Fidic 1992 Risk Clauses
-
Upload
sampath-bandara -
Category
Documents
-
view
224 -
download
1
Transcript of Fidic 1992 Risk Clauses
-
7/27/2019 Fidic 1992 Risk Clauses
1/8
1
FIDIC 4th
Edition 1987/1992 SOME OF THE IMPORTANT CONTRACT
CLAUSES, BOTH TERMS & CONDITIONS, WHICH HAVE ATTENDANT
RISKS FOR THE CONTRACTOR ARE OUTLINED HEREBELOW WITH MY
COMMENTS FOR YOUR REFERENCE.
Clause 2.1 Engineers Duties and Authority
The Contractor must ensure that the Engineer has obtained the specific
approval of the Employer before acting on any of the Engineers
requirements, say for additional works / variations, otherwise the
contractor runs the risk of not being paid for a disputed variation.
However in the event that an instruction is issued by the Engineer
which the Contractor believes to be a variation, but which is contested
by the Engineer, the contractor is duty bound to comply, but must
make his stand very clear that he considers the Engineers requirement
to be a variation involving time and cost and submit his claim inaccordance with clauses 44 or 53, otherwise he runs the risk of losing
his right to time and costs under the contract.
Clauses 2.2 Authority of the Engineers Representative
And 2.3 The Engineer may delegate to the Engineers Representative any of the
duties and authorities vested in the Engineer. The Contractor must
make sure that he receives a copy of such delegation, otherwise he runs
the risk that he will act in accordance with the Resident Engineers
instructions but without having appropriate recourse under the
contract.
Clause 2.5 Instructions in Writing
Any oral instruction issued by the Engineer must be confirmed within
7 days by the Contractor in writing to the Engineer, and such
confirmation must not be contradicted by the Engineer in writing
within 7 days, otherwise the Contractor runs the risk of not being able
to recover costs and / or time.
Clause 3.1 Assignment of Contract
The Contractor shall not, without the prior consent of the Employer,
assign the Contract or any part thereof, etc. otherwise the Contractor
runs the risk of being in breach of a main condition of the contract, andbeing terminated under clause 63.1.
Clause 4.1 Subcontracting
The Contractor shall not subcontract the whole of the Works, and in
addition shall not subcontract any part of the works without the prior
consent of the Engineer, failing which he risks termination under
clause 63.1.
Clause 6.3 Disruption of Progress
The Contractor must give Notice to the Engineer whenever planning or
execution of the Works is likely to be delayed or disrupted unless any
further drawing or instruction is issued by the Engineer within a
-
7/27/2019 Fidic 1992 Risk Clauses
2/8
2
reasonable time. Failure to give such notice may well place at risk the
Contractors entitlement for any requests for additional time and / or
costs.
Clause 7.3 Permanent Works Designed by Contractor
The Contractor remains liable for his design even if approved by theEngineer, and therefore runs the risk of any cost or delay arising from
any fault in the design to the extent that it is not covered by Insurance.
Clause 8.1 Contractors General Responsibilities
The Contractor shall provide all things necessary and shall execute and
complete the Works with due care and diligence, failure of which
render him liable to additional costs.
The Contractor has a duty to give prompt notice to the Engineer of any
error, fault, or other defect in the design of or Specification of the
Works which he discovers, otherwise he runs the risk of any resultant
additional costs or delays.Clause 8.2 Site Operations and Method of Construction
The Contractor shall take full responsibility (the risk) for the adequacy,
stability, and safety of all site operations and methods of construction.
Clause 10.1 Performance Security
This tends to be an on demand bond. The risk here is that an
unscrupulous Employer may well call upon the bond in circumstances
when he is not contractually entitled to do so, and the Contractor has
no remedy except to go to the Courts to try to stop the calling of the
bond, which is an extremely difficult task. This can be time consuming
and costly, with the added risk that if the Employer calls the bonds
when he is in financial difficulties, it will be too late if a year later the
Courts or Arbitrators decide that the calling of the bonds was wrongful,
at which stage, the Employer may have already gone into liquidation.
This is why it is important to contract with a reputable Employer. A
further risk here arises under clause 60.2, that in the event that the
Contractors performance security is delayed, the Engineer does not
have to certify any amount for payment whilst the performance
security is outstanding.
Clause 11.1 Inspection of SiteThe Contractor shall be deemed to have based his Tender on the data
made available by the Employer. The risk here is that if it is
established during the construction period that the information
provided by the Employer was incorrect, the Contractor will only be
able to seek recompense for time and cost if he can demonstrate to an
arbitral tribunal that it was not practicable for him to have carried out
during the tender period, having regard to considerations of cost and
time, the type of inspection and examination required to have
established the accuracy or otherwise of the information provided.
Clause 12.1 Sufficiency of Tender
-
7/27/2019 Fidic 1992 Risk Clauses
3/8
3
The Contractor runs the risk that his prices may not have taken into
consideration all his obligations under the Contract.
Clause 12.2 Not Foreseeable Physical Obstructions or Conditions
The Contractor must forthwith (immediately) give Notice to the
Engineer of any unforeseeable physical obstructions or conditions heencounters, failing which he runs the risk that his claim for time and
cost may not be entertained.
Clause 14.1 Programme to be Submitted
The Contractor must pay particular attention to the preparation of the
programme. Although the FIDIC conditions do not refer to the Critical
Path, most applications for an Extension of Time under Clause 44 do
refer to the impact of a delaying event on the critical path. Therefore
care must be taken to ensure that the programme covers the full
contractual period with the minimum of float, (zero float is preferable),
otherwise the Contractor will run the risk that he may not be able torecover time and cost for any delaying event for which otherwise he
would have been entitled, as the delay may be such as to take up only
part or all of the float.
Clauses 15.1 Contractors Superintendence and Employees
And 16.1 If the Contractor does not provide the necessary superintendence,
skilled technical assistants and the necessary level of skilled workforce,
the Contractor runs the risk of delays and losses.
Clause 17.1 Setting-out
If the Contractor does not carry out the setting out properly and with
the proper survey equipment, he runs the risk of having to remedy any
errors at his own cost.
Clause 19.1 Safety, Security, and Protection of the Environment
If the Contractor does not pay attention to safety and environmental
issues, he runs the risk of being subjected to fines imposed by the
Authorities, as well as stop work orders, either by the relevant
Authorities or by the Engineer.
Clause 20.1 Care of the Works
Clause 20.2 Responsibility to Rectify Loss or Damage
The Contractor carries the risk of caring for the Works, and for thematerials and plant for incorporating therein, to the extent that such
risks are not the Employers risks under clause 20.4, are not covered by
the exclusions and exceptions under clauses 21.4 and 22.2 respectively,
or are not covered under the insurance policies stipulated in clauses 21
through to 25.
Clause 20.4 Employers Risks
The Contractor retains the risk for any riot, commotion, or disorder
solely restricted to the Employees of the Contractor or of his
sub-contractors, for any loss or damage arising from any part of the
-
7/27/2019 Fidic 1992 Risk Clauses
4/8
4
works that have been designed by the Contractor, and for any operation
of the forces of nature that an experienced contractor could reasonably
have been expected to take precautions.
Clause 21.1 Insurance of Works and Contractors Equipment
The Contractor carries the risk for any excesses or deductiblesstipulated in the insurance policies for the items that are not covered in
clauses 20.4, 21.4, and 22.2.
Clause 22.1 Damage to Persons and Property
The Contractor carries the risk of indemnifying the Employer against
all losses and claims which are not included in the exceptions defined
in clause 22.2 and which are not covered by the insurance policies
stipulated in the Contract.
Clause 23.1 Third Party Insurance (including Employers Property)
Clause 23.2 Minimum Amount of Insurance
The Contractor carries the risk of liability for any amount over andabove the minimum amount stipulated in the Appendix to Tender as
well as any deductible stipulated in the insurance policy.
Clause 24.1 Accident or Injury to Workmen
Clause 24.2 Insurance Against Accident to Workmen
The Contractor carries the risk for any exclusions or deductibles
stipulated in the insurance policy.
Clause 25.2 Adequacy of Insurances
The Contractor carries the risk of inadequate insurance cover and
therefore additional costs in the event that there are significant changes
to the nature, extent, or programme for the execution of the Works and
he neglects to inform the insurers.
Clause 26.1 Compliance with Statutes, Regulations
The Contractor carries the risk of penalties and liability in the event
that he fails to conform in all respects with the rules, regulations,
statutes, ordinances, or other laws of duly constituted authorities,
public bodies, etc.
Clause 29.1 Interference with Traffic and Adjoining Properties
The Contractor carries the risk of liability arising from interfering
unnecessarily or improperly with the convenience of the public, oraccess to, use and occupation of roads / properties.
Clause 30.1 Avoidance of Damage to Roads
Clause 30.2 Transport of Contractors Equipment or Temporary Works
The Contractor is deemed to have priced the risk of damaging any
roads or bridges, or the cost of strengthening the same to avoid
damage.
Clause 32.1 Contractor to Keep Site Clear
-
7/27/2019 Fidic 1992 Risk Clauses
5/8
5
Failing which, the contractor runs the risk of being fined or having a
stop work order imposed on the site, in the event that the state of the
site constitutes a safety hazard.
Clause 36.4 Cost of Tests not Provided for
Clause 37.4 RejectionThe Contractor runs the risk of paying for additional tests required by
the Engineer in the event that the test results show that the materials,
plant, or workmanship are not in accordance with the provisions of the
Contract. Breach of Clause 37.4 further carries the risk of termination
under clause 63.1(c).
Clause 38.2 Uncovering and Making Openings
In the event that the Contractor covers up work in breach of clause
38.1, he runs the risk of having to pay for all costs arising from his
having to carry out any of the Engineers instructions in this regard,
such as uncovering the work, making openings, etc.Clause 39.1 Removal of Improper Work, Materials or Plant
Breach of this clause by the Contractor exposes him to a two fold risk.
The first is that the Contractor may have to pay for the costs of another
contractor brought in by the Employer to do this work (clause 39.2),
and the second, a much more serious risk, is termination under clause
63.1(c).
Clause 41.1 Commencement of Works
If the Contractor fails to commence the works without reasonable
excuse, he runs the risk of termination in accordance with clause
63.1(b)(i).
Clause 42.2 Failure to Give Possession
This would entitle the Contractor to Claim an Extension of Time for
completion under clause 44. However, the Contractor runs the risk that
the Engineer may not make a determination (he is not bound to) in
relation to the Contractors claim, in the event that the Contractor does
not give adequate notice under the provisions of clause 44.2.
Clause 44.2 Contractor to Provide Notification and Detailed Particulars
In the event that the Contractor fails to provide notification and
detailed particulars, the Contractor runs the risk that the Engineer maynot make a determination (the clause says the Engineer is not bound
to) in relation to the Contractors claim for an Extension of Time.
Clause 45.1 Restriction on Working Hours
The Contractor is to note that working nights or on public holidays,
runs the risk of disapproval by the Engineer, or of the local authorities
for noise pollution / disturbance.
Clause 46.1 Rate of Progress
If the Contractors rate of progress is slow, for issues that do not entitle
him to an extension of time, he runs the risk of either termination under
-
7/27/2019 Fidic 1992 Risk Clauses
6/8
6
Clause 63.1(b)(ii), or being asked to expedite the Works to comply
with the Time for Completion at his own cost.
Clause 47.1 Liquidated Damages for DelayIf the Contractor fails to comply with the Time for Completion, he runs
the risk of having liquidated damages levied against him, which
depending on the period of delay, can amount to as much as 10% of
the contract sum.
Clause 49.4 Contractors Failure to Carry Out Instructions
During the Defects Liability Period, the Contractor shall, within a
reasonable time, carry out any instructions of the Engineer to execute
any remedial works required as a result of faulty materials, plant or
workmanship, failing which he runs the risk of being liable to the
Employer of the costs of instructing another contractor to carry out thework.
Clause 51.1 Variations
The Contractor shall carry out any variations validly issued to him by
the Engineer under the Contract, which shall be valued at the rates and
prices set out in the Contract. The Contractor here runs the risk that if
his overhead and profit is not uniformly distributed throughout his
rates, the Employer / Engineer may decide to omit or vary a highly
priced item, or increase the quantities of a low priced item, resulting in
reduced profitability or loss for the Contractor.
Clause 52.2 Notice required for Variations
No varied work instructed to be done by the Engineer shall be valued
under sub-clauses 52.1 & 52.2 unless, within 14 days of the date of
such instruction and, other than in the case of omitted work, before the
commencement of the varied work, notice shall have been given of the
intention to claim extra payment or a varied price or rate. The
Contractor here runs the risk that if he does not give his notice as
required under the clause, he will not be able to claim for the varied
work.
Clause 53.4 Failure to ComplyTo successfully lodge a claim under the Contract, the Contractor must
give the required notices and detailed information required under
clauses 53.1, 53.2, and 53.3. Failing which, the Contractor runs the risk
of being paid an amount that will not exceed such amount as can be
verified by contemporary records.
Clause 54 Contractors Equipment, Temporary Works, and Materials
Although the Employer has an obligation to assist the Contractor in
importing his equipment and materials into the country, this remains at
the Contractors risk.
Clause 57.2 Breakdown of Lump Sum Items
-
7/27/2019 Fidic 1992 Risk Clauses
7/8
7
The Contractor runs the risk of any mistakes during his quantity take
off to arrive at any lump sum price items in the Contract.
Clause 59 Nominated Subcontractors
The concept of the Nominated Subcontractor arises from the
Employers desire to secure preferential rates from specialistsubcontractors. The latter are keener to offer more competitive prices
directly to the Employer either due to repeat business with or
guaranteed payments from the Employer.
The Contractors mark up onto the nominated subcontractors price for
co-ordination and attendance tends to be minimal varying from 2.5%
to 12.5%. This is normally not enough to cover his risk, for once he
has given his acceptance to the nomination, the Contractor becomes
fully liable for the performance of the nominated subcontractor to the
same extent that he is liable for his own domestic subcontractors
performance.The only advantage to the Contractor of such an arrangement is the
reduction in the payment risk as he does not have to pay the nominated
subcontractor until after the corresponding payment is received by the
Employer. However, this is becoming more and more a thing of the
past, as many jurisdictions have now outlawed pay when paid clauses
such as the United Kingdom, Australia, and Singapore, to name but a
few.
Clause 60.5 Statement at Completion
In his statement at completion, the Contractor must include all claims
on any matter arising out of or in connection with the Contract or
execution of the Works, otherwise he runs the risk of being barred
from raising these claims at any time in the future, unless such issues
arise after the date of the Statement of Completion.
Clause 60.10 Time for Payment
The General Conditions of Contract allow the Contractor two remedies
for delayed payments. Interest at the rate stated in the Appendix to
Tender, and the Contractors entitlement to slow down or suspend the
Works under clause 69. These rights are sometimes deleted in the
Conditions of Particular Application, with the Contractor running therisk of potentially damaging delays and costs as a result of payments
that are excessively and unduly delayed.
Clause 63.1 Default of Contractor
Many of the risks related to this clause have already been highlighted
earlier. Suffice it to say here that the Contractor must remain vigilant
and be aware of any notice issued to him under the Contract which
could lead to the invoking of this clause by the Engineer.
Clause 65.2 Special Risks
This refers to clause 20.4(b) and excludes rebellion, revolution,
insurrection, or military or usurped power, or civil war, unless they
-
7/27/2019 Fidic 1992 Risk Clauses
8/8
8
relate to the country in which the Works are to be executed. This
transfers the risk back on to the Contractor in a situation where he has
ordered materials from abroad and which are unavoidably delayed as a
result of any one of these risks taking place in the country of origin of
these materials.Clause 66.1 Release from Performance
If any circumstance outside the control of both parties arises after the
issue of the Letter of Acceptance which renders it impossible or
unlawful for either or both parties to fulfill his or their contractual
obligations, or under the law governing the Contract the parties are
released from further performance, then the Parties shall be discharged
from the Contract.
Clause 67.1 Engineers Decision
If the Contractor is not satisfied with the Engineers decision under thisclause he must give notice of his intention to commence arbitration
within 70 days of receiving such decision, otherwise the Engineers
decision becomes final and binding.
Clause 70 Changes in Cost and Legislation
The Contractors risk related to changes in costs either as a result of
price fluctuation or changes in legislation is transferred to the
Employer to the extent stated in the Conditions of Particular
Application.
Clause 71 Currency Restrictions
Clause 72 Rates of Exchange
The Contractors risk related to currency restrictions and changes in
the rates of exchange of a foreign currency where the Contract
provides that part or whole payment is made in that currency is
transferred to the Employer.