/20 Preferential System will be applied to this bid where 80 points are awarded for Price and 20 points are awarded for B-BBEE
5.2 Stage 1 - Mandatory Requirements
The following documents are required to be submitted by each bidder in order to proceed to
the next stage of evaluation:
5.1.1 Proof of attendance of the compulsory briefing session
5.1.2 Proof of registration of the Central Services Data Base
5.1.3 Signed Declaration of Interest form
5.1.4 Acceptance of ACSA terms and Conditions as contained in the bid
5.1.5 Proof of Company registration with relevant consulting professional body, i.e.
Consulting Engineers South Africa (CESA)
REQUEST FOR PROPOSAL 23 of 86
5.2 Stage 2 – Functionality
5.2.1 The functionality evaluation will be conducted by the Bid Evaluation Committee which
comprises of various skilled and experienced members from diverse professional
disciplines. The evaluation process will be based on minimum score to be met for
each criteria and sub criteria.
5.2.2 Bidders need to score a minimum of 60 points in respect of the following quality
criteria as well as meeting the minimum threshold per each criteria for eligibility to
proceed to the next phase
Description of
quality criteria WQ
Sub criteria Max
Score
Minimum
Threshold Quality Score
Tenderer’s resource
proposal 50
Qualifications 25 15
Year of experience in similar
works 25 15
References and
experience 50
At least one (1) references 20 12
Company Experience 30 18
Total Points 100 100 60
Qualifications -25
Proof of qualification should be attached to the resource’s CV’s for evaluation purposes. The
resources CV’s should clearly state the role assigned for this project. The proposed resources
qualification should at least be in the field of mechanical, civil, electrical engineering. The proposed
resources organogram and their role in this project should be attached to this proposal. Proposed
resources refer to key resources that will be directly involved in the designing and signing off the
design.
Note: Proposed resources score will be evaluated individually and the average points scored will be
used as the final score.
REQUEST FOR PROPOSAL 24 of 86
Proposed Resources’ Qualification (25) Max Min
Proposed resources do not have qualifications in the disciplines mentioned above. = [0]
25 15
Proposed resources have qualifications in the above-mentioned disciplines at the lower level than university of technology level = [0] Proposed resources have qualifications in the above-mentioned disciplines at the university of technology level. = [8] Proposed resources have qualifications in the above-mentioned disciplines at the university level. = [10]
Proposed resources are professionally registered with the Engineering Council of South Africa in the above-mentioned disciplines as a technologist or technician [7] Proposed resources are professionally registered with the Engineering Council of South Africa in the above-mentioned disciplines as an engineer [15]
Years of Experience – 25
Proof of relevant experience (provision of professional services for: designing of: underground
pipeline/ pump selection/ reservoir design/ pump house design/ fluid dynamics) should be reflected
in the resources’ CV’s for evaluation purposes.
Note: Proposed resources score will be evaluated individually and the average points scored will be
used as the final score.
Proposed Resources’ Experience Max Min
The proposed resource has not done projects involving the relevant works as detailed
above = [0]
25 15
The proposed resource has done projects involving designing of: underground
pipeline/ pump selection/ reservoir design.
• Less than 3 years =0
• Greater or equal to 5 years but less than 8 years = 15
• Greater than 8 years = 18
The proposed resource has done projects involving designing of: underground
pipeline, pump selection, reservoir design and pump house design.
• Less than 3 years =0
• Greater or equal to 5 years but less than 8 years = 18
• Greater than 8 years = 25
REQUEST FOR PROPOSAL 25 of 86
References – 20
The Suppliers should provide proof of at least one (1) company references of similar works (provision of
professional services for: designing of: underground pipeline/ pump selection/ reservoir design/ pump house
design/ fluid dynamics) previously done.
Company Experience– 30
The Tenderer should provide proof of similarity in the works ((provision of professional services for: designing
of: underground pipeline/ pump selection/ reservoir design/ pump house design/ fluid dynamics) previously
maintained facilities and the frequency of services conducted.
References (20) Max Min
No Reference Provided =0
20 12 1 Reference = 12
2 References = 15
> 3 References = 20
Company Experience (30) Max Min
The Company has not done relevant works as detailed above = [0]
30 18
The Company has done project relating to designing of: underground pipeline/
pump selection/ reservoir design.
• Greater than 1 but less than or equal to 3 projects = 18
• Greater than 3 projects = 20
The Company has done project relating to designing of: underground pipeline,
pump selection and reservoir design.
• Greater than 1 but less than or equal to 3 projects = 20
• Greater than 3 projects = 25
The Company has done project relating to designing of: underground pipeline,
pump selection, reservoir design, pump house design and fluid dynamics).
• Greater than 1 but less than or equal to 3 projects = 25
• Greater than 3 projects = 30
REQUEST FOR PROPOSAL 26 of 86
5.3 Stage 3 - Price and B-BBEE
This is the final stage of the evaluation process and will be based on the PPPFA preference
point system of_80/ 20 Price will amount to 80 points, whilst preference will be 20 points. The
award of business will be made to a bidder which has scored the highest overall points for this
stage of the evaluation Bidders must only price in accordance with the pricing schedule above,
this will enable ACSA to compare priced offers. Failure to submit a priced offer using the
prescribed schedule will make the bid liable for disqualification. The pricing schedule to be
completed is as follows:
REQUEST FOR PROPOSAL 27 of 86
Pricing schedule
Item No
Program Stage Activity Description Price
1 Stage 1
Inception Report
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
2 Stage 2
Preliminary Design
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
3 Stage 3
Detail Design
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
4 Stage 4
Documentation and Procurement
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
5 Stage 5
Contract Administration and Inspection
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
REQUEST FOR PROPOSAL 28 of 86
Item No
Program Stage Activity Description Price
6 Stage 6
Close-out
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
7 Disbursements Disbursements Provisional Sum include in total fees including health and safety inspections
R
8 Permits Provisional Sum: Airside induction Training, Vehicle and Personal Permits
R 5 000.00
9 Other 1: R
10 Other 2: R
11 Other: 3 R
Sub-Total 1 R
10% Contingency R
Total Fees (Excluding Vat) R
Vat R
Total Fees (Including Vat) R
Cost Split per Airport: This is for information purposes only. The sum of the total cost for the
breakdown below should add up to the total project cost excluding contingency cost.
Airport Cost [R]
Total Cost for Kimberley Airport: Water Tank and Supporting Systems
Total Cost for Kimberley Airport: Water Pipeline Reticulation Replacement
Total Cost for East London Airport: Water Tank and Supporting Systems
REQUEST FOR PROPOSAL 29 of 86
6 SECTION 6: OTHER RETURNABLE DOCUMENTS
6.1 These types of documents and information are required but are not mandatory or are only
mandatory at specific stages of the process. ACSA may request bidders to submit these
documents or information after the closing date and time or might already have them on the
system. Where a document or information is only mandatory at a specific stage in the process,
ACSA may only disqualify a bidder for non-submission at that stage and after reasonable efforts
were made to request the document from the bidder. The documents are as follows:
OTHER MANDATORY RETURNABLE DOCUMENTS AND
INFORMATION
SUBMITTED
[Yes or No]
B-BBEE Certificate (certified)
Names and identity documents of Directors (certified)
Certificate of Incorporation
Proof of professional Indemnity of R 5 million
Company Profiles (bidder and other professionals)
Proof of professional registrations (bidder and other professionals)
Valid tax clearance certificate/PIN/Proof of application to SARS
(certified)
6.2 Validity of submitted information
Bidders must ensure that any document or information which has been submitted in
pursuance to this tender remains valid for the duration of the contract period. The duty is on
the bidder to provide updated information to ACSA immediately after such information has
changed.
REQUEST FOR PROPOSAL 30 of 86
APPENDIX A: DECLARATION OF INTEREST FORM
Making a Declaration
Any legal person or persons having a relationship with persons employed by ACSA, including
a blood relationship, may submit a bid in terms of this Bid document. In view of possible
allegations of unfairness, should the resulting bid, or part thereof, be awarded to persons
connected with or related to ACSA employees, it is required that the bidder or his/her
authorised representative declare his/her position in relation to ACSA employees or any
member of the evaluation or adjudication committee which will consider bids. Furthermore,
ACSA requires all bidders to declare that they have not acted in any manner inconsistent with
the law, policy or fairness.
All bidders must complete a declaration of interest form below:
Full name of the bidder or representative of the Bidding entity
Identity Number
Position held in the bidding entity
Registration number of the bidding entity
Tax Reference number of the bidding entity
VAT Registration number of the bidding entity
I/We certify that there is a / no relationship between the bidding entity or any of its shareholders / directors / owner / member / partner with any ACSA employee or official.
Where a relationship exists, please provide details of the ACSA employee or official and the extent of the relationship below:
REQUEST FOR PROPOSAL 31 of 86
Full Names of Directors / Trustees / Members / Shareholders of the bidding entity
Full Name Identity Number Personal Income Tax Reference Number
I/We declare that we have not acted in any manner which promotes unfairness,
contravenes any law or is against public morals. We further certify that we will in full
compliance of this Bid terms and conditions as well as ACSA policies in the event that
we are successful in this Bid.
Declaration:
I/We the undersigned ____________________________________________________
(Name) herby certify that the information furnished in this Bid document is true and correct.
We further certify that we understand that where it is found that we have made a false
declaration or statement in this Bid, ACSA may disqualify our bid or terminate a contract we
may have with ACSA where we are successful in this Bid.
________________________________________________________________________
Signature Date
________________________________________________________________________
Position Name of bidder
REQUEST FOR PROPOSAL 32 of 86
APENDIX B: DECLARATION OF FORBIDDEN PRACTICES
I/We hereby declare that we have not/been found guilty of any illegal activities relating to
corruption, fraud, B-BBEE fronting, anti-competitive practices and/or blacklisted by an organ
of State Owned Company, etc. and/or any other forbidden practices.
I/We declare the following:
Description Penalty Organ of State / State Owned Company
a)
b)
c)
d)
Furthermore, I/We declare that to the best of my/our knowledge there is /are no further
practices to be declared or which are in the process of being finalised. The following are
alleged practices which have not yet been finalised.
Description Organ of State / State Owned Company
a)
b)
This declaration was signed on _______ of ____________________________ 2017
Name:
Designation:
Signature:
REQUEST FOR PROPOSAL 33 of 86
APPENDIX C: ACCEPTANCE OF RFP TERMS AND CONDITIONS
To: Supply chain management office
Airports Company South Africa SOC Limited
Proposal No: KIM05/2017
1. Bidder’s Name and Contact Details
Bidder:
Physical Address:
Correspondence to be addressed to:
Fax Number:
Phone numbers:
Email Address:
Contact Person:
2. Proposal Certification
We hereby submit a Proposal in respect of the designing of a domestic water tank reservoir
and replacement of underground water reticulation pipeline at Kimberley and East London
airports
2.1 We acknowledge that ACSA’s terms and conditions (as amended and mutually agreed
between the parties if necessary) shall apply to the agreement with the successful Bidder/s,
2.2 We have read, understand and agree to be bound by the content of all the documentation
provided by ACSA in this Request for Proposal.
REQUEST FOR PROPOSAL 34 of 86
2.3 We accept that ACSA’s Bid Adjudication Committee’s decision is final and binding.
2.4 We certify that all forms of the Bid as required in the bid document are included in our
submission.
2.5 We certify that all information provided in our bid is true, accurate, complete and correct.
2.6 This bid is specific to the designing of a domestic water tank reservoir and replacement of
underground water reticulation pipeline at Kimberley and East London airports Town
Planning and Urban Design Services only; it has no impact, influence or effect on any other
opportunity for which a bid may be submitted.
2.7 The undersigned is/are authorized to submit and sign the bid that shall be binding on closure
of the bid submission.
2.8 The bid is binding on this Bidder for a period which lapses after one hundred and twenty
(120) days calculated from the closing date of bid submission.
Thus, done and signed at _____________________on this the ______ day of __________2017
Signature:
Name:
For and behalf of:
Bidding entity name:
Capacity:
REQUEST FOR PROPOSAL 35 of 86
APPENDIX D: COMPANY PROFILE, EXECUTIVE SUMMARY AND ORGANOGRAM
Bidder to provide summary of their organisation and include their organisation’s Organogram
relevant to this opportunity with names, (starting with the Managing Directors/CEO)
Signed:
Date:
Name:
Position:
Bidder:
REQUEST FOR PROPOSAL 36 of 86
APPENDIX E: JOINT VENTURE (JV) AGREEMENT (IF APPLICABLE)
Bidder to attach agreement/Memorandum of understanding between the parties.
Signed:
Date:
Name:
Position:
Bidder:
REQUEST FOR PROPOSAL 37 of 86
APPENDIX F: VALID TAX CLEARANCE CERTIFICATE/ PIN/ PROOF OF APPLICATION
TO SARS
Bidder to attach valid tax clearance certificate/ pin/ proof of application to SARS
.
Signed:
Date:
Name:
Position:
Bidder:
REQUEST FOR PROPOSAL 38 of 86
APPENDIX G: B-BBEE DECLARATION FORM
1. Sub-Contracting
1.1 Will any portion of the opportunity be sub-contracted? YES / NO (*Delete whichever is not applicable)
1.2 If yes, indicate: a) The sub-contracted percentage is: ______%
b) The name of the sub-contractor is: ______________________________________
c) The B-BBEE status level of the sub-contractor is: _____________________
d) The sub-contractor is an EME: YES / NO (*Delete whichever is not applicable)
2. Declaration with Regard to the Bidder
2.1 Name of bidding entity
2.2. VAT Registration number:
2.3 Company registration number:
2.4 Type of company / firm:
Partnership/Joint Venture / Consortium
One person business/sole propriety
Close corporation
Company (Pty) Limited
(Indicate by ticking the relevant box)
2.5 Describe principal business activities
REQUEST FOR PROPOSAL 39 of 86
2.6 Company Classification
Manufacturer
Supplier
Professional service provider
Other service providers, e.g. transportation, etcetera.
(Indicate by ticking the relevant box)
2.7 Total numbers of years the company / firm has been in business: _________________ 2.8 I/we, the undersigned, who is/are duly authorised to do so on behalf of the company/firm, certify
that: 2.8.1 The information furnished is true and correct; 2.8.2 If the B-BBEE status level of contribution has been claimed or obtained on a fraudulent
basis or any of the conditions of contract have not been fulfilled, ACSA may, in addition to any other remedy it may have: a) Disqualify the person from the bidding process; b) Recover costs, losses or damages it has incurred or suffered because of that Person’s
conduct; c) Cancel the contract and claim any damages which it has suffered because of having
to make less favourable arrangements due to such cancellation; d) Restrict the bidder or sub-contractor, its shareholders and directors, or only the
Shareholders and directors who acted on a fraudulent basis, from obtaining Business from ACSA for a period not exceeding 10 years, after the audit alteram Partem (hear the other side) rule has been applied; and
e) Forward the matter for criminal prosecution.
Witnesses
1. ____________________________
2. ____________________________
Date: _______________________________________
Address: __________________________________
___________________________________________
___________________________________________
REQUEST FOR PROPOSAL 40 of 86
APPENDIX H: B-BBEE VERIFICATION CERTIFICATE
The bid must include a B-BBEE verification certificate issued by a SANAS accredited ratings
agency, or an IRBA Registered Accounting Practice.
A detailed report of the B-BBEE verification certificate must be included as part of the bid
submission. This report must clearly indicate an analysis of the shareholding.
Signed:
Date:
Name:
Position:
Bidder:
REQUEST FOR PROPOSAL 41 of 86
APPENDIX I: ORGANOGRAM FOR THE KEY RESOURCES, KEY RESOURCES CV’s
AND QUALIFICATIONS.
REQUEST FOR PROPOSAL 42 of 86 COVER PAGES
SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
APPENDIX J: COMPANY EXPERIENCE AND REFERENCES.
Completion certificates should be provided for the below references:
Item No.
Company Description of the works Duration of the
project Cost of Project Excluding Vat
Contact Person Contact Number
1
2
3
4
5
6
REQUEST FOR PROPOSAL 43 of 86 COVER PAGES
SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
APPENDIX K: COMPANY PROFILE
REQUEST FOR PROPOSAL 45 of 86 COVER PAGES
SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
APPENDIX M: DRAFT SERVICES AGREEMENT
AIRPORTS COMPANY SOUTH AFRICA
PROJECT NUMBER: 3432-4411-4412 SCM Ref no. : KIM 05/2017
DESIGN OF DOMESTIC WATER TANKS AND REPLACEMENT OF WATER MAINLINE RETICULATION
NEC 3: PROFESSIONAL SERVICES CONTRACT (PSC)
Between
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED Applicable at: Kimberley and East London Airports (Registration Number : 1993/004149/30)
and
______________________________________________________ (Registration Number: _____________________)
for
DESIGN OF DOMESTIC WATER TANKS AND REPLACEMENT OF WATER MAINLINE RETICULATION
REQUEST FOR PROPOSAL 46 of 86
DESIGN OF DOMESTIC WATER TANKS AND REPLACEMENT OF WATER MAINLINE RETICULATION
NEC 3: PROFESSIONAL SERVICES CONTRACT (PSC)
Contents:
Part C1 Agreements & Contract Data
C1.1 Form of Offer and Acceptance
C1.2a Contract Data provided by the Employer
C1.2b Contract Data provided by the Contractor
C1.3 Pro-forma Guarantee
C1.4 Insurance Schedule
Part C2 Pricing Data
Part C3 Scope of Work
Part C4 Site Information
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
47 of 86 Part C1.1: Form of Offer and Acceptance SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Part C1: Agreement and Contract Data C1.1 Form of Offer and Acceptance
Offer
The Employer, identified in the Acceptance signature block, has solicited offers to enter into a contract for the procurement of: Design of Domestic Water Tanks and Replacement of Water Mainline Reticulation
The tenderer, identified in the Offer signature block, has examined the documents listed in the Tender Data and addenda thereto as listed in the Returnable Schedules, and by submitting this Offer has accepted the Conditions of Tender.
The tenderer, identified in the Offer signature block, has examined the draft contract as listed in the Acceptance section and agreed to provide this Offer.
By the representative of the tenderer, deemed to be duly authorised, signing this part of this Form of Offer and Acceptance the tenderer offers to perform all of the obligations and liabilities of the Consultant under the contract including compliance with all its terms and conditions according to their true intent and meaning for an amount to be determined in accordance with the conditions of contract identified in the Contract Data.
THE OFFERED TOTAL OF THE PRICES INCLUSIVE OF VAT IS: (in words) ……………………………………………………………………………………………………………………..Rands; R ………………………………. including VAT (in figures)
THE OFFERED PRICES ARE AS STATED IN THE PRICING SCHEDULE
This Offer may be accepted by the Employer by signing the Acceptance part of this Form of Offer and Acceptance and returning one copy of this document including the Schedule of Deviations (if any) to the tenderer before the end of the period of validity stated in the Tender Data, or other period as agreed, whereupon the tenderer becomes the party named as the Consultant in the conditions of contract identified in the Contract Data.
Signature(s)
Name(s)
Capacity
For the tenderer:
Name & signature of witness
(Insert name and address of organisation) Date
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
48 of 86 Part C1.1: Form of Offer and Acceptance SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Acceptance
By signing this part of this Form of Offer and Acceptance, the Employer identified below accepts the tenderer’s Offer. In consideration thereof, the Employer shall pay the Consultants the amount due in accordance with the conditions of contract identified in the Contract Data. Acceptance of the tenderer’s Offer shall form an agreement between the Employer and the tenderer upon the terms and conditions contained in this agreement and in the contract that is the subject of this agreement.
The terms of the contract, are contained in:
Part C1 Agreements and Contract Data, (which includes this Form of Offer and Acceptance) Part C2 Pricing Data Part C3 Scope of Work: Works Information
and drawings and documents (or parts thereof), which may be incorporated by reference into the above listed Parts.
Deviations from and amendments to the documents listed in the Tender Data and any addenda thereto listed in the Returnable Schedules as well as any changes to the terms of the Offer agreed by the tenderer and the Employer during this process of offer and acceptance, are contained in the Schedule of Deviations attached to and forming part of this Form of Offer and Acceptance. No amendments to or deviations from said documents are valid unless contained in this Schedule.
The tenderer shall within two weeks of receiving a completed copy of this agreement, including the Schedule of Deviations (if any), contact the Employer’s agent (whose details are given in the Contract Data) to arrange the delivery of any securities, bonds, guarantees, proof of insurance and any other documentation to be provided in terms of the conditions of contract identified in the Contract Data. Failure to fulfil any of these obligations in accordance with those terms shall constitute a repudiation of this agreement.
Notwithstanding anything contained herein, this agreement comes into effect on the date when the tenderer receives one fully completed original copy of this document, including the Schedule of Deviations (if any). Unless the tenderer (now Consultant) within five working days of the date of such receipt notifies the Employer in writing of any reason why he cannot accept the contents of this agreement, this agreement shall constitute a binding contract between the Parties.
Signature(s)
Name(s)
Capacity
for the Employer
Airports Company South Africa SOC Limited, The Maples, River Woods, 24 Johnson Road. Bedfordview Gauteng 2008
Name & signature of witness
Date
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
49 of 86 Part C1.1: Form of Offer and Acceptance SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Schedule of Deviations 1 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Details . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
2 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Details . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
3 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
Details . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .
By the duly authorised representatives signing this agreement, the Employer and the Tenderer agree to and accept the foregoing schedule of deviations as the only deviations from and amendments to the documents listed in the Tender Data and addenda thereto as listed in the returnable schedules, as well as any confirmation, clarification or changes to the terms of the offer agreed by the Tenderer and the Employer during this process of offer and acceptance.
It is expressly agreed that no other matter whether in writing, oral communication or implied during the period between the issue of the tender documents and the receipt by the tenderer of a completed signed copy of this Agreement shall have any meaning or effect in the contract between the parties arising from this agreement.
For the Employer For the Bidder
Signature (s)
Name (s)
Capacity
Name and
Address
Airports Company South Africa SOC
Limited, The Maples, River Woods,
24 Johnson Road. Bedfordview Gauteng
2008
Name &
Signature of
witness
(Insert name and address of organisation) (Insert name and address of organisation)
Date
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
50 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Part C1.2a Contract Data
The Conditions of contract are selected from the NEC3 Professional Services Contract, April 2013. Each item of data given below is cross-referenced to the clause in the NEC3 Professional Services Contract which requires it.
Part one - Data provided by the Employer
1 General
The conditions of contract are the core clauses and the clauses for Main Option: A- Lump Sum Contract with Activity Schedule
Dispute resolution Option clause : W1
Secondary Options
X1. Price Adjustment
X7 Delay damages
X9 Transfer of rights
X10 Employer’s Agent X11 Termination by the Employer
X13. Performance Bond
X18: Limitation of liability
Z: Additional conditions of contract
of the NEC3 Professional Services Contract , April 2013.
The project stages are:
project stage Key deliverable at end of each stage as described in the Scope and accepted by the Employer No Description
1 Preparation As detailed in the scope of works Part C3
2 Project Initiation As detailed in the scope of works Part C3
3 Concept Design As detailed in the scope of works Part C3
4 Design development and tender documentation
As detailed in the scope of works Part C3
5 Construction Supervision As detailed in the scope of works Part C3
6 Close -Out As detailed in the scope of works Part C3
10.1 The Employer is: Airports Company South Africa SOC Limited , Regional Airport
Address:
Airports Company South Africa SOC Limited, The Maples, River Woods, 24 Johnson Road. Bedfordview, Gauteng, 2008
Tel No: +27 11 723 1400
Fax No: +27 11 453 9354
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
51 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
11.2(9)
The services are: Professional Services for design of water tanks and replacement of mainline water reticulation, as fully set out in the scope of works.
11.2(10) The following matters will be included in the Risk Register
• Availability of As Built information
• Access to Site
• Statutory approvals and ACSA approvals
• Site Constraints and Constructability
• Notification of Claims
• Financial and Procurement
11.2(11) The Scope is in the document called Part 3: Scope of Work
12.2 The law of the contract is the law of the Republic of South Africa
13.1 The language of this contract is English
13.3 The period for reply is 7 days
13.6 The period for retention is 1 year following Completion or earlier termination
2 The Parties’ main responsibilities
25.2 The Employer provides access to the following persons, places and things
access to access date
1 as built information and existing services Upon award of the project(s)
2 3
airside and landside safety procedure access to airside and landside
Upon award of the project(s) Upon award of the project(s)
3 Time
31.2 The starting date is on issuing of purchase order. .
11.2(3) The completion date for the whole of the services is 24 months after start date.
11.2(6) The key dates and the conditions to be met are:
Condition to be met key date (end-date)
1 Inspection and Preliminary Design 4 weeks after issuing of purchase order
2 Detailed design 8 weeks after approval of preliminary design
3 4 5
Drafting of tender documentation and evaluation Contract management Close out report
12 weeks after approval of detailed design 78 weeks after appointment of implementation contractor 2 weeks after completion
31.1 The Consultant is to submit a first programme for acceptance within 2 weeks of the Contract Date.
32.2 The Consultant submits revised programmes at intervals of 4 weeks.
4 Quality
40.2 The quality policy statement and quality plan are provided within 2 weeks of the Contract Date.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
52 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
41.1 The defects date is 52 weeks after Completion of the whole of the services.
5 Payment
50.1 The assessment interval ends and starts at 12h00 on the 25th day of each successive month.
51.1 The period within which payments are made is 4 weeks, after the receipt of the tax invoice.
51.2 The currency of this contract is the South African Rand (ZAR).
51.5 The interest rate is the prime lending rate of Standard Bank at any given time.
6 Compensation events No data required for this section of the conditions of contract.
7 Rights to material No data required for this section of the conditions of contract.
8 Indemnity, insurance and liability Refer to Part C1.4- generic conditions of contract insurance clauses
81.1 The amounts of insurance and the periods for which the Consultant maintains insurance are
Event Cover Period following Completion of the whole of the services or earlier termination
failure by the Consultant to use the skill and care normally used by professionals providing services similar to the services
Refer to PartC1.4 (The period is the contract
period plus latent defect period = total)
death of or bodily injury to a person (not an employee of the Consultant) or loss of or damage to property resulting from an action or failure to take action by the Consultant
Refer to PartC1.4
death of or bodily injury to employees of the Consultant arising out of and in the course of their employment in connection with this contract
Refer to PartC1.4
81.1 The Employer provides insurance cover for the project
82.1 Deductibles:
• In the event where the consultant defaults in its insurance obligations, the employer may take insurance on their own and then deduct the monthly premiums from the consultant.
• Refer to Part C1.4
9 Termination Refer to Secondary Clause X11.
10 Data for main Option clause
21.3 The Consultant prepares forecasts of the total of the expenses at intervals of no longer than 4 weeks.
11 Data for Option W1
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
53 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
W1.1 The Adjudicator is the person selected by the Parties as and when a dispute arises in terms of the relevant Z Clause, from the Panel of Adjudicators provided under the relevant Z clause
W1.2(3) The adjudicator nominating body is the current Chairman of the Johannesburg Advocates’ Bar Council.
W1.4(2) The tribunal is Arbitration
W1.4(5) The arbitration procedure is as set out in the Conduct of arbitrations published by the association of Arbitrators (Southern Africa) of its successor body.
The place where arbitration is to be held is Johannesburg, South Africa.
The person or organisation who will choose an arbitrator if the Parties cannot agree a choice or if the arbitration procedure does not state who selects an arbitrator, is the Chairman of the Association of Arbitrators (Southern Africa) or its successor body
12 Data for secondary Option clauses
X1 Price Adjustment
X1.2. Price Adjustment Option A: the total tendered price shall be fixed for the duration of the contract. Price adjustments shall be factored in when pricing.
X7
Delay Damages
X7.1. Delay damages for each section of the work are 0.05% of the contract value per week
X10 The Employer’s Agent
X10.1 The Employer’s Agent is
Name: Sibusiso Lukhele
Address: Airports Company South Africa SOC Limited Regional Airports 39 Wordsworth Avenue Saint Adrew Office Park, Block C Senderwood Bedfordview 2008
The authority of the Employer’s Agent is Project Manager.
X11 Termination by Employer
X11.1 The Employer may terminate the Consultant’s obligation to Provide the services for a reason not stated in this contract by notifying the Consultant.
X13. Performance Bond
X13.1 The performance bond shall be 10% of the total contract value and it should be provided as detailed in Part C1.3.
X18 Limitation of liability
X18.1 The Consultant’s liability to the Employer for indirect or consequential loss is Nil
The Employer’s liability to the Consultant for indirect or consequential loss is Nil The total Direct liability does not exceed 100% of the contract value cumulative total for either party
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
54 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
X18.2 The Consultant’s liability to the Employer for Defects that are not found until after the defects date is capped at the total of the contract price.
X18.3 The end of liability date is 1 year after Completion of the whole of the services.
ADDITIONAL CONDITINS OF CONTRAC
Z1
Z2
Estimation of fees It is specifically recorded that the fees charged by the consultant for services rendered in connection with and/or under this Contract shall be in terms of: The Engineering Council of South Africa (ECSA) Tax invoices The Consultant’s invoice. Delete the first sentence of core clause 50.2 and replace with: Invoices submitted by the Consultant to the Employer include
• the details stated in the Scope to show how the amount due has been assessed, and
• the details required by the Employer for a valid tax invoice. Delete the first sentence of core clause 51.1 and replace with: Each payment is made by the Employer within four weeks of receiving the Consultant’s invoice showing the details which this contract requires or, if a different period is stated in the Contract Data, within the period stated.
Z3 Communications and Notices Z3.1 Add to the end of the first sentence in core Clause 13.1: All notices, notifications, requests, demands or other communications shall be deemed to have reached the other Party –
- if delivered by hand, on the date of delivery; - if posted by ordinary mail or registered post, on the 5th (fifth) calendar day following the date of such
posting; - if transmitted by facsimile or any other electronic medium acceptable to both Parties, on the first
Business Day following the date of transmission / publication / delivery.
Z4 Appointment of the Adjudicator An Adjudicator is appointed when a dispute arises, from the Panel of Adjudicators below. The referring party nominates an Adjudicator, which nomination is either accepted or rejected by the other party. In the instance of a rejection of the nominated Adjudicator, the referring Party refers the appointment deadlock to the Chairman of the Johannesburg Bar Council, who appoints an Adjudicator listed in the Panel of Adjudicators below. The Parties appoint the Adjudicator under the NEC3 Adjudicator’s Contract, April 2013
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
55 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
PANEL OF ADJUDICATORS
Name Location Contact details (phone & e mail)
Adv. Ghandi Badela Gauteng +27 11 282 3700 [email protected]
Mr. Errol Tate Pr. Eng. Durban +27 11 262 4001 [email protected]
Adv. Saleem Ebrahim Gauteng +27 11 535-1800 [email protected]
Mr. Sebe Msutwana Pr. Eng. Gauteng +27 11 442 8555 [email protected]
Mr. Sam Amod Gauteng [email protected]
Adv. Sias Ryneke SC Gauteng 083 653 2281 [email protected]
Mr. Emeka Ogbugo (Quantity Surveyor)
Pretoria +27 12 349 2027 [email protected]
Z4.1
Appointment of the Arbitrator An Arbitrator is appointed when a dispute arises from the Panel of Arbitrators below. The referring party nominates an Arbitrator, which nomination is either rejected or accepted by the either party. In the instance of a rejection of the nominated Arbitrator, the referring party refers the Appointment deadlock to the Chairman of the Johannesburg Bar Council, who appoints an Arbitrator listed in the Panel of Arbitrators below. An appointed Arbitrator shall provide his written award no later than 30 days following the last day of closing arguments.
PANEL OF ARBITRATORS
Name Location Contact details (phone & e mail)
Adv. Ghandi Badela
Gauteng +27 11 282 3700 [email protected]
Mr. Errol Tate Pr. Eng.
Durban +27 11 262 4001 [email protected]
Adv. Saleem Ebrahim
Gauteng +27 11 535-1800 [email protected]
Mr. Sebe Msutwana Pr. Eng.
Gauteng +27 11 442 8555 [email protected]
Mr. Sam Amod
Gauteng [email protected]
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
56 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Adv. Sias Ryneke SC
Gauteng 083 653 2281 [email protected]
Mr. Emeka Ogbugo (Quantity Surveyor)
Pretoria +27 12 349 2027 [email protected]
Z5 Interpretation of the law
Add to core clause 12.3: Any extension, concession, waiver or relaxation of any action
stated in this contract by the Parties, the Project Manager, the Supervisor, or the Adjudicator
does not constitute a waiver of rights, and does not give rise to an estoppel unless the Parties
agree otherwise and confirm such agreement in writing.
Z6 Providing the Works: Delete core clause 20.1 and replace with the following:
The Consultant will supervise the works in accordance with the Works Information and
warrants that the results of the Works done in accordance with the drawings and
specifications, when complete, shall be fit for their intended purpose.
Z7 Extending the defects date: add the following as a new core clause 46:
Z7.1 If the Employer cannot use the works due to a Defect, which arises after Completion and before the defects date, the defects date is delayed by a period equal to that during which the Employer, due to a Defect, is unable to use the works.
Z7.2 If part of the works is replaced due to a Defect arising after Completion and before the defects
date, the defects date for the part of the works which is replaced is delayed by a period equal to
that between Completion and the date by when the part has been replaced.
Z7.3 The Project Manager notifies the Consultant of the change to a defect date when the delay occurs. The period between Completion and an extended defects date does not exceed twice the period between Completion and the defects date stated in the Contract Data.
Z8 Termination
Z8.1 Add the following to core clause 91.1, at the second main bullet, fifth sub-bullet point,
after the words “assets or”: “business rescue proceedings are initiated or steps are taken to
initiate business rescue proceedings”.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
57 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Z9 Cession, delegation and assignment
Z9.1 The Consultant shall not cede, delegate or assign any of its rights or obligations to any person without the written consent of the Employer, which consent shall not be unreasonably withheld.
Z9.2 The Employer may, on written notice to the Consultant, cede and delegate its rights and obligations under this contract to any person or entity.
Z10 Z10.1
Ethics The Consultant Undertakes:
Z10.1.1 not to give any offer, payment, consideration, or benefit of any kind, which constitutes or could be construed as an illegal or corrupt practice, either directly or indirectly, as an inducement or reward for the award or in execution of this contract;
Z10.1.2 to comply with all laws, regulations or policies relating to the prevention and combating of bribery, corruption and money laundering to which it or the Employer is subject, including but not limited to the Prevention and Combating of Corrupt Activities Act, 12 of 2004.
Z10.2 The Consultant’s breach of this clause constitutes grounds for terminating the Consultant’s obligation to Provide the Works or taking any other action as appropriate against the Consultant (including civil or criminal action). However, lawful inducements and rewards shall not constitute grounds for termination.
Z10.3 If the Consultant is found guilty by a competent court, administrative or regulatory body of participating in illegal or corrupt practices, including but not limited to the making of offers (directly or indirectly), payments, gifts, gratuity, commission or benefits of any kind, which are in any way whatsoever in connection with the contract with the Employer, the Employer shall be entitled to terminate the contract in accordance with the procedures stated in core clause 92.2. the amount due on termination is A1.
Z11. Confidentiality
Z11.1. All information obtained in terms of this contract or arising from the implementation of this contract shall be treated as confidential by the Consultant and shall not be used or divulged or published to any person not being a party to this contract, without the prior written consent of the Project Manager or the Employer, which consent shall not be unreasonably withheld.
Z11.2 If the Consultant is uncertain about whether any such information is confidential, it is to be regarded as such until otherwise notified by the Project Manager.
Z11.3 This undertaking shall not apply to –
Z11.3.1 Information disclosed to the employees of the Consultant for the purposes of the implementation of this agreement. The Consultant undertakes to procure that its employees are aware of the confidential nature of the information so disclosed and that they comply with the provisions of this clause;
Z11.3.2 Information which the Consultant is required by law to disclose, provided that the Consultant notifies the Employer prior to disclosure so as to enable the Employer to take the appropriate action to protect such information. The Consultant may disclose such information only to the extent required by law and shall use reasonable efforts to obtain assurances that confidential treatment will be afforded to the information so disclosed; and
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
58 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Z11.3.3 Information which at the time of disclosure or thereafter, without default on the part of the Consultant, enters the public domain or to information which was already in the possession of the Consultant at the time of disclosure (evidenced by written records in existence at that time).
Z11.4 The taking of images (whether photographs, video footage or otherwise) of the works or any portion thereof, in the course of Providing the Works and after Completion, requires the prior written consent of the Project Manager. All rights in and to all such images vests exclusively in the Employer.
Z11.5 The Consultant ensures that all his Sub-Consultants abide by the undertakings in this clause.
Z12. Employer’s Step-in rights
Z12.1 If the Consultant defaults by failing to comply with his obligations and fails to remedy such default within 2 weeks of the notification of the default by the Project Manager, the Employer, without prejudice to his other rights, powers and remedies under the contract, may remedy the default either himself or procure a third party (including any sub-Consultant or supplier of the Consultant) to do so on his behalf. The reasonable costs of such remedial works shall be borne by the Consultant.
Z12.2 The Consultant co-operates with the Employer and facilitates and permits the use of all required information, materials and other matter (including but not limited to documents and all other drawings, CAD materials, data, software, models, plans, designs, programs, diagrams, evaluations, materials, specifications, schedules, reports, calculations, manuals or other documents or recorded information (electronic or otherwise) which have been or are at any time prepared by or on behalf of the Consultant under the contract or otherwise for and/or in connection with the works) and generally does all things required by the Project Manager to achieve this end.
Z13. Intellectual Property
Z13.1 Intellectual Property (“IP”) rights means all rights in and to any patent, design, copyright, trade mark, trade name, trade secret or other intellectual or industrial property right relating to the Works.
Z13.2 IP rights remain vested in the originator and shall not be used for any reason whatsoever other than carrying out the works.
Z13.3 The Consultant gives the Employer an irrevocable, transferrable, non-exclusive, royalty free licence to use and copy all IP related to the works for the purposes of constructing, repairing, demolishing, operating and maintaining the works.
Z13.4 The Consultant shall indemnify and hold the Employer harmless against and from any claim alleging an infringement of IP rights (“the claim”), which arises out of or in relation to:
Z13.4.1 the Consultant’s design, manufacture, construction or execution of the Works;
Z13.4.2 the use of the Consultant’s Equipment, or
Z13.4.3 the proper use of the Works.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
59 of 86 Part C1.2a: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Z13.5 The Employer shall, at the request and cost of the Consultant, assist in contesting the claim and the Consultant may (at its cost) conduct negotiations for the settlement of the claim, and any litigation or arbitration which may arise from it.
Z14 Dispute resolution: The following amendments are made to Option W1:
Z14.1 Under clause W1.3, in the fourth row of the first column of the adjudication table, the
following words are added after the words “any other matter”: “excluding disputes relating
to termination of the contract”.
Z14.2 The following clauses are added at the end of clause W1.3:
Z14.2.1 “The Adjudicator shall decide the dispute solely on the written submissions of the parties. No
oral submissions shall be heard during adjudication.”
Z14.2.2 Z15
“Disputes relating to or arising from termination of the Contract shall not be determined by an
adjudicator. Any such dispute shall be referred directly to arbitration.”
The Consultant shall be expected to annually present a compliant BEE Certificate. Failure to do
adhere to these requirements shall be considered a material breach of the conditions of this
Contract, the sanction for which may be a cancellation of this Contract.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
60 of 86 Part C1.2b: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Part C1.2b Contract Data
The conditions of contract are the NEC3 Professional Service Contract, April 2013 Each item of data given below is cross-referenced to the clause in the NEC3 Professional Service Contract to which it mainly applies.
Part two - Data provided by the Consultant
Clause Statement
10.1 The Consultant is (Name):
Address:
Tel No.:
Fax No.:
Email:
22.1 The Consultant’s key persons are:
1 Name:
Job: Role in this Project
Responsibilities:
Qualifications:
Experience:
2 Name:
Job: Role in this Project
Responsibilities:
Qualifications:
Experience:
3 Name:
Job: Role in this Project
Responsibilities:
Qualifications:
Experience:
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
61 of 86 Part C1.2b: Contract Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
4 Name:
Job: Role in this Project
Responsibilities:
Qualifications:
Experience:
11.2(3) The completion date for the whole of the services is as required by ACSA
11.2(10) The following matters (if any) will be included in the Risk Register
• Availability of As-Built Information
• Access to Site
• Progress vs Programme
• Cash Flow Management
11.2(13) The staff rates are as stated in the Pricing Data
A
Priced contract with activity schedule
11.2(14) The activity schedule is in the Pricing Data
11.2(18) The tendered total of the Prices is in the Form of Offer and Acceptance
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
62 of 86 Part C1.3: Pro-Forma Guarantees SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Part C1.3 Pro-forma Guarantee (Performance Bond)
Pro forma Performance Bond – Demand Guarantee (for use with Option X13) (to be reproduced exactly as shown below on the letterhead of the Bank providing the Bond / Guarantee)
Airports Company South Africa SOC Limited, The Maples, River Woods, 24 Johnson Road. Bedfordview Gauteng 2008
Bank reference No.
Date:
Dear Sirs,
Performance Bond – Demand Guarantee for [insert name of Consultant] required in terms of contract [insert
Consultant’s contract reference number or title]
1. In this Guarantee the following words and expressions shall have the following meanings: -
1.1 “Bank” means [Insert name of Bank], [●] Branch, Registration No. [●]
1.2 “Bank’s Address” means [Insert physical address of Bank]
1.3 “Contract” means the written agreement relating to the Services, entered into between the Employer
and the Consultant, on or about the [●] day of [●] 200[●] (Contract Reference No.
[●]) as amended, varied, restated, novated or substituted from time to time;
1.4 “Consultant” means [●] a company registered in accordance with the laws of [●] under Registration
No [●].
1.5 “Employer” means [●] a company registered in accordance with the laws of the Republic of South
Africa under Registration Number [●]
1.6 “Expiry Date” means the earlier of
• the date that the Bank receives a notice from the Employer stating that all amounts due from the Consultant as certified in terms of the contract have been received by the Employer and that the Consultant has fulfilled all his obligations under the Contract, or
• the date that the Bank issues a replacement Bond for such lesser or higher amount as may be required by the Employer.
1.7 “Guaranteed Sum” means the sum of R[●], ([●] Rand)
1.8 “Services” means [●]
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
63 of 86 Part C1.3: Pro-Forma Guarantees SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
2. At the instance of the Consultant, we the undersigned ______________ and ______________, in our respective capacities as _____________ and ___________ of the Bank, and duly authorized thereto, confirm that we hold the Guaranteed Sum at the disposal of the Employer as security for the proper performance by the Consultant of all of its obligations in terms of and arising from the Contract and hereby undertake to pay to the Employer, on written demand from the Employer received prior to the Expiry Date, any sum or sums not exceeding in total the Guaranteed Sum.
3. A demand for payment under this guarantee shall be made in writing at the Bank’s address and shall:
• be signed on behalf of the Employer by a director of the Employer;
• state the amount claimed (“the Demand Amount’);
• state that the Demand Amount is payable to the Employer in the circumstances contemplated in the Contract.
4. Notwithstanding the reference herein to the Contract the liability of the Bank in terms hereof is as principal and not as surety and the Bank’s obligation/s to make payment:
• is and shall be absolute provided demand is made in terms of this bond in all circumstances; and
• is not, and shall not be construed to be, accessory or collateral on any basis whatsoever.
5. The Bank’s obligations in terms of this Guarantee:
• shall be restricted to the payment of money only and shall be limited to the maximum of the Guaranteed Sum; and
• shall not be discharged and compliance with any demand for payment received by the Bank in terms hereof shall not be delayed, by the fact that a dispute may exist between the Employer and the Consultant.
6. The Employer shall be entitled to arrange its affairs with the Consultant in any manner which it sees fit, without advising us and without affecting our liability under this Guarantee. This includes, without limitation, any extensions, indulgences, release or compromise granted to the Consultant or any variation under or to the Contract.
7. Should the Employer cede its rights against the Consultant to a third party where such cession is permitted under the Contract, then the Employer shall be entitled to cede to such third party the rights of the Employer under this Guarantee on written notification to the Bank of such cession.
8. This Guarantee:
• shall expire on the Expiry Date until which time it is irrevocable;
• is, save as provided for in 7 above, personal to the Employer and is neither negotiable nor transferable;
• shall be returned to the Bank upon the earlier of payment of the full Guaranteed Sum or expiry hereof;
• shall be regarded as a liquid document for the purpose of obtaining a court order; and
• shall be governed by and construed in accordance with the law of the Republic of South Africa and shall be subject to the jurisdiction of the Courts of the Republic of South Africa.
• will be invalid and unenforceable if any claim which arises or demand for payment is received after the Expiry Date.
9. The Bank chooses domicilium citandi et executandi for all purposes in connection with this Guarantee at the Bank’s Address.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
64 of 86 Part C1.3: Pro-Forma Guarantees SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Signed at on this day of 20__
For and on behalf of the Bank
Bank Signatories(s)
Name(s) (printed)
Witness(s)
Bank’s seal or stamp
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
65 of 86 Part C1.4: Insurance Schedule SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Part C1.4 Insurance – Generic Conditions of Contract Insurance
SECTION A: DEFINITIONS
Landside refers to:
• Areas of the airport before the security points, and
• The restricted area beyond the security points but, within the perimeter of gatehouses, passenger
terminals and cargo buildings
Airside refers to:
• The Apron / manoeuvring areas
• Area within the airside boundary/perimeter fence, excluding the internal areas of the passenger
terminals, perimeter gatehouses and cargo buildings
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
66 of 86 Part C1.4: Insurance Schedule SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
SECTION B: INSURANCE CLAUSES
1. Insurance requirements for contracts with a value below R50million on the LANDSIDE
1.1 Contract Works
• With regards to contract works claims, the contractor/consultant is responsible for a deductible
(excess) of R250 000.
• Contractors / consultants may re-insure the deductible
1.2 Public Liability
• In the event of a claim against the contractor / consultant for 3rd party property damage the contractor
/ consultant will be responsible for a deductible (excess) of R275 000
• In the event of a claim against the contractor / consultant for removal of lateral support, the contractor
/ consultant will be responsible for a deductible (excess) of R500 000
• Contractors / consultants may re-insure the deductibles
1.3 Professional Indemnity
• All consultants are responsible for Professional Indemnity cover of R5million
• Contractors who have a material design element, excluding typical P & G related work, as part of their
scope, are responsible for Professional Indemnity cover of R5million
• In the event of a claim above R5million, the ACSA PI cover will kick in for the amount in excess of
R5m.
• Proof of cover in the form of a certificate of insurance should be provided to ACSA before a contract
is signed between ACSA and the contractor and/or consultant.
2. Insurance requirements for contracts below R50million on the AIRSIDE
2.1 Contract Works
• With regards to contract works claims, the contractor / consultant is responsible for a deductible
(excess) of R250 000.
• Contractors / consultants may re-insure the deductible
2.2 Public Liability
• In the event of a claim brought against the contractor / consultant for 3rd party property damage the
contractor / consultant will be responsible for a deductible (excess) of R525 000
• In the event of a claim brought against the contractor / consultant for removal of lateral support, the
contractor / consultant will be responsible for a deductible (excess) of R750 000
• In the event of a claim brought against the contractor / consultant for damage to aircraft, the contractor
/ consultant will be responsible for a deductible (excess) of R750 000
• Contractors / consultants may re-insure the deductibles
2.3 Professional Indemnity
• All consultants are responsible for Professional Indemnity cover of R5million
• Contractors who have a material design element, excluding typical P & G related work, as part of their
scope, are responsible for a Professional Indemnity cover of R5million.
• In the event of a claim above R5million, the ACSA PI cover will kick in for the amount in excess of
R5million.
• Proof of cover in the form of a certificate of insurance should be provided to ACSA before a contract
is signed between ACSA and the contractor and/or consultant.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
67 of 86 Part C2: Pricing Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Part C2: Pricing Data
C2.1 Pricing Instructions
Remuneration for Professional Services Remuneration for professional services will be on Activity Schedule as outlined in the document below. The pricing structure is as per the proposal submitted (RFP ref no. KIM 05/2017) by the Consultants.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
68 of 86 Part C2: Pricing Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
C2.2 Price Schedule Pricing structure per activity, as per the proposal submitted (RFP ref no. KIM 05/2017)
Item No
Program Stage Activity Description Price
1 Stage 1
Inception Report
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
2 Stage 2
Preliminary Design
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
3 Stage 3
Detail Design
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
4 Stage 4
Documentation and Procurement
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
5 Stage 5
Contract Administration and Inspection
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
69 of 86 Part C2: Pricing Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
6 Stage 6
Close-out
KIM: Water Tank and Supporting Systems R
KIM: Water Pipeline Reticulation Replacement R
ELS: Water Tank and Supporting Systems R
7 Disbursements Disbursements Provisional Sum include in total fees including health and safety
R
8 Permits Provisional Sum Airside Induction Training, Vehicle and personal Permits
R 5 000.00
9 Other 1: R
10 Other 2: R
11 Other: 3 R
Sub-Total 1 R
10% Contingency R
Total Fees (Excluding Vat) R
Vat R
*Total Fees (Including Vat) R
*This amount shall be carried over to form of offer Part C1.1
Cost Split per Airport: This is for information purposes only. The sum of the total cost for the
breakdown below should add up to the total project cost excluding contingency cost.
Airport Cost [R]
Total Cost for Kimberley Airport: Water Tank and Supporting Systems
Total Cost for Kimberley Airport: Water Pipeline Reticulation Replacement
Total Cost for East London Airport: Water Tank and Supporting Systems
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
70 of 86 Part C2: Pricing Data SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
DISBURSMENT SCHEDULE (a) Only project related costs listed below and presented to ACSA will be compensated by ACSA.
(b) Any disbursement costs related to travelling to and from the airport or accommodation for the purpose of
the project(s) is deemed to be inclusive in the agreed fee structure, unless otherwise agreed in writing by both parties. Disbursement costs not mentioned below (including under note (e)) may be brought to the attention of the ACSA project representative for approval and agreement on the recoverable amount, prior to incurring such cost.
(c) All rates are exclusive of VAT
(d) Health and Safety Agent will be recovered through Disbursements.
(e) No mark-up on any disbursement cost will be paid.
(f) No payment for disbursement will be made for the following:
- Travelling (except for on-site travelling) and accommodation - Typing of correspondence, payment certificates, variation orders, progress reports or financial reports - Telephone calls - Cellular calls - Computer costs - Telefaxes (outgoing or incoming) - Email (sent or received)
Above expenses by the Tenderer are deemed to be inclusive in their professional fees.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
71 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Part C3: Scope of work
C3.1: EMPLOYER’S SCOPE
Description of the services
Executive overview
In brief, the Consultant will be responsible for:
Developing a detailed design for the domestic water tank at Kimberley and East London Airport including piping
to connect to the existing water reticulation network that supplies the airport with domestic water. The design
should also cater for a booster pump station to allow for adequate supply of water to the terminal building and
the neighbouring areas. East London Airport has an existing domestic water tank with booster pump station,
however the tank capacity is not adequate to meet the water demand during water outages. Kimberley airport
is not equipped with a domestic water tank, domestic water is supplied by the municipal line directly to the
building
Developing a detailed design for the replacement of domestic water mainline reticulation at Kimberley airport.
The water reticulation pipeline shall be designed in conjunction with the domestic water tank design to allow
for a complete system.
The consultant will also be responsible for development of the tender documentation for the implementation
phase; contract administration and site inspection; and compilation of the close out report as more detailed in
the specifications below.
The design shall take into consideration the climate conditions in the different locations (i.e. corrosion
protection, use of corrosion resistant material, etc.), however standardisation in the designs shall be key.
Note: as built drawings are not available, identification and mapping of the current reticulation pipeline should
be taken into consideration when pricing.
Objectives: The objectives is to develop a detailed design for the replacement of the asbestos cement water reticulation
pipeline and development of a detail design for the domestic water tanks and supply systems at Kimberley and
east London airport.
The project shall be delivered in stages and the project stages are:
• Inception Report
• Preliminary Design
• Detailed Design
• Documentation
• Contract Administration and inspection
• Close-Out
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
72 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Specification and description of the services
The professional services are for designing of the domestic water tank and replacement of water mainline reticulation at East London and Kimberley airports. The scope of services will be divided into the following stages (the components are as per the Government Gazette No. 39480, 2015) :
Stage 1 Inception Report
(1) Assist in developing a clear project brief. (2) Attend project initiation meetings. (4) Advise on the rights, constraints, consents and approvals. (5) Define the services and scope of work required. (6) Conclude the terms of the agreement with the client. (7) Inspect the site and advise on the necessary surveys, analyses, tests and site or other investigations where such information will be required for Stage 2 including the availability and location of infrastructure and services. (8) Determine the availability of data, drawings and plans relating to the project. (9) Advise on criteria specific to own scope of work that could influence the project life cycle cost significantly. (10) Provide necessary information within the agreed scope of the project to other consultants involved. Deliverables for this phase will include:
• Agreed services and scope of work.
• Report on project, site and functional requirements.
• Schedule of required surveys, tests, analyses, site and other investigations.
• Schedule of consents and approvals and related lead times.
Stage 2 Preliminary Design
(1) Agreed documentation programme with consultant (2) Attend design and consultants’ meetings. (3) Establish the concept design criteria. (4) Prepare initial concept design and related documentation. (5) Advise the Employer regarding further surveys, analyses, tests and investigations which may be required. (6) Establish regulatory authorities’ requirements and incorporate into the design. (7) Refine and assess the concept design to ensure conformance with all regulatory requirements and consents. (8) Establish access, utilities, services and connections required for the design. (9) Coordinate design interfaces with other systems involved. (10) Prepare preliminary process designs, preliminary designs, and related documentation for approval by authorities and client and suitable for costing. (11) Provide cost estimates and comment on life cycle costs as required. (12) Liaise, co-operate and provide necessary information to the Employer, Deliverables for this phase will include:
• Concept design.
• Schedule of required surveys, tests and other investigations and related reports.
• Process design.
• Preliminary design.
• Cost estimates as required.
Stage 3: Detailed Design
(1) Review documentation programme with Employer (2) Attend design and consultants’ meetings. (3) Incorporate Employee’s and authorities’ detailed requirements into the design. (4) Incorporate other consultants’ designs and requirements into the design. (5) Prepare design development drawings including draft technical details and specifications.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
73 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
(6) Review and evaluate design and outline specification and exercise cost control. (7) Prepare detailed estimates of construction cost. (8) Liaise, co-operate and provide necessary information to the Employer (9) Submit the necessary design documentation to local and other authorities for approval. Deliverables for this phase will include:
• Design development drawings.
• Outline specifications.
• Local and other authority submission drawings and reports.
• Detailed estimates of construction costs.
Stage 4: Documentation
(1) Attend design and consultants’ meetings. (2) Prepare specifications and preambles for the works. (3) Accommodate services design. (4) Check cost estimates and adjust designs and documents if necessary to remain within budget. (5) Prepare documentation for contractor procurement. (6) Review designs, drawings and schedules for compliance with approved budget. (7) Call for tenders and/or negotiation of prices and/or assist the Employer where relevant. (8) Liaise, co-operate and provide necessary information to the Employer as required. (9) Assist in the evaluation of tenders. (10) Assess samples and products for compliance and design intent. Deliverables for this phase will include:
• Specifications.
• Services co-ordination.
• Working drawings.
• Budget construction cost.
• Tender documentation.
• Tender evaluation report.
• Tender recommendations.
• Priced contract documentation.
Stage 5: Contract Administration and inspection
(1) Attend site handover. (2) Issue construction documentation in accordance with the documentation schedule including, in the case of structural engineering, reinforcing bending schedules and detailing and specifications of structural steel sections and connections. (3) Carry out contract administration procedures in terms of the contract. (4) Prepare schedules of predicted cash flow. (5) Prepare pro-active estimates of proposed variations for client decision making. (6) Attend regular site, technical and progress meetings. (7) Review the Contractor’s quality control programme and advise and agree on a quality assurance plan. (8) Inspect the works for quality and conformity to contract documentation, on average once every 4 weeks during the course of the works as described in more detail in 3.3.2 for Level 1: periodic construction monitoring. (9) Review the outputs of quality assurance procedures and advise the contractor and Employer on the adequacy and need for additional controls, inspections and testing. (10) Adjudicate and resolve financial claims by contractor(s). (11) Assist in the resolution of contractual claims by the contractor. (12) Establish and maintain a financial control system. (13) Clarify details and descriptions during construction as required. (14) Prepare valuations for payment certificates to be issued by the principal agent. (15) Instruct witness and review all tests and mock ups carried out both on and off site. (16) Check and approve contractor drawings for design intent. (17) Update and issue drawings register.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
74 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
(18) Issue contract instructions as and when required. (19) Review and comment on operation and maintenance manuals, guarantee certificates and warranties. (20) Inspect the works and issue practical completion and defects lists. (21) Arrange for the delivery of all test certificates, statutory (regulatory) and other approvals, as built drawings and operating manuals Deliverables for this phase will include:
• Schedules of predicted cash flow.
• Construction documentation.
• Drawings register.
• Estimates for proposed variations.
• Contract instructions.
• Financial control reports.
• Valuations for payment certificates.
• Progressive and draft final account(s)
• Practical completion and defects list
• All statutory certification and certificates of compliance as required by the Local and
• other Statutory Authorities
Stage 6: Close-Out
(1) Inspect and verify the rectification of defects (2) Receive, comment and approve relevant payment valuations and completion certificates (3) Facilitate and/or procure final operations and maintenance manuals, guarantees and warranties. (4) Prepare and/or procure as-built drawings and documentation. (5) Conclude the final accounts where relevant. Deliverables for this phase will include:
• Valuations for payment certificates
• Works and final completion lists
• Operations and maintenance manuals, guarantees and warranties
• As-built drawings and documentation
• Final accounts
Design Specification/Standards
The below list should be used as a guide; however it is not exhaustive. The Consultant shall ensure compliance current and relevant industry standards and norms pertaining to the Works
• SANS 966 : Components of Pressure Pipe System
• SANS 241: Drinking Water Quality Programme
• ISO 9001:2008: Quality Management System
• OHS Act: Occupational Health &Safety Act 85 of 1993
Drawing requirements
All drawings shall bear accepted contract references using a project title block which is accepted by the Employer. Detailed revision blocks and drawing numbers are suffixed accordingly. All drawings, particularly layout drawings, submitted for acceptance shall be to a scale acceptable to the Employer. All drawings are to be made to scale and fully detailed and dimensioned. All dimensions marked on the drawings are to be considered correct, although measurements by scale may differ therefrom. The material from which each part is to be made shall be indicated. The drawings include tolerances for manufacture and installation. The tolerances are suitable and of sufficient accuracy to provide safe and trouble free construction and operation over the life of the component.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
75 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
All copies of drawings submitted to the Employer are to be provided in the form of 4 prints on white paper with black lines. The drawing size is A3 unless the use of another size is unavoidable. All native electronic format documents are also provided. All drawings shall be dimensioned in metric units unless the use of another unit is required and/or recommended, e.g. imperial sizes for flange holes, studs, etc. Where applicable, drawings shall show a graphic scale key plan and north arrow. Dates on drawings shall be reflected in the following format: dd/mm/ccyy. Revisions shall be designated R0, R1, R2, R3, etc., commencing with the first issue. All revisions shall be clearly described in the revision column bearing the revision number. All as-built and CAD data produced for this project adhere to the standards and requirements set out in the ACSA CAD Standards and ensure that throughout the project life a complete set of drawings is updated with “As-built” information in the required format. ACSA CAD Standards:
• Title block should clearly specify the project name & number; the status of the project, i.e. (Approval/ Construction/ As-builds) and the dates of any up-dating done in the drawing. The contractors/ consultants will be issued with the ACSA drawing Logo.
• Title block should clearly specify the consultants/ contractors working in the project; their contact details and physical address and also the responsibilities of the consultants/contractors. This will help with the tracking and tracing the project data if we might need in the future and for references.
• Line scale and line type must be clear.
• The components in the drawings should be in their own layers and we should be able to switch them on/off. They should be indicated on the plans specially and must have attribute data to identify them. This makes it easy to work on and extract only the specific layers needed.
• If XREF’s are used, they should be attached/ bind on the drawing.
• The text type and dimensions must be in ISO Standard and; also in their own layers.
• All As-built drawings should be issued in Auto-CAD; electronic format and in 3 X discs, accompanied by the drawing register.
• The issued As-built drawings, depending on the scope of the project should include: Services drawings; Architect drawings; Close out Reports and Certificates of compliance. Close out Reports and Certificates of compliance must be in pdf.
• At the hand over stage 3 X discs with as-built must be issued by the contractor/consultant to the ACSA project manager; who will then issue 1 X discs/CDs directly to the Assets Information Management Office/ GIS.
Please note that all service providers are requested to submit all As-built drawings to the CAD Office at the airports within 14 working days after the completion of the project. The As-builts must submitted in AutoCAD and PDF format; as indicated in the above points.
Design Software and Programmes/Methodologies to be utilised
AutoCAD,
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
76 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Constraints on how the Consultant Provides the Services.
Management meetings
To be able to manage the contract, the Employer and Consultants will have various meetings, to proactively and jointly manage and minimise adverse risks to the project. The attendees shall have the necessary delegated authority to make decisions in respect of matters discussed at such meetings. Regular meetings of a general nature may be convened and chaired by the Employer’s Agent as follows:
Title and purpose Approximate time & interval
Location Attendance by:
Risk register and compensation events
Monthly To be confirmed Employer’s Agent, Consultant
Overall contract progress and feedback
Monthly To be confirmed Employer’s Agent, Consultant
Meetings of a specialist nature may be convened as specified elsewhere in this Scope or if not so specified by persons and at times and locations to suit the Parties, the nature and the progress of the services. Records of these meetings shall be submitted to the Employer’s Agent by the person convening the meeting within five days of the meeting. All meetings shall be recorded using minutes or a register prepared and circulated by the person who convened the meeting. Such minutes or register shall not be used for the purpose of confirming actions or instructions under the contract as these shall be done separately by the person identified in the conditions of contract to carry out such actions or instructions.
Consultant’s key persons
The Consultant is required to nominate a senior partner or director who will have overall responsibility for this project and other senior personnel responsible for the execution of the project. No change may be made without prior consultation with and approval by the Employer. The Consultant is required to submit an organogram showing the key persons and their lines of authority / communication.
Work Plan
Objectives The project shall be done firstly in accordance with the Employer’s objective as per his appointed NEC Scope of Works Briefing with detail tasks and deliverables for each of the project stages, i.e. Scoping and Brief Stage, Preliminary Design Stage, Detail Design and Bid Stage, Working Drawing Stage and Construction Stage.
ISO Quality management System All projects shall be managed in accordance with strict ISO 9001 quality system ensuring quality in design, administration, reports and site administration. Consultants must be accredited with ISO9001 compliance and each project shall be administrated with respect to quality and technical compliance, in accordance with these strict international Quality Procedures.
Programme and monthly feedback A detailed programme for each project needs to be submitted within 14days of appointment and updated regularly/monthly.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
77 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Consultation and Client Feedback Detailed consultation with the designated ACSA representative and on-going feedback and reporting during feasibility preliminary design, detailed design and construction stages will be essential in delivering optimal and acceptable solutions which are in line with ACSA specifications and budget allocations. A monthly progress and cost report shall be done from detail design stage onwards till construction ends.
Understanding the Works The Employer is not responsible for the failure of the Consultant to understand the precise nature of his undertaking under this contract or for any erroneous interpretation concerning the conditions affecting his performance, it being recognized that the Employer provided the Consultant sufficient opportunity to ask the Employer for clarification of the terms and conditions of this contract prior to submission of his tender to provide the services.
Compliance with Laws The Consultant keeps himself fully informed of, and complies with all laws which apply to the Works and/or Services and/or to Providing the Works and/or Services (including laws which apply to persons employed to provide the Services and/or Works). “Laws” includes all national and provincial legislation, statutes ordinances and other laws and regulations and by-laws, orders and decrees of government or other legally constituted public authority and the common law.
Compliance with Codes & Standards The Services comply with the codes and standards stated in the Scope. To the extent not stated, the Services comply with internationally recognised codes and standards which are accepted by the Employer. In case of conflict between national, international codes, standards or guidelines and/or the requirements specified in this Scope, and unless otherwise instructed by the Employer, the more onerous one takes precedence; provided always that the Services comply as a minimum and in any event, with applicable law and mandatory South African national codes, standards and guidelines.
Environment, Health and safety
The Consultant shall at all times comply with the health and safety requirements prescribed by law as they may apply to the services.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
78 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
OCCUPATIONAL HEALTH AND SAFETY AGREEMENT
IN TERMS OF SECTION 37(2) OF THE OCCUPATIONAL HEALTH & SAFETY ACT (ACT 85 Of 1993) &
CONSTRUCTION REGULATION 5.1(k)
OBJECTIVES
To assist Airport Company South Africa (ACSA) to comply with the requirements of:
1. The Occupational Health & Safety (Act 85 of 1993) and its regulations and
2. The Compensation for Occupational Injuries & Diseases Act (Act 130 of 1993) also known as the (COID Act).
To this end an Agreement must be concluded before any contractor/ subcontracted work may
commence
The parties to this Agreement are:
Name of Organization:
AIRPORTS COMPANY SOUTH AFRICA SOC Limited
Physical Address:
Port Elizabeth International Airport
Administrator Office, Aeropark Office Complex Block A, 1st floor
Allister Miller Drive
Eastern Cape
6065
Hereinafter referred to as “Client”
Name of organisation:
Physical Address:
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
79 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
Hereinafter referred to as “the Mandatary/ Principal Contractor”
MANDATORY’S MAIN SCOPE OF WORK
To be completed by contractor
GENERAL INFORMATION FORMING PART OF THIS AGREEMENT
1. The Occupational Health & Safety Act comprises of SECTION 1-50 and all un-repealed REGULATIONS promulgated in terms of the former Machinery and Occupational Safety Act No.6 of 1983 as amended as well as other REGULATIONS which may be promulgated in terms of the Act and other relevant Acts pertaining to the job in hand.
2. “Mandatary” is defined as including as agent, a principal contractor or a contractor for work, but WITHOUT DEROGATING FROM HIS/HER STATUS IN HIS/HER RIGHT AS AN EMPLOYER or user of the plant
3. Section 37 of the Occupational Health & Safety Act potentially punishes Employers (PRINCIPAL CONTRACTOR) for unlawful acts or omissions of Mandataries (CONTRACTORS) save where a Written Agreement between the parties has been concluded containing arrangements and procedures to ensure compliance with the said Act BY THE MANDATARY.
4. All documents attached or refer to in the above Agreement form an integral part of the Agreement. 5. To perform in terms of this agreement Mandataries must be familiar and conversant with the
relevant provisions of the Occupational Health & Safety Act 85 of 1993 (OHS Act) and applicable Regulations.
6. Mandatories who utilize the services of their own Mandatories (contractors) must conclude a similar Written Agreement with them.
7. Be advised that this Agreement places the onus on the Mandatary to contact the CLIENT in the event of inability to perform as per this Agreement.
8. This Agreement shall be binding for all work the Mandatary undertakes for the client. 9. All documentation as per the Safety checklist including a copy of the written Construction Manager
appointment in terms of construction regulation 8, must be submitted 7 days before work commences.
THE UNDERTAKING
The Mandatary undertakes to comply with:
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
80 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
INSURANCE
1. The Mandatary warrants that all their employees and/or their contractor’s employees if any are covered in terms of the COID Act, which shall remain in force whilst any such employees are present on the Client’s premises. A letter is required prior commencing any work on site confirming that the Principal contractor or contractor is in good standing with the Compensation Fund or Licensed Insurer.
2. The Mandatary warrants that they are in possession of the following insurance cover, which cover shall remain in force whilst they and /or their employees are present on the Client’s premises, or which shall remain in force for that duration of their contractual relationship with the Client, whichever period is the longest.
• Public Liability Insurance Cover as required by the Subcontract Agreement.
• Any other Insurance cover that will adequately makes provision for any possible losses and/or claims arising from their and /or their Subcontractors and/or their respective employee’s acts and/or omissions on the Client’s premises.
COMPLIANCE WITH THE OCCUPATIONAL HEALTH &SAFETY ACT 85 OF 1993
The Mandatary undertakes to ensure that they and/or their subcontractors if any and/or their respective
employees will always comply with the following conditions:
1. All work performed by the Mandatary on the Client’s premises must be performed under the close supervision of the Mandatary’s employees who are to be trained to understand the hazards associated with any work that the Mandatary performs on the Client’s premises.
2. The Mandatary shall be assigned the responsibility in terms of Section 16(1) of the OHS Act 85 of 1993, if the Mandatary assigns any duty in terms of Section 16(2), a copy of such written assignment shall immediately be forwarded to the Client.
3. The Mandatary shall ensure that he/she familiarise himself/herself with the requirements of the OHS Act 85 of 1993 and that s/he and his/her employees and any of his subcontractors comply with the requirements.
4. The Mandatary shall ensure that a baseline risk assessment is performed by a competent person before commencement of any work in the Client’s premises. A baseline risk assessment document will include identification of hazards and risk, analysis and evaluation of the risks and hazards identified, a documented plan and safe work procedures to mitigate, reduce or control the risks identified, and a monitoring and review plan of the risks and hazards.
5. The Mandatary shall appoint competent persons who shall be trained on any Occupational Health & Safety aspect pertaining to them or to the work that is to be performed.
6. The Mandatary shall ensure that discipline regarding Occupational Health & Safety shall be strictly enforced.
7. Any personal protective equipment required shall be issued by the Mandatary to his/her employees and shall be worn at all times.
8. Written safe working practices/procedures and precautionary measures shall be made available and enforced and all employees shall be made conversant with the contents of these practises.
9. No unsafe equipment/machinery and/or articles shall be used by the Mandatary or contractor on the Client’s premises.
10. All incidents/accidents referred to in OHS Act shall be reported by the Mandatary to the Provincial Director: Department of Labour as well as to the Client.
11. No user shall be made by the Mandatary and/or their employees and or their subcontractors of
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
81 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
any of the Client’s machinery/article/substance/plant/personal protective equipment without prior written approval.
12. The Mandatary shall ensure that work for which the issuing of permit is required shall not be performed prior to the obtaining of a duty completed approved permit.
13. The Mandatary shall ensure that no alcohol or any other intoxicating substance shall be allowed on the Client’s premises. Anyone suspected to be under the influence of alcohol or any other intoxicating substance shall not be allowed on the premises. Anyone found on the premises suspected to be under the influence of alcohol or any other intoxicating substance shall be escorted off the said premises immediately.
14. Full participation by the Mandatary shall be given to the employees of the Client if and when they inquire into Occupational Health & Safety.
FURTHER UNDERTAKING
1. Only a duly authorised representative appointed in terms of Section 16.2 of the OHS Act is eligible to sign this agreement on behalf of the Mandatary. The signing power of this representative must be designated in writing by the Chief Executive Officer of the Mandatary. A copy of this letter must be made available to the Client.
2. The Mandatary confirms that he has been informed that he must report to the Client’s management, in writing anything he/she deems to be unhealthy and /or unsafe. He has versed his employees in this regard.
3. The Mandatary warrants that he/she shall not endanger the health & safety of the Client’s employees and other persons in any way whilst performing work on the Client’s premises.
4. The Mandatary understands that no work may commence on the Client’s premises until this procedure is duly completed, signed and received by the Client.
5. Non-compliance with any of the above clauses may lead to an immediate cancellation of the contract.
ACCEPTANCE BY MANDATARY
In terms of section 37(2) of the Occupational Health & Safety Act 85 of 1993 and section 5.1(k) of the
Construction Regulations 2014,
I, ……………………………………………………. (Identity Number: …………………..), a duly authorised
16.2 Appointee acting for and on behalf of ……………………………………. undertake to ensure that the
requirements and the provision of the OHS Act 85 of 1993 and its regulations are complied with.
Mandatary – WCA/ Federated Employers Mutual No……………………………….
Expiry date ………………………………………………………………………………
________________________________________ _______________
SIGNATURE ON BEHALF OF MANDATARY DATE
(Warrant his authority to sign)
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
82 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
_________________________________________ _______________
SIGNATURE ON BEHALF OF THE CLIENT DATE
AIRPORT COMPANY SOUTH AFRICA
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
83 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
ENVIRONMENTAL TERMS AND CONDITIONS TO COMMENCE WORK - EMS 048
The following Environmental Terms and Conditions shall be strictly adhered to by all contractors
when conducting works for ACSA. ACSA shall audit contractor activities, products and services on
an ad hoc basis to ensure compliance to these environmental conditions. Any pollution clean-up
costs shall be borne by the contractor.
ISSUE REQUIREMENT
Environment
al Policy
ACSA’s Environmental Policy shall be communicated, comprehended and
implemented by all ACSA appointed contractor staff.
Storm water,
Soil and
Groundwater
Pollution
• No solid or liquid material may be permitted to contaminate or potentially
contaminate storm water, soil or groundwater resources.
• Any pollution that risks contamination of these resources must be cleaned-
up immediately. Spills must be reported to ACSA immediately. Contractors
shall supply their own suitable clean-up materials where required.
• Washing, maintenance and refuelling of equipment shall only be allowed in
designated service areas on ACSA property. It is the contractor’s
responsibility to determine the location of these areas.
• No leaking equipment or vehicles shall be permitted on the airport.
Air Pollution
• Dust: Dust resulting from work activities that could cause a nuisance to
employees or the public shall be kept to a minimum.
• Odours and emissions: All practical measures shall be taken to reduce
unpleasant odours and emissions generated from work related activities.
• Fires: No open fires shall be permitted on site.
Noise
Pollution
• All reasonable measures shall be taken to minimize noise generated on site
due to work operations.
• The Contractor shall comply with the applicable regulations regarding noise.
Waste
Management
• Waste shall be separated as general or hazardous waste.
• General and hazardous waste shall be disposed of appropriately at a
permitted landfill site should recycling or re-use of waste not be feasible.
• Under no circumstances shall solid or liquid waste be dumped, buried or
burnt.
• Contractors shall maintain a tidy, litter free environment always in their work
area.
• Contractors must keep on file:
1. The name of the contracting waste company
2. Waste disposal site used
3. Monthly reports on quantities – separated into general, hazardous
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
84 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
and recycled
4. Maintained file of all Waste Manifest Documents and Certificates of
Safe Disposal
5. Copy of waste permit for disposal site
This information must be available during audits and inspections.
Handling &
Storage of
Hazardous
Chemical
Substances
(HCS)
• All HCS shall be clearly labelled, stored and handled in accordance to
Materials Safety Data Sheets.
• Materials Safety Data Sheets shall be stored with all HCS.
• All spillages of HCS must be cleaned-up immediately and disposed of as
hazardous waste. (HCS spillages must be reported to ACSA immediately).
• All contractors shall be adequately informed with regards to the handling
and storage of hazardous substances.
• Contractors shall comply with all relevant national, regional and local
legislation regarding the transport, storage, use and disposal of hazardous
substances.
Water and
Energy
Consumption
ACSA promotes the conservation of water and energy resources. The
contractor shall identify and manage those work activities that may result in
water and energy wastage.
Training &
Awareness
The conditions outlined in this permit shall be communicated to all contractors
and their employees prior to commencing works at the airport.
Penalties
Penalties shall be imposed by ACSA on Contractors who are found to be infringing these requirements
and/or legislation. The Contractor shall be advised in writing of the nature of the infringement and the
amount of the penalty. The Contractor shall take the necessary steps (e.g. training/remediation) to
prevent a recurrence of the infringement and shall advise ACSA accordingly.
The Contractor is also advised that the imposition of penalties does not replace any legal proceedings,
the Council, authorities, land owners and/or members of the public may institute against the Contractor.
Penalties shall be between R200 and R20 000, depending upon the severity of the infringement. The
decision on how much to impose will be made by ACSA’s Airport Environmental Management
Representative in consultation with the Airport Manager or his/her designate, and will be final. In
addition to the penalty, the Contractor shall be required to make good any damage caused due to the
infringement at his/her own expense.
AIRPORTS COMPANY SOUTH AFRICA SOC LIMITED
85 of 86 Part C3 : Scope of Work SCM Ref no.: KIM 05/2017 Project Number 3432-4411-4412
I, ……………………………………………………. of ……………………………………………………
agree to the above conditions and acknowledge ACSA’s right to impose penalties should I or any
of my employees or sub-contractors fail to comply with these conditions.
Signed: ___________________________ on this date: _______________________
(dd/mm/yyyy)
at: ………………………………………………...
Working on the Employer’s property
Work done on or near an active airport is subject to several special requirements and conditions to ensure the safe operation of the airport at all times. Various limitations and requirements are to be taken cognisance of during the preparation of the tender and construction programme. This work will be on the Landside and Airside area of the airport and the normal operations must be able to continue for the duration of the contract.
People restrictions, hours of work, conduct and records
The work under this contract is to be carried out under operational conditions of the airport and is therefore subject to several special requirements and conditions to ensure the safe operation of the airport at all times. The Consultant keeps records of his people working on the Employer’s property, including those of his Sub-consultants, and the Employer’s Agent shall have access to these records at any time.
Cooperating with and obtaining acceptance of Others
Whenever work being done by Others on the project is dependent on or adjacent or related to the Services, the interface and sequence of such works and the Services should be such that the least interference possible will result to the Consultant and to Others and such sequence is determined by the Employer. Cooperation is required between the Consultant and Others to ensure the completion of the Services and other project works within the programme for the project as a whole. As may be required from time to time or as per statutory requirements, the Consultant will liaise with and obtain acceptance from statutory authorities and avail themselves for any inspections that would be required. At the earliest possible date, detailed programmes prepared for all other project works having interfaces with the Services are discussed by the Employer with the Consultant in order that the phasing, duration, use of working areas, attendance work etc. can be drawn into overall programmes for the project works.
Things provided by the Employer
The Employer will issue to the Consultant available information that will assist in the carrying out of the services. This information may include Base plans to indicate existing services, Traffic Impact Assessments and other available information. The providing of this information does not relieve the Consultant of their professional responsibility to verify information that will be used as a basis for their designs.