COIMBATORE CITY MUNICIPAL CORPORATION · PDF file7 IEC International Electro technical...

1

COIMBATORE CITY MUNICIPAL CORPORATION

Expression of Interest (EOI)

“Invitation for Expression of Interest (EOI)” from MNRE approved channel

partners for setting up of Solar PV Power Plant of capacity 50 KW connected to grid tied

at Main Office, Coimbatore Corporation, Coimbatore, Tamilnadu

The Commissioner, Coimbatore City Municipal Corporation, Coimbatore invites

Expression of Interest (EOI) from MNRE approved channel partners, who are in the field of

Supply, Erection, Commissioning and O & M of Solar Power plant Projects, for ‘’Engineering,

Procurement, Construction, Operation and Maintenance of 50 KW Solar Photovoltaic Grid tied

Connected Power Plant at the Main Office of Coimbatore City Municipal Corporation, Tamil

Nadu.

The bidder should submit the following documents along with EOI:

• Company profile along with audited financial statements for last three years

• Past experience of similar assignments (At least equal or larger projects) which include

the above proposed scope

• Performance and experience certificate from the clients of similar type of solar project.

• Proposed solar photovoltaic cells and its manufacturing facility

Last date of submission is 23 .10.2013 on the below mentioned address and mail:

Commissioner

Coimbatore City Municipal Corporation

Big Bazaar Street,

Coimbatore – 641 001.

E-mail: [email protected]

Coimbatore Corporation

Invitation for Expression of Interest (EOI) from MN RE

approved channel partners

Plant of capacity (

Office, Coimbatore Corporation


E

2



channel partners for setting up of Solar PV P

of capacity ( 50 KW) connected to grid tie

Coimbatore Corporation ,Coimbatore, Tamilnadu

Tender Ref:


Big Bazaar Street,

Coimbatore – 641 001.

Phone:+91-422 2396026

Fax:+91-422 2390167

E-mail: [email protected]

Website:www.ccmc.gov.in



for setting up of Solar PV P ower

grid tie d at Main

,Coimbatore, Tamilnadu

3

TABLE OF CONTENTS

Description Page No.

1. Introduction 10

2. Tender Data Sheet 10

3. Tender Eligibility Criteria 11

4. Instructions to the Bidder 14

4.1 General Instructions 15

4.2 Language of the Bids 15

4.3 Bid Currency 16

4.4 Letter of Authorization 16

4.5 Clarifications and Amendments 16

4.6 Contacting Tender Inviting Authority 17

4.7 Force Majeure. 17

4.8 Arbitration 17

5. Tender Cost and EMD 18

5.1 Cost of Bidding 18

5.2 Tender Document Fee 18

5.3 Earnest Money Deposit (EMD) 18

6. Bid Preparation and Submission 20

6.1 Techno Commercial Bid (Envelope-A) 20

6.1.1 Bid Preparation 20

6.1.2 Details to be furnished in the Techno Commercial Bid 20

6.1.3 Signing the Techno Commercial Bid 21

6.1.4 Sealing the Techno Commercial Bid 21

6.2 Price Bid (Envelope-B) 22

6.2.1 Details to be furnished 22

6.2.2 Signing the Price Bids 22

6.2.3 Sealing the Price Bid 22

6.3 Outer Cover 23

6.4 Mode of submission of Bids 23

6.5 Modification and withdrawal of Bid 23

7. Bid opening 24

4

7.1 Techno Commercial Bid Opening 24

7.2 Tender Validity 24

7.3 Initial Scrutiny 24

7.4 Clarifications by CCMC 25

7.5 Price Bid Opening 25

8. Tender Evaluation and Selection 25

8.1 Suppression of facts and misleading information 25

8.2 Techno Commercial Bid Evaluation 26

8.3 Price Bid Evaluation 26

8.4 CCMC reserves the right to 27

9. Award of work 27

9.1 Acceptance of the Tender 27

9.2 Letter of Acceptance (LOA) 27

9.3 Payment of Security Deposit (SD) 28

9.4 Execution of Agreement 28

9.5 Release of Firm Work Order 28

9.6 Installation & Completion Schedule 29

9.7 Refund of EMD 29

9.8 Termination of Contract 29

9.8.1 Termination of default 29

9.8.2 Termination for insolvency 30

9.8.3 Termination for convenience 30

10. Execution of Work

10.1 Scope of work

30

10.2 Insurance 31

10.3 Handing Over 31

10.4 Comprehensive Maintenance 31

11. Liquidated Damages 32

12 Warranty 32

13 Pre- Despatch Inspection

33

13.1 Components manufactured in India 33

5

13.2 Components Manufactured Abroad

34

14.Product Take Back & Recycling

34

15. Traceability of the product to be supplied

35

16. Payment Terms

35 & 36

17. Technical Specification 37

18. Technical Requirements/Standards 39

Techno Commercial Bid (Envelope – A) 39

A 1.1 Profile of the Bidder 39

A 1.2 EMD amount 39

A 1.3 Furnished details for meeting the Eligibility Criteria 45

A 1.4 Technical Bid for SPV Power plants 47

Appendix -1 Bidder’s undertaking covering letter 49

Appendix -2 Model Form of Contract 52

Appendix -3 Bank Guarantee Format 60

Appendix -4 Performance Certificate 62

Appendix -5 Draft Undertaking in Lieu of EMD 63

Appendix -6 Accredited Test Centres for MNRE Off-Grid tie

Programme

65

Price Bid (Envelope B) 67

6

ACRONYMS

S.No Parameter Details

1 AC Alternating Current

2 BIS Bureau of Indian Standard

3 BOS Balance Of System

4 FF Fill Factor

5 GI Galvanised Iron

6 HDPE High Density Poly Ethylene

7 IEC International Electro technical Commission

8 IECQ IEC Quality Assessment for Electronic

components

9 MCB Miniature Circuit Breaker

10 MCCB Moulded Case Circuit Breaker

11 MOV Metal Oxide Varistor

12 MPPT Maximum Power Point Tracking

13 NABL National Accreditation Board for testing and

calibration Laboratories

14 PCU Power Conditioning Unit

15 PSC Pre Stressed Concrete

16 PVC Poly Vinyl Chloride

17 RFID Radio Frequency Identification

18 SEC Solar Energy Centre

19 SPV Solar Photo Voltaic

20 SS Stainless Steel

21 STC Standard Testing Conditions

22 TAC Tender Acceptance Committee

23 CCMC Coimbatore City Municipal Corporation

24 TEDA Tamil Nadu Energy Development Agency

7

Short Titles used in the Tender Document

1. Bidder Bidder means the party who makes a formal offer in

pursuance of the Tender floated

2. Successful Bidder Successful Bidder means the Bidder who becomes

successful through the Tender process.

3. Day A day means a calendar day

4. Cost Cost means the total cost to be incurred towards the

supply, installation, commissioning, testing and 5 year

comprehensive maintenance of SPV power plants

5. Purchaser Purchaser means the Government of Tamil Nadu

(Coimbatore city municipal corporation) for whom the

procurement is made through this Tender.

6. CCMC Procurement agency

7. Commissioning Commissioning means the energization of SPV power

plants and the testing of functioning of the system.

8. End user End user means the main office in whose land or site

the solar power plant is installed

Applicability of Tamil Nadu Transparency in Tenders Act 1998

This Tender process will be governed by The Tamil Nadu Transparency in Tenders Act

1998 , The Tamil Nadu Transparency in Tenders Rules 2000

(http://www.tn.gov.in/gorders/fin446-e.htm) and MNRE Rules as amended from time to time.

8

Checklist for Enclosures (Bidder should fill up the page no without fail)

Bid

Enclosures

Page No

1 Whether the Tender is submitted in Two covers Technical Bid and Price Bid?

2 Whether Two covers along with EMD cover are put into an outer cover?

3 Whether Technical Bid (Envelope - A) contains the following

3.1 Bidder’s undertaking covering letter in the Letter Head shall be signed by the

authority, stamped and submitted.

3.2 Signed and stamped Letter of Authorization or Power of Attorney for signing the

Tender document shall be submitted(if the Power of Attorney has been

appointed)

3.3 Bidder’s undertaking in the Letter Head for minimum quantity offered shall be

signed and stamped and submitted.

3.4 All pages of the blank Tender document in full shall be signed by the authority,

stamped and submitted

3.5 Earnest Money Deposit (EMD) amount as specified in the Tender shall be

submitted

3.6 Filled up Technical Bid shall be signed by the authority, stamped and submitted

3.7 All supporting documents for proving the Eligibility Criteria shall be signed by

the authority and stamped in all pages (the documents should be bonded

properly with yarn consisting table of contents along page number)

3.8 Supporting documents to meet the Eligibility Criter ia

a) All the supporting documents to meet the Eligibility Criteria as laid down in the Tender

under Eligibility Criteria shall be signed by the authority and stamped

b) Bidder’s Certificate of Incorporation

c) Relevant Excise duty returns or Sales Tax Returns for the components manufactured shall

be submitted

d) Annual Report including Balance Sheet and Profit & Loss accounts for the past three years

should be submitted.

e) For component (s) manufacturing capacity, copy of the Manufacturing License or any valid

proof for manufacturing should be submitted.

9

f) Clientele list for the SPV power on line plant installed in last five years along with

satisfactory performance certificate.

g) Bidder’s undertaking letter to meet the Blacklisting criteria shall be submitted

h) The bidder’s name has been included in the list of channel partners accredited by the

Ministry and Decentralized Solar Applications under JNNSM as on march 2013, Ministry

of New and Renewable Energy,GOI

i)The bidder should have minimum 5 years experience in the SPV power plant installation,

operation and maintenance project in the any government organization of GOTN or GOI or

parastatal department besides the relevant work ‘s performance and satisfactory certificate

also have to be submitted

3.9 Test report or Certificate for the SPV power pl ant from MNRE approved lab oratories

i. SPV Modules

a) IEC 61215 or IS 14286 for Crystalline Modules or IEC 62108 for Concentrator PV modules

& Assemblies

b) IEC 61730 Part 1 & 2/ Equivalent IS(under Dev.)

c) IEC 61701/IS 61701

d) STC performance certificate

ii. Junction Boxes or Enclosures of Inverters - IP 21 ( for indoor)as per IEC 529

iii . Power Conditioner/Inverter including MPPT & Prote ctions – IEC 61683/IS 61683 &

IEC 60068-2(1,2,14,30)/Equivalent BIS Std

iv. Cables – IEC 60227/IS 694 , IEC 60502/ IS 1554 (pt.I & II)

v. Switches/Circuit Breakers/Connectors - IEC 60947 Part I , II ,III / IS 60947 part I,II,III ,

EN 50521

4. Whether Price Bid (Envelope -B) contains the following

a) Filled Price Bid with signature and stamp in all pages shall be submitted (including all taxes)

b) Whether corrections or overwriting if any is attested?

IMPORTANT NOTE:

Bidders must ensure that they submit all the required documents indicated in the Tender

document without fail. Bids received without supporting documents for the various

10

requirements mentioned in the tender document or test certificate are liable to be rejected at

the initial stage itself. The data sheet for the critical components should be submitted by the

Bidder for the scrutiny.

1. Introduction

Now it is proposed to call for Invitation for Expression of Interest (EOI) from MNRE

approved channel partners for setting up of Solar PV Power Plant of capacity 50 KW

connected to grid tie through competitive bidding process, following the procedures

stipulated in the Tamil Nadu Transparency in Tenders Act 1998 and Tenders Rules 2000

and MNRE Rules.

Bidder may quote and supply & commission within 90 days after delivered the LOA by

postal or Email.

The Successful Bidder(s) should work closely with the Government of Tamil Nadu departments involved in implementing the above work and ensure success of the programme within the stipulated time.

2. Tender Data Sheet

1. Tender inviting Authority, Designation

and Address

The Commissioner, Coimbatore City

Municipal Corporation, Big Bazaar Street,

Coimbatore

2. a) Name of the Work Invitation for Expression of Interest (EOI)

from MNRE approved channel partners for

setting up of Solar PV Power Plant of

capacity 50 KW connected to grid tie at main

Office of the Coimbatore Corporation

b) Tender Reference Tender Notice No:15792/2008/MD3 (Solar-

EOI)

c) Place of execution At main Office of the Coimbatore

Corporation

3. a) Tender documents available place

and due date for obtaining tender

On all working days between 11.00 A.M. and

5.00 P.M. IST from 20.09.2013 to

23.10.2013 from the Address mentioned in

column (1) above. Alternatively, Tender

11

documents can be downloaded free of cost

from the Corporation web site

b) Cost of Tender Document Rs. 16,890/-(Rupees Sixteen Thousand

Eight Humdred and Ninety

only) per Tender Document for direct

purchase from CCMC. The Tender

document fee is waived for the downloaded

Tender Document

4. Earnest Money Deposit (EMD) EMD Rs.70,000/- has to be paid by way of

Demand Draft or Banker’s Cheque drawn in

favour of “The Commissioner,Coimbatore

city municipal corporation” and payable at

Coimbatore only

5. Pre – Bid Meeting

04.10.2013, 4.00 P.M

6. Due Date, Time and Place of

submission of Tender

23-10-2013, 3.00 P.M,

Commissioner


Big Bazaar Street,

Coimbatore – 641 001

7. Date, Time and Place of Tender

opening

23-10-2013, 4.00 P.M JNNURM Conference

Hall, Coimbatore Corporation

8. Date, Time and Place of opening of

Price Bids

Will be intimated only to the bidders qualified

in Techno commercial bid.

3. Tender Eligibility Criteria

The Bidder(s) should meet the following Eligibility Criteria to participate in the Tender

and should enclose documentary proof for fulfilling the Eligibility in the Techno

commercial Bid.

S.No Minimum Eligibility Criteria Proof to be submitted for

fulfilling the Eligibility Criteria

12

1. a) Bidder shall be a Registered

Company in existence for at least the

past three audited year.

Certificate of Incorporation or

Registration of the bidder shall be

submitted.

b) Consortium not exceeding three partners.

Each partner of the Consortium should be a

Registered Company in existence for at least

past three audited year.

i. Certificate of Incorporation or

Registration of all the partners

shall be submitted.

ii. Copy of consortium agreement

shall be submitted (OR) A letter of

intent to execute a consortium

agreement in the event of a

successful bid shall be signed by

all the partners and submitted with

the Bid together with the copy of

the proposed consortium

Agreement.

iii. In case of Consortium, all

partners of the consortium shall

be liable jointly and severally for

the execution of the contract in

accordance to the contract terms

and a statement to this effect shall

be included in the letter of intent.

2. The Bidder shall use only SPV

modules manufactured in India

Necessary Self undertaking letter

shall be submitted

3. Bidder or Consortium shall have a

a. minimum turnover of Rs. 1.25Cr in

any one of the three audited years

from 2008-09.

Turnover of Parent Company is

a) Annual Report

b) Balance Sheet &

c) Profit & Loss accounts

13

allowed

b. minimum turnover of Rs. 1 Cr in PV

field in the last financial year(or in the

current financial year)

for any three audited years from

2008-09 shall be submitted

towards meeting annual turnover

criteria.

Documentary evidence for

minimum of 1 Cr annual turnover

in PV field for the last financial

year (or in the current financial

year) shall be submitted.

4. Bidder should have installed a

minimum of 10 Nos. SPV power plant

of capacity 50KWp and above in the

last five years (50KWp power plant

installed minimum 6 months prior to

the date of bid submission will only be

considered ) & these systems should

be working satisfactorily.

Copy of Work Orders and

performance certificate for

satisfactory function of power

plants obtained from the agency

issuing work order

5. Various components such as PV

Modules, PCU & Battery of the SPV

system shall conform to the MNRE

standards as per clause “15”

Copy of test certificates along with

reports for each component shall

be submitted.

6. Bidder should not be currently

blacklisted by any of the State or

Central Government or organizations

of the State or Central Government as

on date of submission of tender

Necessary Undertaking letter

should be furnished.

7 The bidder’s name has been included in

the list of channel partners accredited

by the Ministry for On line-Grid tie and

Decentralized Solar Applications under

JNNSM as on march 2013, Ministry of

Empanelled list of MNRE should

be furnished

14

New and Renewable Energy,GOI

8 The bidder should have minimum 5

years experience in the SPV power

plant installation, operation and

maintenance project in the any

government organization of GOTN or

GOI or parastatal department

The relevant work ‘s

performance and satisfactory

certificate have to be submitted

9 Technical team have to be engaged

for O&M of plant

Proposed staff pattern should be

submitted along

name.designation, experience

Special Conditions for the Consortium

1) In case of consortium, it would be sufficient if the prime bidder makes the remittance of

the cost of bid document.

2) In case of a successful Bid, the Agreement shall be signed by the Prime Bidder so as to

be legally binding on all the partners.

3) The Prime Bidder shall be authorized by the Consortium partners to act on their behalf to

incur liabilities and receive instructions for and on behalf of him and all partners of the

consortium and entire execution of the contract including payment shall be done exclusively

to the Prime Bidder.

4) All partners of the consortium shall be liable jointly and severally for the execution of the

contract in accordance to the contract terms and a statement to this effect shall be included

in the authorization mentioned above as well as in the Bid and in the agreement (in case of

successful bid). The consortium agreement should indicate precisely the role of the

members of the consortium in respect of the contract.

5) Copy of the consortium agreement shall be submitted with the Bid. Consortium

agreement should be registered in India.

6) Alternatively a letter of intent to execute a consortium agreement in the event of a

successful bid shall be signed by all the partners and submitted with the bid together with

the copy of the proposed agreement

15

The consortium agreement should be registered before execution of agreement with CCMC

so as to be legally valid and binding on all partners.

7) Only one Bid will be allowed from a Consortium. The partners of a Consortium are not

allowed to bid individually or to be the partner of another Consortium.

4. Instructions to the Bidder

4.1 General Instructions

a) It will be imperative for each Bidder(s) to familiarize himself or themselves with the

prevailing legal situations for the execution of contract. CCMC shall not entertain any

request for clarification from the Bidder regarding such legal aspects of submission of the

Bids

b) It will be the responsibility of the Bidder that all factors have been investigated and

considered while submitting the Bids and no claim whatsoever including those of financial

adjustments to the contract awarded under this tender will be entertained by CCMC. Neither

any time schedule nor financial adjustments arising thereof shall be permitted on account of

failure by the Bidder to apprise themselves.

c) The Bidder shall be deemed to have satisfied him or herself fully before Bidding as to the

correctness and sufficiency of its Bids for the contract and price quoted in the Bid to cover

all obligations under this Tender.

d) It must be clearly understood that the Terms and Conditions and specifications are

intended to be strictly enforced. No escalation of cost in the Tender by the Bidder will be

permitted throughout the period of Agreement or throughout the period of completion of

contract whichever is later on account of any reasons whatsoever.

e) The Bidder shall make all arrangements as part of the contract for Supply, Installation,

Commissioning, Testing and 10 years Comprehensive Maintenance of SPV power plant

and train the personnel at their own cost. And they should have maintain the power plant 10

years in their own after that sufficient technical supports should be given to the department

to the life time of plant

f) The Bidder should be fully and completely responsible to CCMC for all the deliveries and

deliverables. The bidder shall be responsible for the proper functioning of the finally erected

systems.

g) Sufficient technical staff should be engaged as per the norms of GOI,GOTN

16

h) The plant should be designed and installed in view of further 25 years power requirement

in that campus.

4.2 Language of the Bids

The bid prepared by the Bidder as well as all correspondence and documents relating to the

bid shall be in English only. The supporting documents and printed literature furnished by

the Bidder may be in any another language provided they are accompanied by an accurate

translation in English duly notarized, in which case, for all purposes of the Bid, the

translation shall govern. Bids received without such translation copy will be rejected.

4.3 Bid Currency

Price should be quoted in Indian Rupees (INR) only and Payment shall be made in Indian

Rupees only. Price quoted in any currency other than INR will be rejected.

4.4 Letter of Authorization

A letter of Authorization from the Board of Directors or Managing Director of Bidder

organization authorizing the Tender submitting authority should be submitted in the Techno

commercial Bid. The Bids received without the Letter of Authorization or Power of Attorney

will be summarily rejected.

4.5 Clarifications and Amendments

a) A prospective Bidder requiring any clarification in the Tender may address CCMC by

Registered post or by personal delivery under acknowledgement. No clarifications will be

offered by CCMC within 7 days prior to the time of opening of the Tender.

b) Before the closing date of the Tender, clarifications and amendments, if any, will be

notified in the government website mentioned in the Tender Data sheet. The Bidders should

periodically check for the amendments or corrigendum or information in the website till the

closing date of this Tender. CCMC will make individual communication by email to only

those bidders who have purchased the tender document from the office of CCMC. CCMC

will not make any individual communication to others and will in no way be responsible for

any ignorance pleaded by Bidders.

17

c) CCMC is not responsible for any misinterpretation of the provisions of this tender

document on account of the Bidders failure to update the Bid documents based on changes

announced through individual communication or website as the case may be.

4.6 Contacting Tender Inviting Authority

a) Bidders shall not make attempts to establish unsolicited and unauthorized contact with

the Tender Inviting Authority or Tender Scrutiny Committee or Tender Accepting Authority

after the opening of the Tender and prior to the notification of the Award and any attempt by

any Bidder to bring to bear extraneous pressures on the Tender Inviting or Scrutiny or

Accepting Authority may lead to disqualification of the Bidder.

b) Notwithstanding anything mentioned above, the Tender Inviting or Scrutiny or Accepting

Authority may seek bona-fide clarifications from Bidders relating to the tenders submitted by

them during the evaluation of tenders.

4.7 Force Majeure

Neither CCMC nor the Successful Bidder shall be liable to the other for any delay or failure

in the performance of their respective obligations due to causes or contingencies beyond

their reasonable control such as:

� Natural phenomena including but not limited to earthquakes, floods and epidemics.

� Acts of any Government authority, domestic or foreign including but not limited to war

declared or undeclared, priorities and quarantine restrictions.

� Accidents or disruptions including, but not limited to fire, explosions, breakdown of

essential machinery or equipment.

4.8 Arbitration

In case of any dispute, the matter will be referred to a sole Arbitrator to be appointed by

CCMC under the “Arbitration and Conciliation Act 1996”. The arbitration shall be held in

Chennai (INDIA) and the language shall be English only. Subject to the above, the Courts at

Chennai alone only shall have jurisdiction in the matter.

5. Tender Cost and EMD

18

5.1 Cost of Bidding

The Bidders should bear all costs associated with the preparation and submission of Bids.

CCMC will in no way be responsible or liable for these charges or costs incurred regardless

of the conduct or outcome of the bidding process.

5.2 Tender Document Fee

a) The Tender documents may also be purchased from the office of CCMC on payment of

fees in Indian Rupees as mentioned in the Tender Data sheet. The Tender document is not

transferable to any other Bidder.

b) The Tender document cost may be paid by way of Demand Draft or Banker’s Cheque in

favour of “The Commissioner, Coimbatore City Municipal Corporation, Coimbatore”,

payable at Coimbatore.

c) Alternatively, the Tender document can be downloaded free of cost from the website

mentioned in the Tender data sheet.

d)Along with the final bid the bidder shall invariably furnish necessary bank guarantee

towards 30% of the value of the bid with guarantee period of five years which will be

released soon after the receipt of 30% subsidy either though the TEDA or directly from the

MNRE

3 Earnest Money Deposit (EMD)

a) An EMD amount as specified in the Tender should be paid in Indian Rupees by way of

Demand Draft or Banker’s cheque only, obtained from any of the Nationalized or Scheduled

banks, drawn in favour of “The Commissioner, Coimbatore city municipal corporation,

coimbatore” payable at Coimbatore. EMD submitted in any other forms will be SUMMARILY

REJECTED.

b) The EMD amount of the bidders not qualified in the Techno commercial bid will be

refunded within a reasonable time. The EMD amount held by CCMC till it is refunded to the

unsuccessful Bidders will not earn any interest thereof.

c) The EMD amount paid by the Successful Bidder(s) will be adjusted towards Security

Deposit payable by them. If the successful Bidder submits Security Deposit for the

stipulated value in full in the form of DD or by way of Bank Guarantee in favour of “The

Commissioner, Coimbatore City Municipal Corporation, Coimbatore” the EMD will be

refunded.

19

d) The EMD amount will be forfeited by CCMC , if the Bidder withdraws the bid during the

period of its validity specified in the tender or if the successful Bidder fails to sign the

contract or the successful Bidder fails to remit Security Deposit within the respective due

dates.

e) The bids received without the specified EMD amount will be SUMMARILY

REJECTED.

f) The following categories of industries are exempted from payment of Earnest Money

Deposit.

i) The Small Scale Industrial units located within the State and Registered with the Tamil

Nadu Small Industries Development Corporation.

ii) The Small Scale Industrial units located within the State and Registered with National

Small Industries Corporation (NSIC).

iii) The SSI units holding Permanent Registration certificate from the District Industries

Centres of Directorate of Industries and Commerce in respect of those items for which the

Registration Certificate has been obtained.

iv) Undertakings and Corporations owned by Government of Tamil Nadu.

v) Small Scale Industrial units located outside the State but registered with National Small

Industries Corporation (NSIC) in respect of the items manufactured by them.

g) Industries exempted from payment of EMD shall enclose duly attested Photostat copies

of their Registration Certificate showing the subject materials specifying capacity which they

are permitted to manufacture and the period of validity of the certificate and the related G.O

as proof of eligibility for exemption from payment of EMD.

h) Those Bidders who are exempted from payment of E.M.D, shall furnish in lieu of EMD an

under taking in a non-judicial stamp paper of value not less than Rs. 80.00/- (Rupees Eighty

only) in the prescribed format, as per Appendix- 5 to the effect to pay penalty an amount

equivalent to EMD in the event of non-fulfillment or non-observance of any of the conditions

stipulated in the contract consequent to such breach of contract.

20

i) Undertaking and proof of exemption of EMD shall be kept in the EMD cover as specified

in clause 6.3 . TENDERS RECEIVED WITHOUT PROOF FOR EXEMPTION OF EMD AND

UNDERTAKING WILL NOT BE READOUT AND WILL BE REJECTED SUMMARILY.

6. Bid Preparation and Submission

Bidders should examine all Instructions, Terms and Conditions and Technical specifications

as given in the Tender documents. Failure to furnish information required by the Bid or

submission of Bids not substantially responsive or viable in every respect will be at the

Bidders’ risk and may result in rejection of Bids. Bidders should strictly submit the Bid as

specified in the Tender, failing which the bids will be held as non-responsive and will be

rejected.

The Bids should be submitted separately in two parts namely viz. (1) Techno commercial

Bid and (2) Price Bid . The Techno commercial Bid and Price Bid shall be submitted in two

separate covers.

6.1 Techno commercial Bid (Envelope-A)

6.1.1 Bid Preparation

a) The Techno commercial Bid enables CCMC to evaluate whether the Bidder is techno

commercially competent and capable of executing the order. Only those Bids which qualify

in the Techno commercial stage will be eligible for the Price bid opening. The Price Bid of

Bidders who failed in the Techno commercial stage will not be opened and the bid of the

particulars will be recorded.

b) The Techno commercial Bid format as given in the Tender shall be filled, signed and

stamped in all pages. CCMC will not be responsible for the errors committed in the Bids by

the Bidders.

c) The Techno commercial Bid should strictly not contain any Price indications or otherwise

the Bids will be summarily rejected.

6.1.2 Details to be furnished in the Techno Commerc ial Bid

a) The EMD amount should be submitted in the prescribed form Authorization letter from

the Board of Directors or Chairman & Managing Director or Power of Attorney to sign the

Tender documents should be submitted.

21

The Tenders received without Authorization letter or Power of Attorney will not be

considered for further processing.

b) The blank Tender document in full should be printed, signed by the authorized person

and stamped in all pages and should be submitted as a token of accepting the conditions.

c) The Techno Commercial Bid should be duly filled, signed by the authorized person and

stamped in all the pages and should be submitted.

d) The supporting documents to prove Bidder’s eligibility should be duly attested and should

be submitted.

e) Valid Test certificates along with test reports shall be submitted for components or

systems from notified testing agencies as per “clause 15”.

f) The published Annual Report should be signed by the authorized person and stamped in

all pages and should be submitted.

g) The bidder should indicate the manufacturing plant addresses.

h) All the required documents insisted in the Tender should be enclosed in the Techno

Commercial Bid. No document would be allowed to be supplemented or exchanged after

opening of the bids.

i) The documentary evidence shall establish Bidder’s qualifications to the satisfaction of

CCMC.

6.1.3 Signing the Techno Commercial Bid

a) The Bids shall be typed and shall be signed by the Authorized official of Bidder. All pages

of the bid shall be signed and stamped by the authorized person

b) Any alterations, deletions or overwriting will be treated as valid only if they are attested by

the full signature by the authorized person.

6.1.4 Sealing the Techno Commercial Bid

The Techno Commercial bid shall be placed in a sepa rate cover (Envelope-A) and

sealed appropriately. The Techno Commercial bid cov er shall be super scribed with

“Techno Commercial Bid (Envelope A) – Invitation for Expression of Interest (EOI) from

MNRE approved channel partners for setting up of So lar PV Power Plant of capacity

50 KW connected to grid tied at Main Office, Coimbatore Corporation – Tender Ref.:

22

15792/2008/MD3 due on .09.2013.” The “FROM” address and “TO” address shall be

written without fail otherwise the Techno Commercia l bid is liable for rejection.

6.2 Price Bid (Envelope-B)

6.2.1 Details to be furnished

a) All the Price items as asked in the Tender should be filled in the Price Bid format as given

in the Tender. The prices quoted shall be in INDIAN RUPEES (INR) only . The Tender is

liable for rejection if Price Bid contains conditional offers or partial offers and if quoted in any

currency other than INR.

b) The cost quoted by the Bidder shall include the breakup cost of the components of SPV

power plants viz., panel, Inverter, and other accessories which are required for on line plant

Set etc.

c) The cost quoted by the Bidder shall be kept firm for a period specified in the Tender from

the date of opening of the Tender. The Bidder should keep the Price firm during the period

of Contract including the period of extension of time if any. The Bidders should particularly

take note of this factor before submitting the Bids.

6.2.2 Signing the Price Bids

a) The Bid shall be typed and shall be signed by the Bidder or a person or persons duly

authorized to bind the Bidder to the Contract. All pages of the bid document including the

supporting documents shall be signed and stamped by the authorized person.

b) Any alterations, deletions or overwriting shall be treated valid only if they are attested by

full signature by the authorized person.

6.2.3 Sealing the Price Bid

The Price Bid shall be placed in a separate cover (Envelope-B) and sealed appropriately.

The Price Bid cover shall be super scribed with “Price Bid (Envelope B) – Invitation for

Expression of Interest (EOI) from MNRE approved channel partners for setting up of Solar

PV Power Plant of capacity

23

50 KW connected to grid tie at Main Office, Coimbatore Corporation– Tender Ref.:

15792/2008/MD1 due on .09.2013.” The “FROM” address and “TO” address shall be

written without fail otherwise the Price Bid is liable for rejection.

6.3 Outer Cover

Techno Commercial Bid cover (Envelope-A) and Price Bid cover (Envelope-B) shall then

be put in a single outer cover and sealed. The oute r cover shall be superscribed with

Invitation for Expression of Interest (EOI) from MN RE approved channel partners for

setting up of Solar PV Power Plant of capacity 50 K W connected to grid tied at

Coimbatore Corporation– Tender Ref.: 15792/2008/MD3 due on .09.2013.” The “FROM”

address and “TO” address shall be written without fail otherwise the Bid is liable for

rejection.

EMD may be kept in the outer cover or in Techno Commercial Bid cover (Envelope – A)

6.4 Mode of Submission of Bids

a) The Bids should be dropped in the Tender box kept at Coimbatore City Municipal

Corporation, Big Bazaar Street, Coimbatore, Tamil Nadu, India, on or before the due date

and time. The Bids will not be received personally.

b) Alternatively, if the Bidder prefers to submit the Bid by post, the Bidders should ensure

that the Bids reach CCMC on or before the due date and time. CCMC will not be liable or

responsible for any postal delay or any other delay whatsoever.

c) The Bids received after Due Date and Time or Unsealed or in incomplete shape or

submitted by Facsimiles (FAX) or email will be summarily rejected.

6.5 Modification and withdrawal of Bids

The Bids once submitted

(i) cannot be modified or amended.

(ii) cannot be withdrawn after the due date for submission of tender.

24

7. Bid Opening

7.1 Techno Commercial Bid Opening

The Tender outer cover and Techno commercial Bid cover, will be opened at CCMC on the

date and time as specified in the Tender Data sheet or any other date published in the

website specified. The Tender will be opened in the presence of the Bidders who choose to

be present. The representative(s) of the Bidder who chooses to attend Tender opening shall

bring an authorization letter from the Bidder. A maximum of two representatives for each

Bidder would be allowed to attend the Tender opening.

7.2 Tender Validity

a) Bids submitted shall remain valid for a period of 180 days from the date of Tender

opening. If the bid validity is lesser than 180 days, the Bid will be rejected as non-

responsive.

b) In exceptional circumstances, CCMC may solicit the Bidders to extend the validity. The

Bidder should extend price validity and Bid security validity.

7.3 Initial Scrutiny

Initial Bid scrutiny will be held and Tenders as given below will be treated as non-

responsive.

��Tender received without EMD amount

��Tender not submitted in two parts as specified in the Tender and signing and stamping

in all pages of the Bid

��Tender received without the Letter of Authorization as specified in the Tender

��Tender found with suppression of facts or details

��Tender with incomplete information, subjective, conditional offers and partial offers

��Tender submitted without supporting documents to prove Eligibility criteria and

Evaluation

��Tender not complying with any of the clauses stipulated in the Tender

��Tender with lesser validity period

25

��Tender submitted without sample test report of components from the Testing Agency

All responsive Bids will be considered for further evaluation. The decision of CCMC will be

final in this regard.

7.4 Clarifications by CCMC

When deemed necessary, CCMC may seek bona-fide clarifications on any aspect from the

Bidder. However, that would not entitle the Bidder to change or cause any change in the

substance of the Bid or price quoted. During the course of Techno commercial Bid

evaluation, CCMC may seek additional information or historical documents for verification to

facilitate decision making. In case the Bidder failed to comply with the requirements of

CCMC as stated above, such Bids at the discretion of CCMC, shall be rejected as

technically non-responsive.

7.5 Price Bid Opening

Bidders who are qualified in Techno commercial Bid (Envelope-A) only will be called for

Price Bid opening. The Price Bids will be opened in the presence of the Bidders at CCMC.

The Bidders or their authorized representatives (maximum two) will be allowed to take part

in the Price Bid opening.

8. Tender Evaluation and Selection

8.1 Suppression of facts and misleading information

a) During the Bid evaluation, if any suppression or misrepresentation of information is

brought to the notice of CCMC, CCMC shall have the right to reject the Bid and if after

selection, CCMC would terminate the contract as the case may be, will be without any

compensation to the Bidder and the EMD or Security Deposit as the case may be, shall be

forfeited.

b) Bidders should note that any figures in the proof documents submitted by the Bidders for

proving their eligibility is found suppressed or erased, CCMC shall have the right to seek the

correct facts and figures or reject such Bids.

c) The Tender calls for full copies of documents to prove the Bidder’s experience, capacity

and other requirements to undertake the project.

26

8.2 Techno Commercial Bid Evaluation

a) The Bidders who have duly complied with the Eligibility Criteria will be eligible for further

processing.

b) The Tenders, which do not conform to the Technical Specifications or Tender conditions

or Tenders from Bidders without adequate capabilities for supply & installation, will be

rejected. The Eligible Bidders alone will be considered for further evaluation.

8.3 Price Bid Evaluation

1) Bidders who are qualified in Techno commercial Bid (Envelope-A) only will be called for

Price Bid opening. The Price Bids will be opened in the presence of the Bidders at CCMC.

The Bidders or their authorized representatives (maximum two) will be allowed to take part

in the Price Bid opening.

2) The Price Bid evaluation will be conducted as stipulated in the Tamil Nadu Transparency

in Tenders Act 1998 and Tamil Nadu Transparency in Tenders Rules 2000 and MNRE

rlues. The Price evaluation will include all Duties and Taxes as given below.

(i) In cases of discrepancy between the cost quoted in Words and in Figures, the lower of

the two will be considered.

(ii) In evaluation of the price of articles which are subject to excise duty, the price will be

determined inclusive of such excise duty;

(iii) In a tender where all the renderers are from within the State of Tamil Nadu, or where all

the tenderers are from outside the State of Tamil Nadu, the Value Added Tax shall be

included for the evaluation of the price; and

(iv) In a tender where the tenderers are both from the State of Tamil Nadu as well as from

outside the State of Tamil Nadu, [ the Value Added Tax levied under Tamil Nadu Added Tax

Act 2006 (TamilNadu Act 32 of 2006)] shall be excluded for the evaluation of the price.

3) The lowest cost as per the above evaluation will be adjudged as L1. CCMC will not be

responsible for any erroneous calculation of tax rates or any subsequent changes in rates

or structure of applicable taxes. All differences arising out as above shall be fully borne by

the Successful Bidder.

4) No dispute can be raised by any Bidder whose Bid has been rejected and no claims will

be entertained or paid on this account.

27

8.4 CCMC reserves the right to;

1) Negotiate with the Bidder whose offer is the lowest evaluated price for further reduction

of prices.

2) Ask other Bidders to match L1 price.

3) Apportion the total quantity among the L1 Bidder and other Bidders who have agreed to

match L1 rate.

4) Insist on quality or specification of materials to be supplied.

5) Modify, reduce or increase the quantity requirements to an extent of 25% of the

Tendered quantity as per the provisions of Tamil Nadu Transparency in Tenders Act 1998

and Tamil Nadu Transparency in Tenders Rules, 2000 and MNRE rlues.

6) Change the list of areas of installation locations from time to time based upon the

requirement.

7) Reallocate the quantity to other Bidder if performance of the Bidder is not as per the

completion Schedule

8) Inspect the bidders’ factory or office premises and based on the inspection reduce the

quantity ordered.

9) Withhold any amount for the deficiencies in the service aspect of SPV power plants

installed at the identified locations.

9. Award of Work

9.1 Acceptance of the Tender

The final acceptance of the Tender is entirely vested with Tender Acceptance Committee

(TAC) who reserves the right to accept or reject any or all of the Tenders in full or in part.

The TAC may also reject any tender for reasons such as changes in the new technologies,

court orders, accidents or calamities and other unforeseen circumstances. After acceptance

of the Tender by TAC, the Bidder shall have no right to withdraw their Tender or claim

higher price

9.2 Letter of Acceptance (LOA)

After acceptance of the Tender by the TAC, a Letter of Acceptance (LOA) will be issued

only to the Successful Bidder(s). CCMC has the right to issue LOA to more than one bidder

28

9.3 Payment of Security Deposit (SD)

a) The Successful Bidders will be required to remit the Security Deposit equivalent to 5%

(Five percent) of the value of the Work Order inclusive of EMD amount. The SD should be

paid by way of Demand Draft drawn in favour of “Coimbatore City Municipal Corporation”

payable at Coimbatore or in the form of unconditional and irrevocable Bank Guarantee,

valid till the completion of 5 year comprehensive maintenance. The SD should be paid

within 15 days from the date of issue of Letter of Acceptance by CCMC.

b) The Security Deposit will be refunded to the Successful Bidder only after successful

performance and comprehensive maintenance for 5 years. The Security Deposit held by

CCMC till it is refunded to the Successful Bidder will not earn any interest thereof.

c) The Security Deposit or EMD will be forfeited if the Successful Bidder(s) withdraw(s) the

Bid during the period of Bid validity specified in the Tender or if the Bidder fails to sign the

contract.

9.4 Execution of Agreement

a) The Successful Bidder shall execute a Contract in the INR 80/- non-judicial stamp paper

bought in Tamil Nadu only in the name of the Bidder, within 15 days from the date of Letter

of Acceptance issued by CCMC.

b) The Successful Bidder shall not assign or make over the contract, the benefit or burden

thereof to any other person or persons or body corporate for the execution of the contract or

any part thereof without the prior written consent of CCMC, which reserves its right to

cancel the work order either in part or full, if this condition is violated.

c) In case of the successful bidder fails to execute necessary agreements as prescribed,

within the stipulated period, then his EMD shall be forfeited and his tender held as non

responsive.

9.5 Release of Firm Work Order

After execution of the Contract and payment of Security Deposit, “Firm Work Order” for

Supply, installation , commissioning & 5 years comprehensive maintenance of SPV power

plants will be issued to the Successful Bidder by the Coimbatore city Municipal Corporation.

29

9.6 Installation & Completion Schedule

The entire work involving Supply, installation & commissioning of quoted number of Solar

PV Power plant of 50 KW connected to grid tied at Main Office, Coimbatore Corporation,

should be completed within 90 days of work order.

9.7 Refund of EMD

The EMD amount paid by the Successful Bidder(s) will be adjusted towards Security

Deposit payable by them. If the successful Bidder submits Security Deposit for the

stipulated value in full by way of Bank Guarantee, the EMD will be refunded. The EMD

amount of the unsuccessful Bidders will be refunded by CCMC against finalization and

signing of agreement by the Successful Bidder with CCMC.

9.8 Termination of Contract

9.8.1 Termination for default

a) Coimbatore City Municipal Corporation may without prejudice to any other remedy for

breach of contract, by written notice of default with a notice period of 7 days, sent to the

Successful Bidder, terminate the contract in whole or part, (i) if the Successful Bidder fails to

Supply, install , commission & testing of Solar PV power plant of 50 KW connected to grid

tied at Main Office, Coimbatore Corporation within the time period(s) specified in the

contract ,or fails to fulfill the requirements as per the Delivery Schedule or within any

extension thereof granted by Coimbatore City Municipal Corporation or (ii) if the Successful

Bidder fails to perform any of the obligation(s) under the contract; or (iii) if the Successful

Bidder, in the judgment of Coimbatore City Municipal Corporation, has engaged in

fraudulent and corrupt practices in competing for or in executing the Contract

b) In the event Coimbatore City Municipal Corporation terminates the Contract in whole or in

part, Coimbatore City Municipal Corporation may opt upon terms and in such manner as it

deems appropriate, the services of the other bidders and the Successful Bidder shall be

liable to Coimbatore City Municipal Corporation for any additional costs due to this.

However, the Successful Bidder shall continue the performance of the contract to the extent

not terminated.

30

9.8.2 Termination for Insolvency

Coimbatore City Municipal Corporation may at any time terminate the Contract by giving

written notice with a notice period of 7 days to the Successful Bidder, if the Successful

Bidder becomes bankrupt or otherwise insolvent. In this event, termination will be without

compensation to the Successful Bidder, provided that such termination will not prejudice or

affect any right of action or remedy that has accrued or will accrue thereafter to Coimbatore

City Municipal Corporation.

9.8.3 Termination for Convenience

Coimbatore City Municipal Corporation may by written notice, with a notice period of seven

days sent to the Successful Bidder, may terminate the Contract, in whole or in part, at any

time for its convenience. The notice of termination shall specify that termination is for

Coimbatore City Municipal Corporation’s convenience, the extent to which performance of

work under the Contract is terminated, and the date upon which such termination becomes

effective. On termination, the successful Bidder is not entitled to any compensation

whatsoever

10. Execution of Work

10.1 Scope of work

a) Scope of work covers Supply, Installation & Commissioning of SPV power plant as per

the technical specification.

b) Insuring the goods in transit is the responsibility of the bidders.

c) Comprehensive maintenance of the system is for 10 years. The comprehensive

maintenance shall include preventive maintenance service visits monthly till the completion

period of comprehensive maintenance. The maintenance shall include replacement of all

parts or components found defective due to manufacturing defect or because of wear and

tear. If the SPV power plant is not functional, the same should be repaired or restored or

replaced within 7 days.

d) If the successful bidder, having been notified fails to rectify the defect(s) and restore the

SPV power plant to good working condition within the period specified above, then a penalty

31

of Rs. 500/- per system per day beyond 7 days breakdown will be levied. This will be

deducted from the bills due.

e) The successful bidder shall undertake to supply spares free of cost for the maintenance

of the offered items during the warranty period. The successful bidder should keep all the

spares available for sale at least for a period of 5 years after the completion of the warranty

period.

f) If the operation or use of the system proves to be unsatisfactory during the warranty

period, the Successful Bidder shall replace the faulty ones or carry out necessary repairs as

per the warranty terms and conditions to the full satisfaction of Coimbatore City Municipal

Corporation.

h) In case the Successful Bidder fails to carry out the warranty regulations, Coimbatore City

Municipal Corporation would engage any other agency and carry out the service or

replacement and deduct the amounts from the performance guarantee amount retained by

Coimbatore City Municipal Corporation as per the Payment terms or from their pending bills

or any money due or payable to them.

10.2 Insurance

Transportation of components to the installation site and insuring the goods in transit is

the responsibility of the Bidder. The goods being installed under the contract should be

covered for comprehensive Insurance by the Successful Bidder against loss (or) damage

incidental to transportation, storage at site and delivery to site during the erection period.

10.3 Handing Over

The system shall be handed over to The Commissioner after successful commissioning

through prescribed handing over and taking over format.

10.4 Comprehensive Maintenance

a) The Successful Bidder should provide 10 year comprehensive maintenance of the SPV

power plant which shall include corrective maintenance as well as routine service visits. b)

The service personnel of the Successful Bidder will make routine maintenance visits

32

monthly till the completion period of comprehensive maintenance. Apart from this any

complaint registered or service calls received or faults notified, the service personal

should reach the site within 2 days and attend to the defects or faults and rectify the same

or replace the faulty systems if needed within 7 days.

c) The deputed personnel shall be in a position to check and test all the equipments

regularly, so that preventive actions, if any, could be taken well in advance to save any

equipment from damage.

d) Normal and preventive maintenance of the SPV power plants such as cleaning of module

surface, tightening of all electrical connections, changing of tilt angle of module mounting

structure, etc. are also the duties of the deputed personnel during maintenance visits.

e) During operation and maintenance period of the SPV power plants, if there is any loss or

damage of any component due to miss management or miss handling or due to any other

reasons pertaining to the deputed personnel, what-so-ever, the supplier shall be

responsible for immediate replacement or rectification. The damaged component may be

repaired or replaced by new component.

f) The maintenance shall include replacement of any component irrespective of whether the

defect was a manufacturing defect.

g) If the successful bidder, having been notified fails to rectify the defect(s) and restore the

SPV Power plants to good working condition within the period specified above, then a

penalty of Rs. 500/- per system per day beyond 7 days breakdown will be levied. This will

be deducted from the bills due.

h) Coimbatore City Municipal Corporation reserves the right to claim damages and Costs for

non-fulfillment of warranty, apart from forfeiting un-paid amount if any, in the event of

unsatisfactory maintenance.

11. Liquidated Damages

If the Successful Bidder fails to commission the system as within the delivery period

specified. Liquidated Damages at the rate of 2% per completed week per system will be

levied subject to a maximum of 10% for each delayed commissioning. The Liquidated

Damages amount will be automatically deducted from the Bills submitted by the Successful

Bidder.

12 Warranty

1. (a) The SPV panel shall carry a warranty of minimum 25 years.

33

(b) The SPV panel must be warranted for their output peak watt capacity which should not

be less than 90% at the end of 10 years and 80% at the end of 25 years (c)The PCU/ LED

luminaries /battery charger/charge controller shall carry a warranty of minimum 5 years. (d)

The battery shall carry a warranty of minimum 5 years.

2. The power conditioners/inverters/chargers/charge controllers/ maximum power point

tracker units/ distribution boards/digital meters/ switchgear/ storage batteries, LED lighting

units and overall workmanship of the SPV power plants/ standalone street lighting systems

including mechanical structures and electrical works must be warranted against any

manufacturing/ design/ installation/performance defects for a minimum period of 5 years

from the date of commissioning.

3. The warranty will be against breakages, malfunctions, non fulfilment of guaranteed

performance degradation of generation of below the specified level by the MNRE etc.,

and breakdowns due to manufacturing defects or defects that may arise due to improper

operation of electrical / electronic components of the system but do not include physical

damages by the end users.

4. The above warranty shall take effect from the date on which the system is taken over by

the Corporation after commissioning.

5. The successful tenderer shall be liable to make good the loss by replacing the defective

product during the warranty period for the entire system free of cost, failing which

corporation would deduct the amount from the amount retained by corporation as per

Payment terms (or) issue recovery and also the bidder will be blacklisted.

6. The warranty will cover all the materials and goods involved in the installation and

commissioning of solar PV power plant by the successful Bidder under this contract

irrespective of the fact whether these have been manufactured by the Successful Bidder or

not. The decision in this regard by corporation is final and binding on the successful bidder.

13 Pre- Despatch Inspection 13.1 Components manufactured in India

a) Successful Bidder should conduct 100% pre-despatch inspection on all the components

of solar power plant b) CCMC will nominate third party agencies who will conduct

34

independent inspection and specification conformity of the product(s) manufactured by the

successful bidder and of the major components purchased from other manufacturers on

random sample basis, at the manufacturer‟s plant. The successful bidder shall make

necessary arrangements for inspection of components purchased from others by third party

agencies at the respective manufacturing plants. The infrastructure for testing the

components as called for in the specifications must be available at the manufacturing

plants. Calibrated equipments certified by NABL accredited labs should be available at the

manufacturing plants for testing. c) CCMC would bear the cost of third party inspection at

only one manufacturing plant for each component. If a component is produced in more than

one location, then the cost of positioning the third party inspection by CCMC in the second

and subsequent plants would be borne by the Successful Bidder at their cost.

d) The minimum lot size for various components shall be as below:

Only after the third party testing agency clears the lot & random super check by CCMC

Engineers, it will be permitted to be supplied. Lot will be rejected, if any sample has more

than 3% deviation. The successful bidder shall bear the cost of Third Party Inspection of the

lot replacing the rejected lot. If the bidder desires to have smaller lots, he has to bear the

cost of inspection. e) Components to be supplied must give same performance results or

better results with respect to technical evaluation results. f) CCMC may nominate its own

officers to be in the manufacturing plant to supervise the quality of manufacturing process.

This would be in addition to the third party inspection.

13.2 Components Manufactured Abroad

The conditions in 11.1 (a) to (f) above are applicable for the components manufactured in

abroad also. CCMC nominated third party agencies will conduct inspection at the

manufacturing plant or at a single specified location within the State of Tamil Nadu. If the

inspection is arranged at the manufacturing plant abroad, the successful bidder shall bear

the entire cost towards travel, accommodation & food for Third party inspection. Cost of two

CCMC officers for super check shall also be borne by the successful bidder.

14.Product Take Back & Recycling

Proper decommissioning and recycling of SPV panels , Batteries & electronics etc., are

necessary to ensure that harmful materials are not released in to the environment. Hence

35

an under taking from the successful bidder for product take back after expiry of their life

shall be submitted. It is mandatory for the successful bidder to comply with batteries

(Management and handling) Rules 2001 of MOEF, as amended from time to time.

15. Traceability of the product to be supplied In order to prevent the misuse of the product such as unauthorised sale or diversion to the

open market, the following incorporation shall be made in the product.

a) Engraving (or) Screen printing of GOTN & CCMC Logo at a suitable place on the main

components viz., SPV Panel, Battery, PCU, LED Lighting Units to be used in the installation

of the solar street lighting systems.

b) RFID shall be provided in the SPV panels

c) The unique system ID number as provided by CCMC Shall be permanently pasted (or)

marked on each component of the system.

Note: Design approval for the logo shall be obtaine d from CCMC before using in the

production. The above feature is meant for the specific supply to CCMC and the

successful Bidders are not permitted to use them for their normal sale.

16. Payment Terms

The payment in the following forms will be released after carrying out inspection of the

installation and commissioning of SPV power plants.

1) All payments will be made in INR only.

2) No advance will be paid or no letter of credit will be issued.

3) The bidder should submit the bank guarantee for the total subsidy amount of this project

along with financial bid if the bidder failed to submit the bank guarantee in the financial bid,

that bid will rejected even the bidder qualified in the technical bid evaluation.

3. 85% payment will be made in accordance with MNRE norms and conditions on

satisfactory commissioning and inspection .

4) a.Along with the final bid the bidder shall invariably furnish necessary bank guarantee



MNRE

36

b. 15% payment will be made after the completion of 1 year CMC period against submission

of 4 Nos. irrevocable BGs of 3% each of contract value valid for 12 months, 24 months , 36

months and 51 months respectively. The 4 Nos. Irrevocable BGs will be released every

year after satisfactory functioning of Solar power plants. In case of default , BGs will be

encashed.

5) The Comprehensive Maintenance Contract payment will be subject to fulfillment of

Warranty or Comprehensive Maintenance obligations.

6) If the Duties and/or Taxes have been reduced retrospectively, the successful bidder is

liable to return the same.

7) The Successful Bidder will have full and exclusive liability for payment of all Duties,

Taxes and other statutory payments payable under any or all of the Statutes or Laws or

Acts etc now or hereafter imposed.

ANNEXURE-IIA TECHNICAL SPECIFICATION FOR GRID TIE SPV POWER PLAN TS

Solar PV Array (KWp) 50 KW Power Conditioning Unit (KVA) 50KVA DEFINITION A Grid Tie Solar Photo Voltaic (SPV) power plant consists of SPV array, Module Mounting Structure, Power Conditioning Unit (PCU) consisting Maximum Power Point Tracker (MPPT), Inverter, Controls & Protections, interconnect cables and switches. PV Array is mounted on a suitable structure. Grid tie SPV system is without battery and should be designed with necessary features to supplement the grid power during day time.

37

Components and parts used in the SPV power plants including the PV modules, metallic structures, cables, junction box, switches, PCUs etc., should conform to the BIS or IEC or international specifications, wherever such specifications are available and applicable.

17.Technical Specifications of Major Components of Solar PV Power Plant

1. Solar PV modules and array 2. Module mounting structure 3. Junction Boxes 4. Power Conditioning Unit 5. DC & AC Switches 6. Cables and installation accessories 7. Earthing and lightning protection

1. SOLAR PV MODULES AND ARRAY (i) Only indigenous modules shall be used in the pr oject. Solar module shall be

Crystalline (Mono/Poly) (or) Thin Film (or) Concentrator PV modules type. The peak power output of the PV Module shall be min 100Wp under STC. Module Voc shall be minimum 21V. The total array capacity shall not be less than 50 KWp (to be filled based on the capacity of the plant) and this shall be operating at the DC voltage of 24 V (to be selected based on capacity of the plant). The power output of the PV module must be reported under standard test conditions (STC). I_V curve of the sample module should be submitted.

(ii) The mechanical structure shall withstand gusts of wind / cyclonic wind up to 150 km/hr from back side of the panel.

(iii) The offered modules must conform to the latest edition of any of the following IEC/

equivalent BIS Standards for PV module design qualification and type approval:

Crystalline Silicon Terrestrial PV Modules : IEC 61215/IS14286 Thin Film Terrestrial PV Modules : IEC 61646/ Equivalent IS (Under Dev.) Concentrator PV Modules & Assemblies : IEC 62108

(iv) In addition, the modules must conform to IEC 61730 1- requirements for construction & Part 2 – requirements for testing, for safety qualification or Equivalent IS (Under Dev.)

(v) PV modules must also qualify Salt Mist Corrosion Testing as per IEC 61701/IS61701.

(vi) SPV modules shall be certified by NABL/IECQ accredited test centre. The bidder

shall submit appropriate certificates. (vii) Protective devices against surges at the PV module shall be provided. Low voltage

drop bypass diodes shall be provided.

(viii) Module Junction box (weather proof), where the module terminals shall be interconnected and output taken, shall be designed for long life out door operation in

38

harsh environment as per the relevant BIS specifications and protected against surges. It should have a provision for “Opening” for replacing the cable, if required.

(ix) PV modules used in solar power plants must be warranted for output wattage, which

should not be less than 90% at the end of 10 years and 80% at the end of 25 years.

(x) Each PV module must use a RF identification tag (RFID), which must contain the following information:

a. Name of the manufacturer of PV Module b. Name of the manufacturer of Solar cells c. Unique Serial Number & Model No. of the module d. Month and year of the manufacture (separately for Solar cells and module) e. Country of origin (separately for solar cells and module) f. I-V curve for the module g. Peak Wattage of the module, Im, Vm and FF for the module h. Date and year of obtaining IEC PV module qualification certificate i. Name of the test lab issuing IEC certificate

j. Other relevant information on traceability of solar cells and module as per ISO 9000 series

RFID shall be mandatorily placed inside the module laminate. A distinctive serial number starting with NSM will be engraved on the frame of the module or screen printed on the tedlar sheet of the module.

1.1 ORIENTATION AND TILT OF PV MODULES

(i) Modules shall be North –South oriented at the Tilt Angle of 11° -13°

2. MOUNTING STRUCTURES

The PV modules will be mounted on fixed metallic structures of adequate strength and appropriate design, which can withstand load of modules and high wind velocities up to 150 km per hour. The support structure used in the power plants will be hot dip Galvanized Iron (G.I). The “Mounting Structure” should have the following features: • The modules support structure shall be Mild Steel /hot dipped Galvanized (at least 120 micron) Iron for holding the PV modules. The size of angle iron should not be less than 50x50x5 mm. • Each panel frame structure shall be so fabricated as to be grouted on roof on its legs. The legs of the structure shall be fixed and grouted in the PCC foundation column made with 1:2:4 cement concrete. The foundation shall support SPV modules at a given orientation, absorb and

39

transfer the mechanical loads to the ground properly and shall withstand maximum wind speed of 150 km/hr. • All nuts and bolts should be made of good quality Stainless Steel. • The structure should be designed to allow easy replacement of any module. • The array structure shall be so designed that it will occupy minimum space without sacrificing the output from the SPV panels. • The minimum clearance of the lowest part of the module structure and the developed ground level shall not be less than 500 mm. • The minimum clearance required from the parapet wall of the roof & in between row of panels is min 2 feet for cleaning the panels & servicing. • The bidder shall specify installation details of the PV modules and the support structures with appropriate diagrams and drawings. The work shall be carried out as per the designs approved by the procuring entity.

3. JUNCTION BOXES

The junction boxes shall be dust proof, vermin and waterproof and made of FRP / Thermo Plastic. The terminals shall be connected to copper bus bar arrangement of proper sizes. The junction boxes shall have suitable cable entry points fitted with cable glands of appropriate sizes for both incoming and outgoing cables. Suitable markings shall be provided on the bus bar for easy identification and cable ferrules shall be fitted at the cable termination points for identification. Each main junction box shall be fitted with appropriate rating blocking diode. The junction boxes shall be of reputed make.

4. POWER CONDITIONING UNIT (PCU)

As SPV array produce direct current electricity, it is necessary to convert this direct current into alternating current and adjust the voltage levels to match the grid voltage. Conversion shall be achieved using an electronic Inverter and the associated control and protection devices. All these components of the system are termed the “Power Conditioning Unit (PCU)”. In addition, the PCU shall also house MPPT (Maximum Power Point Tracker), an interface between Solar PV array & the Inverter, to maximize Solar PV array energy input into the System. PCU including MPPT & protection conform to IEC 61683/IS 61683, IEC 60068-2(1,2,14,30)/Equivalent BIS Std., 18. DETAILED SPECIFICATION

1) Normal DC Array Input Voltage

To be filled up based on the capacity of PV plant DC Voltage of the PV array shall be suitable for th e MPPT range of PCU

2) DC Array Input Operating Voltage -20% to +15% of the DC Array input voltage in S.No. 1 above

40

3) Type of Solar Charge Controller MPPT Based Solar Charge Controller

4) Switching device MOSFET / IGBT based

5) Continuous inverter Output Rating

Equal to capacity of PV plant. To be mentioned in K VA

6) Output Wave Form Pure Sine Wave Output

7) Total Harmonic Distortion

< 3% with resistive load

8) Output Voltage 230± 3 % in case of 1 phase PCU 400± 3 % in case of 3 phase PCU

9) Output Frequency 50 Hz. ± 0.5 Hz.

10) Power Factor >0.9

11) PCU Efficiency >90 % at nominal voltage & power

12) Idle Current <4 % of rated capacity

13) Regulation Line regulation & Load regulation – 2 %

14) Overload Features 150% for 1 minute

15) Cooling Forced Air Cooling, with temperature controlled cooling fan

16) Operating temperature 0 – 5° C

17) Relative Humidity 95% Maximum

18) LED / LCD Display: Indications

Display shall indicate system functional parameters and protection functional indicator

19) Data monitor and display controls RS485, Ethernet OR RS232 connectivity

20) Protections

1) Input over voltage 2) Low / High Frequency

3) Short circuit 4) Under / over output voltage

5) Over Temperature 6) Grid Input under voltage / over voltage with auto recovery

7) DC disconnect device

8) DC reverse polarity

9) Anti Islanding Protection as per the standard

21) Enclosure Protection IP 21 (for indoor) as per IEC 529

22) Safety 1. IEC 62103 2. IEC 62109 Part 1 & 2 3. Galvanic Isolation at input & output through transformer

5. DC & AC Switches

41

a. DC SIDE

(i) MCB of suitable rating shall be provided for connection and disconnection of array &

PCU for maintenance purpose.

(ii) Switches and Circuit Breakers on DC side shall be DC rated or they shall be sufficiently de-rated, if AC rated switches are used.

b. AC SIDE

MCB of suitable rating shall be provided for connection and disconnection of PCU & load.

6. Cables and accessories

All the cables shall be supplied conforming to IEC 60227/IS 694 & IEC 60502/IS 1554 shall be of 1.1 kV grade as per requirement. Only PVC copper cables shall be used. The size of the cables between array interconnections, array to junction boxes, junction box to PCU, PCU to AC Distribution Box etc shall be so selected to keep the voltage drop and losses to the minimum. Permissible Wire Drop on DC side shall be <= 1% The bidder shall supply installation accessories, which are required to install and successfully commission the power plant.

7. Earthing and Lightning Protection:

Earthing: The array structure of the PV yard shall be grounded properly using adequate number of earthing kits. All metal casing or shielding of the power plants shall be thoroughly grounded to ensure safety of the solar power plants. Lightning: The SPV power plants shall be provided with lightning & over voltage protection. The main aim in this protection shall be to reduce the over voltage to a tolerable value before it reaches the PV or other sub system components. The source of over voltage can be lightning, atmosphere disturbances etc

8. OPERATION AND MAINTENANCE MANUAL

An Operation and Maintenance Manual, in English and Tamil, should be provided with the solar PV power plants. The following minimum details must be provided in the Manual: (a) About Photo Voltaic & PV Module (b) Clear instructions about mounting of PV module. (c) About electronics used in (d) DO's and DONT's, (e) Clear instructions on regular maintenance and Trouble Shooting of the power plants. (f) Name & address of the person or Centre to be contacted in case of failure or complaint.

42


43

“Invitation for Expression of Interest (EOI)” from MNRE

approved channel partners for setting up of Solar PV

Power Plant of capacity 50 KW connected to grid tied at

Main Office, Coimbatore Corporation

Tender Ref: CCMC/

Techno commercial Bid (Envelope-A)

Tender Details


Coimbatore

Techno Commercial Bid (Envelope-A)

(All pages of the Techno commercial Bid should be organized, annexed with proof

documents, serially numbered and stitched or spiral bound in tact and submitted) Loose

pages shall not be accepted.

44

1.1 Profile of the Bidder

1.2 EMD Amount

S.No Particulars Please furnish details

Name of the Bank

S. No Particulars Bidder

1. Name of the Company

2. Year of incorporation

3. Registered office

Address

Office Telephone Number

Fax Number

Contact Person

Name

Personal Telephone Number

Mobile Number

Email Address

5. Local office(s)in Tamil Nadu

Address

Office Telephone Number

Fax Number

6. Tender signing authority

Name

Address

Personal Telephone Number

Email Address

Please enclose Authorization or Power of Attorney to sign and submit the Tender

7. Address for communications under the current Tender

8. Registration Details

Permanent Account Number

VAT Registration Number

CST Registration Number

Service Tax Registration Number

Banker's Name, Address and Account Number

45

2. Demand Draft (DD) Number

3. DD Date

4. DD Amount

A1.3 Furnish details for meeting the Eligibility Cr iteria

1) Details about Incorporation

S.No Description Bidder

1. Year of Incorporation

2. Please enclose Certificate of Incorporation

2) Details about Manufacturing of PV Modules


1. Please enclose Manufacturing License

2. Date of commencement of production

3. Date of commencement of sale of the product manufactured

4. Manufacturing plant address

5. Please enclose monthly returns of Excise duty or CST filed or any

valid proof for last 1 audited year

3) Details about Annual Turnover

S.No Audited years Bidder

1. 2012-2013

2. 2011-2012

3. 2010-2011

4. 2009-2010

5. 2008-2009

* Please enclose audited Annual Report including Balance sheets and

Profit and Loss accounts for 3 audited years since 2008 - 2009

46

4) Details about Manufacturing Capacity


1. Manufacturing capacity per annum

2. Please enclose valid proof for the manufacturing capacity

5) Details about minimum quantity installed

S.No Name , Address &

contact details of the

Client

Capacity or

Quantity

Installed

(KWp or Nos)

Date of

Commissioning

1.

2.

A 1.4 TECHNICAL BID FOR SPV POWER PLANTS

(To be submitted separately for each location)

A.

SPV MODULE To be furnished by

the Bidder

1. Type of Module

2. Make

3. Availability of RFID tag

4. Max power at STC Pmax (W)

5. Max power voltage Vmp(V)

6. Max power current Imp(A)

7. Open circuit voltage Voc (V)

8. Short circuit current Isc (A)

9. Load voltage V ld (V)

10. Conversion Efficiency

11. No of cells per module

47

12. ` No of bypass diodes

13. Solar module frame material

14. Module Dimension

15. Module Weight

16. No of Modules

17. Array Capacity

18. Series or parallel combination

19. Other details

B. MODULE MOUNTING STRUCTURE

1. Type (Design drawing to be enclosed)

2. Structure material

3. Size

4. Structure leg material

5. Height & Dia of leg

6. PCC Foundation size

7. Other details

C. PCU(Charge Controller + Inverter)

1. Make

2. Type of Switching Element

3. Type of Charger

4. Input from Solar Array

5. Out put voltage

6. No load consumption

INVERTER

1. Nominal Capacity

2. Input Voltage

3. Output voltage

4. Output voltage Regulation

5. Output frequency

6. Over load capacity

7. Efficiency

48

8. %THD (Voltage )

9. %THD(Current)

10 Low Battery cut off

11. Protections

12. Indicators

13. Enclosure

D. CABLES

1. Make

2. Size & Quantity

3. Standard

4. Other details

E. EARTHING

1. Details of points earthed

2. Earth Resistance

Signature of the authorized person:

Name of the authorized person:

Designation:

Name and Address of Bidder

Stamp of bidder

49

Appendix-1 Bidder’s undertaking covering letter

(Letter should be submitted on Bidder(s) Letter Head)

Date:

To

The Commissioner

Coimbatore City Municipal Corporation (CCMC)

Coimbatore

Dear Sir,

Sub: Invitation for Expression of Interest (EOI)” f rom MNRE approved channel

partners for setting up of Solar PV Power Plant of capacity 50 KW connected to grid

tie at Main Office, Coimbatore Corporation– Reg.

Ref: Tender Reference

****

1. We have examined the tender for Supply, installation, commissioning & 5years

comprehensive maintenance of Solar PV Power plant of 50 KW capacity at Main Office,

Coimbatore Corporation as specified in the Tender. We undertake to meet th e

requirements and services as required in the Tender document.

2. We attach our Techno commercial Bid and Price Bid in separate sealed covers as

required by the Tender both of which together constitute our proposal, in full conformity with

the said Tender.

3. We have read the provisions of Tender and confirm that these are acceptable to us. We

further declare that additional conditions, variations, deviations, if any, found in our

response shall not be given effect to.

4. We undertake, if our Bid is accepted, to adhere to the requirements as specified in the

Tender or such modified plan as may subsequently be agreed.

50

5. We agree to unconditionally accept all the terms and conditions set out in the Tender

document and also agree to abide by this Bid response for a period as mentioned in the

Tender from the date fixed for bid opening and it shall remain binding upon us with full force

and virtue, until within this period a formal contract is prepared and executed, this Bid

response, together with your written acceptance thereof in your notification of award, shall

constitute a binding contract between us and CCMC.

6. We affirm that the information contained in the Techno commercial Bid or any part

thereof, including its schedules, and other documents, etc. delivered or to be delivered to

CCMC is true, accurate, and complete. This proposal includes all information necessary to

ensure that the statements therein do not in whole or in part mislead CCMC as to any

material fact.

7. We agree that CCMC is not bound to accept the lowest or any Bid you may receive. We

also agree that you reserve the right in absolute sense to reject all or any of the products or

service specified in the bid response without assigning any reason whatsoever.

8. It is hereby confirmed that I or We are entitled to act on behalf of our company or

organization and empowered to sign this document as well as such other documents, which

may be required in this connection.

9. We also declare that our Company or Organisation is not blacklisted by any of the State

or Central Government and organisations of the State or Central Government

10. We undertake to use the BoS components as per the standards stipulated in clause 15.

Signature of the authorized person:

Name of the authorized person:

Designation:

Name and Address of Bidder

Stamp of bidder

51

CERTIFICATE AS TO AUTHORISED SIGNATORIES

I, certify that I am(Name) …………………………… (Designation) …………………,and that

(Name)…………………………………… who signed the above Bid has been duly authorized

to sign the same on behalf of our Organisation.

Date:

Signature:

Seal:

52

Appendix-2 Model Form of Contract

To be executed on a Rs.80/- Non-judicial Stamp paper bought in Tamil Nadu by the

Successful Bidder for Supply, installation, commissioning & 5years comprehensive

maintenance of Solar PV Power plant of 50KW capacity at Main Office, Coimbatore

Corporation (NO FIGURES IN NUMERALS OR WORDS SHALL BE FILLED UP IN THIS

SAMPLE FORM AT THE TIME OF SUBMISSION OF TENDER)

CONTRACT

This Contract is entered into at Coimbatore on the ............... day of 2012 between CCMC ,

a wholly owned Government Dept of Tamil Nadu and having its Registered Office at

Coimbatore City Municipal Corporation, Big Bazaar Street, Coimbatore, Tamil Nadu ,India,

hereinafter referred to as “CCMC” (Which term shall mean and include its successors and

permitted assigns) on behalf of Government of Tamil Nadu, hereinafter referred to as

“Implementing Agency” and ................., a Company registered under .........................and

having its Registered office at .............................. hereinafter referred to as the “Successful

Bidder” (Which term shall mean and include its successors and permitted assigns)

Whereas CCMC has invited a tender vide Tender Ref. No. 15792/2008/MD3 (Solar-EOI)

for Supply, installation, commissioning & 5years comprehensive maintenance of Solar PV

Power plant of 200 KW capacity at Main Office, Coimbatore in the State of Tamil Nadu

and the Successful Bidder was selected as per the f ollowing terms and conditions:-

This document on having been signed by both the parties shall constitute a binding contract

between the parties and shall remain in force for a period of five years. But in the event of

any breach of the Contract at any time on the part of the Successful Bidder, the contract

shall be terminated by CCMC without compensation to the Successful Bidder. The contract

may also be put to an end at any time by the Implementing Agency upon giving seven days

notice to the Successful Bidder.

53

The Successful Bidder agrees for Supply, Installati on, Commissioning, Testing and 5

year Comprehensive Maintenance of as per the Terms & Conditions given below.

1. Installation & Completion Schedule

The entire work involving Supply, installation, commissioning & 5 years comprehensive

maintenance of Solar PV Power plant of 50 KW at Main Office, Coimbatore Corporation

within 180 days.

2. Insurance

Transportation of components to the installation site and insuring the goods in transit is the

responsibility of the Bidder. The goods installed under the contract should be covered for

comprehensive Insurance by the Successful Bidder against loss (or) damage incidental to

transportation, storage at site and delivery to site during the erection period.

3. Price Schedule:

Description Cost per System (Rs.)

1 Supply, Installation & Commissioning of 50 KW SPV Power Plant

2 Taxes if CST or VAT

3 Total cost per system inclusive of Solar wiring

4. Comprehensive Maintenance

a) The Successful Bidder should provide 5 year comprehensive maintenance of the SPV

Power Plant, which shall include corrective maintenance at the identified locations.

b) The service personnel of the Successful Bidder will make routine maintenance visits

monthly for the first three months and quarterly thereon for the first year and the next year

onwards once in a year till the completion period of comprehensive maintenance. Apart

from this any complaint registered or service calls received or faults notified , the service

personal should reach the site within 2 days and attend to the defects or faults and rectify

the same or replace the faulty systems if needed within 7 days.

c) The deputed personnel shall be in a position to check and test all the equipments

regularly, so that preventive actions, if any, could be taken well in advance to save any

equipment of the system from damage.

d) Normal and preventive maintenance of the SPV Power Plants, such as cleaning of

module surface, tightening of all electrical connections, changing of tilt angle of module

54

mounting structure, etc. are also the duties of the deputed personnel during maintenance

visits.

e) During operation and maintenance period of the SPV power plants, if there is any loss or

damage of any component of the system due to miss management or miss handling or due

to any other reasons pertaining to the deputed personnel, what-so-ever, the supplier shall

be responsible for immediate replacement or rectification. The damaged component may be

repaired or replaced by a new component.

f) The maintenance shall include replacement of all parts.

g) If the successful bidder, fails to rectify the defect(s) and restore the SPV power plants to

good working condition within 7 days, then a penalty of Rs.500/- (Rs. Five Hundred only)

per system per day beyond 7 days breakdown will be levied. This will be deducted from the

bills due.

h) CCMC reserves the right to claim damages and Costs for non-fulfilment of warranty,

apart from forfeiting unpaid amount, if any, in the event of unsatisfactory maintenance.

5. Liquidated Damages for delayed installations

This is a time bound project. Any delay will make the project fruitless. Hence if the

Successful Bidder fails to commission the SPV power plants within the delivery period

specified, Liquidated Damages at the rate of 2% per completed week per system will be

levied subject to a maximum of 10% for each delayed commissioning. The Liquidated

Damages amount will be automatically deducted from the Bills submitted by the Successful

Bidder. Even, if installation is not completed, CCMC will make alternate arrangements and

the cost incurred by CCMC for doing the same will be recovered from the Successful

Bidder.

6. Warranty

1. (a) The SPV panel shall carry a warranty of minimum 25 years.

(b) The SPV panel must be warranted for their output peak watt capacity which should not

be less than 90% at the end of 10 years and 80% at the end of 25 years

(c) MPPT charge controller shall carry a warranty of minimum 5 years.

55

2. The controllers or maximum power point tracker units or distribution boards or digital

meters or switchgear, and overall workmanship of the SPV power plants or including

mechanical structures and electrical works must be warranted against any manufacturing or

design or installation or performance defects for a minimum period of 5 years.

3. The warranty will be against breakages, malfunctions, non fulfillment of guaranteed

performance and breakdowns due to manufacturing defects or due to wear and tear or

defects that may arise due to improper operation of electrical or electronic components of

the system but do not include physical damages by the end users.

4. The above warranty shall take effect from the date on which the system is taken over by

the users or beneficiaries

5. The successful tenderer shall be liable to make good the loss by replacing the defective

product during the warranty period for the entire system free of cost, failing which CCMC

would deduct the amount from the amount retained by CCMC as per Payment terms and

will be blacklisted.

6. The warranty will cover all the materials and goods involved in the installation and

commissioning of SPV power plants by the successful Bidder under this contract

irrespective of the fact whether these have been manufactured by the Successful Bidder or

not. The decision in this regard by CCMC is final and binding on the successful bidder.

7. PAYMENT TERMS:

1) All payments will be made in INR only.

2) No advance will be paid or no letter of credit will be issued.

3)Along with the final bid the bidder shall invariably furnish necessary bank guarantee



MNRE

4)a. 85% payment will be made in accordance with MNRE norms and conditions on

satisfactory commissioning and inspection

b. 15% payment will be made after the completion of 1 year CMC period against submission

of 4 Nos. irrevocable BGs of 3% each of contract value valid for 12 months, 24 months , 36

months and 51 months respectively. The 4 Nos. Irrevocable BGs will be released every

56

year after satisfactory functioning of Solar Power Plants. In case of default , BGs will be

encashed.

4) The Comprehensive Maintenance Contract payment will be subject to fulfillment of

Warranty or Comprehensive Maintenance obligations.

5) If the Duties and / or Taxes have been reduced retrospectively, the successful bidder is

liable to return the same.

6) The Successful Bidder will have full and exclusive liability for payment of all Duties,

Taxes and other statutory payments payable under any or all of the Statutes/Laws/Acts etc

now or hereafter imposed.

8. Force Majeure

Neither CCMC nor the Successful Bidder shall be liable to the other for any delay or failure

in the performance of their respective obligations due to causes or contingencies beyond

their reasonable control such as:

� Natural phenomena including but not limited to earthquakes, floods and epidemics.

� Acts of any Government authority, domestic or foreign including but not limited to war

declared or undeclared, priorities and quarantine restrictions.

� Accidents or disruptions including, but not limited to fire, explosions, breakdown of

essential machinery or equipment, power and water shortages.

9. The following documents shall be deemed to form and be read and construed as

part of this Contract.

a) Technical Specifications

b) Tender Terms and Conditions

c) Amendments issued by CCMC for the Tender document

d) Corrigendum or Clarifications issued by CCMC for the Tender document

e) Detailed final offer of the Successful Bidder

f) Work Order(s) issued by CCMC from time to time

57

g) Correspondence made by CCMC to the successful Bidder from time to time during the

period of the contract. Wherever the offer conditions furnished by the Successful Bidder are

at variance with conditions of this contract or conditions stipulated in the work order, the

later shall prevail over the offer conditions furnished by the Successful Bidder.

10. Waiver of any terms and conditions by CCMC in writing shall not have the effect of

waiving or abandoning other terms and conditions of the contract.

11. (a) Unless otherwise provided in the Contract, any notice, request, consent or other

communication given or required to be given hereunder shall be given by mailing the same

by registered mail, postage prepaid to CCMC at its registered office

(b) Any notice to the Successful Bidder shall be deemed to be sufficiently served, if given or

left in writing at their usual or last known place of abode or business.

12. Termination of Contract

12.1 Termination for default

a) CCMC may without prejudice to any other remedy for breach of contract, by written

notice of default with a notice period of seven days, sent to the Successful Bidder, terminate

the contract in whole or part, (i) if the Successful Bidder fails to install and commission the

SPV Power plants within the delivery Schedule or within any extension thereof granted by

CCMC or (ii) if the Successful Bidder fails to perform any of the obligation(s) under the

contract; or (iii) if the Successful Bidder, in the judgment of CCMC, has engaged in

fraudulent and corrupt practices in competing for or in executing the Contract.

b) In the event CCMC terminates the Contract in whole or in part, CCMC may procure, upon

terms and in such manner as it deems appropriate, the goods and services similar to those

tendered and the Successful Bidder shall be liable to CCMC for any additional costs for

these. However, the Successful Bidder shall continue the performance of the contract to the

extent not terminated.

12.2 Termination for Insolvency

CCMC may at any time terminate the Contract by giving written notice with a notice period

of 7 days to the Successful Bidder, if the Successful Bidder becomes bankrupt or otherwise

insolvent. In this event, termination will be without compensation to the Successful Bidder,

provided that such termination will not prejudice or affect any right of action or remedy that

has accrued or will accrue thereafter to CCMC .

58

12.3 Termination for Convenience

CCMC may given by written notice, with a notice period of seven days sent to the

Successful Bidder, may terminate the Contract, in whole or in part, at any time for its

convenience. The notice of termination shall specify that termination is for CCMC’s

convenience, the extent to which performance of work under the Contract is terminated, and

the date upon which such termination becomes effective. On termination, the successful

Bidder is not entitled to any compensation whatsoever.

If the installation & commissioning is not effected as specified in the work order, CCMC

shall have the full authority to cancel the order and to take any such action that will be

deemed fit in the circumstances.

13. In case of failure by the Successful Bidder to install and commission the SPV Power

Plants within the period specified or in case of installations made by them, not being of the

stipulated quality and specifications. CCMC shall have the power to reject any such

installations.

14. In case of any dispute, the matter will be referred to a sole Arbitrator to be appointed by

the Chairman and Managing Director, CCMC accordance with the Arbitration and

Conciliation Act 1996. The arbitration shall be held in Chennai, India and the language

English only.

15. Subject to the above, the Courts at Chennai alone only shall have jurisdiction in the

matter.

In Witness whereof the parties hereto have signed on the day, month and year above

written in the presence of

For and on behalf of


For and on behalf of

Successful Bidder

Witnesses: Witnesses

1.

2.

3

1.

2.

3.

60

Appendix - 3 Bank Guarantee Format

(To be executed in Rs.80/- Stamp Paper)

To

The Commissioner

Coimbatore City Municipal corporation

Coimbatore.

Bank Guarantee No:

Amount of Guarantee:

Guarantee covers from:

Last date for lodgement of claim:

This Deed of Guarantee executed by ……………….. (Bankers Name & Address) having our

Head Office at …………………..(address) (hereinafter referred to as “the Bank”) in favour of

The Commissioner, Coimbatore City Municipal Corporation, Big Bazaar Street, Coimbatore,

Tamil Nadu (hereinafter referred to as “the Beneficiary”) for an amount not exceeding

Rs._______/- (Rupees ________ Only) as per the request of M/s. ______ having its office

address at ___________ (hereinafter referred to as “Supplier”) against Letter of Acceptance

reference ___________ dated __ __ __ of M/s. CCMC . This guarantee is issued subject to the

condition that the liability of the Bank under this guarantee is limited to a maximum

Rs._______/- (Rupees ________ Only) and the guarantee shall remain in full force up to 60

months from the date of Bank Guarantee and cannot be invoked otherwise by a written

demand or claim by the beneficiary under the Guarantee served on the Bank before 2 months

from the date of Bank Guarantee.

AND WHEREAS it has been stipulated by you in the said ORDER that the supplier shall furnish

you with a Bank Guarantee by a Scheduled or Nationalised Bank for the sum specified therein

as security for compliance with the Supplier’s performance obligations for a period in

accordance with the contract.

61

AND WHEREAS we have agreed to give the Agency a Guarantee.

THEREFORE, we (Bankers address)……………., hereby affirm that we are Guarantors and

responsible to you on behalf of the Supplier up to a total of Rs._______/- (Rupees ________

Only) and we undertake to pay you, upon your first written demand declaring the Supplier to be

in default under the contract and without any demur, cavil or argument, any sum or sums within

the limit of Rs._______/- (Rupees ________ Only) as aforesaid, without your needing to prove

or show grounds or reasons for your demand or the sum specified therein. We will pay the

guaranteed amount notwithstanding any objection or dispute whatsoever raised by the

Supplier.

This Guarantee is valid until 60 months from the date of Bank Guarantee.

Notwithstanding, anything contained herein

Our liability under this guarantee shall not exceed Rs._______/- (Rupees ________ Only). This

Bank Guarantee shall be valid up to 60 months from the date of Bank Guarantee and we are

liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only and

only if you serve upon us a written claim or demand on or before 2 months.

In witness whereof the Bank, through its authorized Officer, has set its, hand and stamp on this

…………………………………. at ______.

Witness: (Signature)

(Name in Block Letters)

62

APPENDIX -4 FORMAT FOR SUBMISSION OF PERFORMANCE CE RTIFICATE FROM

THE END USER BY THE SUPPLIER

To Whom so ever it may concern

This is to certify that the SPV Power Plants installed by-----------------------------------------at the

premises of ---------------------------------------------------------on-------------------------- is working

satisfactorily till date.

Signature of the Beneficiary

Name in Block Letters:

Designation:

Organisation

Signature of the Supplier

Name in Block Letters:

Designation:

Company or firm

Date:

Place:

63

Appendix- 5 DRAFT UNDERTAKING IN LIEU OF E.M.D.

(To be furnished in non-judicial stamp paper of val ue not less than Rs.80/-)

THIS DEED OF UNDERTAKING EXECUTED AT __________________ ON THIS THE

________________ DAYOF ________________________________ TWO THOUSAND

AND BY M/s._____________________________________________ a company

registered under companies Act 1956, having its registered office at

_________________ hereafter called “Tenderer” (which expression shall where the context

so admits mean and include their Agents, Representatives, Successors-in-office and

Assigns)

TO AND IN FAVOUR OF COIMBATORE CITY MUNICIPAL CORPORATION having its

office at Coimbatore City Municipal Corporation, Big Bazaar Street, Coimbatore, Tamil

Nadu herein called the “ CCMC ” (which expression shall where the context so admits mean

and include its successors in office and Assigns).

WHEREAS the tenderer is required to pay Earnest Money Deposit of Rs.________ for

participation in the tender for supply and installation of ___________________in terms of

specification No. _________________________________ AND WHEREAS the tenderer is

exempted from payment of EMD as per ______________________, subject to the tenderer

executing an undertaking to the value of Rs.___________ (Rupees

_______________________________________only) representing the amount equivalent

to the amount of EMD specified to be paid to CCMC in the event of non-fulfillment or breach

of any of the conditions of the tender by the Tenderer as mentioned here under. AND

WHEREAS in consideration of the acceptance by CCMC of the above proposal, The

tenderer has agreed to pay to CCMC the said amount of Rs.______________ in the event

of :-

i. Withdrawing his tender before the expiry of the validity period

ii. Withdrawing his tender after acceptance or fails to remit the Security Deposit.

iii. Violating any of the conditions of the tender issued by the competent authority.

64

NOW THE CONDITION OF THE above written undertaking is such that if the tenderer shall

duly and faithfully observe and perform the conditions specified as above, then the above

written undertaking shall be void, otherwise it shall remain in full force.

The tenderer undertakes not to revoke this guarantee till the contract is completed under

the terms of contract.

The expression, ‘tenderer’ and ‘ CCMC’ hereinafter before used shall include their

respective successors and assign in office.

IN WITNESS WHERE OF THIRU__________________________________________

acting for and on behalf of the Tenderer has signed this deed on the day, month and year

herein before first mentioned.

SIGNATURE

NAME IN BLOCK LETTERS

SEAL OF THE COMPANY

In the presence of Witnesses

Signature

Name and Address

Signature

Name and Address

65

Appendix- 6 ACCREDITED TEST CENTRES FOR MNRE GRID T IED PROGRAMME

Lab/Organization PV Module Battery Inverter > 200W

Efficiency Environmental

SEC Yes (IEC61215up

to 200Wp) NABL

Accredited

Yes MNRE

Accredited

Yes (up to

10KVA) MNRE

Accredited

Yes (Including IP)

MNRE Accredited

ERTL (east) STC Test Facility

MNRE Accredited

Yes up to 2000

AH

Yes NABL/

MNRE Accredited

Yes

NABL/MNRE

Accredited

ETDC (B) Yes

(IEC61215)under

ICEEE-CB, IEC

61701

(upto200Wp)NAB

L Accredited

Yes up to 200 AH Yes (up to 3KVA)

NABL/ MNRE

Accredited

Yes

NABL/MNRE

Accredited

CPRI (B) No Yes up to 500 AH Yes (up to

10KVA) NABL/

MNRE Accredited

Yes

NABL/MNRE

Accredited

ERTL (N) No No Yes (up to 5KVA)

NABL Accredited

Yes

NABL Accredited

UL (B) Yes (IEC61215

IEC 61730 Pt.II

and IEC 61701)

up to 400Wp

NABL Accredited

No Yes (up to 6KVA)

NABL/ MNRE

Accredited

Yes

NABL Accredited

TUV Rhineland Yes (IEC61215 &

61730 Pt-II)

upto400Wp NABL

Accredited

No Yes (up to

10KVA) NABL

Accredited

Yes

NABL Accredited

Inter Tek No No Yes (up to 5KVA)

NABL Accredited

Yes

NABL Accredited

66

Coimbatore corporation

Invitation for Expression of Interest (EOI)” from M NRE approved channel

partners for setting up of Solar PV Power Plant of capacity 50 KW

connected to grid tied at Main Office, Coimbatore C orporation

Tender Ref:

Price Bid (Envelope-B)

Tender Details


Coimbatore

67

PRICE BID FOR 50 KW SOLAR POWER PLANT

(As per Approved technical specifications in annexure)

S.No Particulars Cost per system (Rs.)

1 Design, Supply, Installation & Commissioning of 50 KW, Solar Power Plant.

2 Taxes if any & CST or VAT

3 Total cost of solar system inclusive of solar wiring

Rupees in words ----------------------------------- --------------------------------------------

Cost per system is inclusive of all taxes, excluding CST or VAT, insurance, octroi,

transportation, loading-unloading, installation, testing & commissioning and CMC for 5

years. The amount of CST or TNVAT and percentage shall be indicated explicitly &

separately.

Quantity offered ________ ( in words ____________________ numbers)

(Signature of the authorized signatory)

Date: Name___________________

Designation______________

Place : Company seal

68

BILL OF MATERIAL

Sl.No

.

Description Total Qty UOM Cost of

each

Rs.

Total Cost

Rs.

1 SPV module –

(minimum 200 Wp, crystalline module)

As per the capacity

of module

Nos

2 Module mounting structure Suitable for Sl.No 1 Set

3 Inverter Suitable for Sl.No 1 No

4 MCBs & Switches

5 Solar wiring

6 Civil works

7 Others, if any, please specify separately

8 Ex Works price ( sum of 1 to 11)

9 Packing & Forwarding , Freight & Insurance

charges etc ., ( shall be indicated separately)

10 Duties or Taxes (shall be indicated separately

with %)

11 All Inclusive price per system

69

12 Installation & Commissioning

Total Cost / system

Note 1. In case of discrepancy between the cost quoted in words and in figures , the lower of the

two will be considered . ( Total cost offered should be both in figures and words)

Rupees in words ----------------------------------- --------------------------------------------

(Signatures of the authorized signatory)

Name___________________

Designation________________

Name & Address of the Bidder

Stamp of Bidder

Date :

Place:

COIMBATORE CITY MUNICIPAL CORPORATION · PDF file7 IEC International Electro technical...

Documents

Transcript of COIMBATORE CITY MUNICIPAL CORPORATION · PDF file7 IEC International Electro technical...