Avaya V15.1 Implementation Alpharetta, GA 30005 ( ^Adtech Global) and TSG, A TeleTech Company, with...
Transcript of Avaya V15.1 Implementation Alpharetta, GA 30005 ( ^Adtech Global) and TSG, A TeleTech Company, with...
Presented to:
TSG, a TeleTech Company - Newell Rubbermaid
Revised April 2016
Version 7.0
Avaya V15.1 Implementation
Written by:
John Randall
Services Architect
(678) 679-2034
Pre-sales:
Kent Pylant
Solution Architect
(678) 679-2036
1880 McFarland Parkway, Suite 100
Alpharetta, GA 30005 USA
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 2
Statement of Work
This Statement of Work (“SOW”) is entered into as of May 23, 2016 (the “Effective Date”), by and between Adtech
Global Solutions, Inc., a Texas corporation, with a principal place of business at 1880 McFarland Parkway, Suite
100, Alpharetta, GA 30005 (“Adtech Global”) and TSG, A TeleTech Company, with a principal place of business at
2575 White Oak Circle, Aurora, IL 60502 (“Customer”). This SOW outlines the Services and deliverables for Adtech
Global’s Professional Services within the Customer Environment.
Table of Contents
1. SOLUTION OVERVIEW ....................................................................................................................3
2. SOFTWARE PRODUCTS TO BE IMPLEMENTED ..................................................................................4
3. METHODOLOGY REVIEW ................................................................................................................6
4. IMPLEMENTATION TASKS OVERVIEW .............................................................................................7
5. TRAINING OVERVIEW .....................................................................................................................8
6. CUSTOMER RESPONSIBILITIES .........................................................................................................9
7. PROJECT SCHEDULING .................................................................................................................. 10
8. CHANGE REQUEST PROCEDURES ................................................................................................... 10
10. TRAVEL & LIVING EXPENSES ........................................................................................................ 11
11. INVOICE SCHEDULE ..................................................................................................................... 11
12. SIGNATURES............................................................................................................................... 12
ATTACHMENT 1 - TRAINING DESCRIPTIONS ...................................................................................... 13
SCHEDULE A - DEFINITIONS .............................................................................................................. 19
SCHEDULE B – GENERAL TERMS AND CONDITIONS ............................................................................ 21
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 3
1. Solution Overview Adtech Global will install and configure an additional SSL Enabled Avaya Contact Recorder (ACR) into the existing Avaya V15.1 solution for the Poland Site.
Adtech Global Quote Number: AGQQ2306
Sites: Poland
End User Point of Contact/Project Manager Contact Information:
David R Nixon
EMEA Information Technology
Newell Brands
Office:- +44 (0) 191-511-5505
Mobile:- +44 (0) 7899-991-744
[email protected] Hardware: Customer Furnished Servers (Detailed in CFE Guide provided by Adtech Global)
Servers (Summary)
Location Server Role Platform Flavor QTY
Poland Recording Server Slave Avaya Contact Recorder - Linux 1
Total Number of Servers 1
Additional Customer-Furnished Equipment Items (Summary)
Item Name QTY
Archive Storage 12 GB
License Count: 70 Named Users
License Provider: TSG, a TeleTech Company
Telephony Environment: Avaya CM v6.3 / AES v6.3 (Based in UK Data Center)
Recording Mode: DMCC
Business Units in Scope: Human Resources (two sites in Poznan, Poland)
Services included in SOW Adtech Global will manage and complete the implementation of the Avaya version 15.1 solution per the listed milestones. Adtech Global will provide Verint Certified Engineers for the execution of this SOW. Each Service below is defined in Schedule A: Definitions.
☒ Implementation Design
☒ Installation
☐ Migration
☒ Site Acceptance Testing
☒ Training
☐ Other ______________
☒ Readiness Validation
☒ Integration
☐ UAT Participation
☐ Multi-site / Multi-phase Rollout
☐ Cutover Support
☐ First Business Day Support
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 4
2. Software Products to be Implemented
Framework
Feature In Scope Feature In Scope
Standard Reporting Ad-Hoc Reporting
Data Center Redundancy High Availability
Other [Insert Here] Other [Insert Here]
Recording/QM
Feature In Scope Feature In Scope
Voice Recording Search and Replay
ACD Adapter Recorder Redundancy
Record on Demand Real Time Monitoring
Archiving Custom Call Tagging (via CTI), Up to
[Number]
Screen Capture Telephone Playback
Agent-Initiated Monitoring Import Manager
Quality Monitoring – Evaluations and Forms
Intelligent Recording Add-On
Quality Monitoring - Coaching ACR Data Migration
Workforce Management (WFM)
Feature In Scope Feature In Scope
Forecasting and Scheduling Adherence
Time Off Manager Strategic Planner
Time Banking Blended Media Integration
Time Accrual Shift Bidding
Time Record Export Adapter (Payroll Adapter)
Screen Pop-Up Alerts
Outbound Scheduling (Dialer) WFM Migration
Queue Hopping Custom ACD Integration
Campaign Pooling Additional Switch (WFM) (Separate
Adapters)
Historical Data Import1 Additional Adapters [qty]
1F&S only – File & data format must meet Verint
CSI adapter requirements. Adherence data import is not supported and not in scope.
Other [Insert Here]
Other [Insert Here]
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 5
Security
Feature In Scope Feature In Scope
High Security Environment PCI Compliant Environment
SSL Enablement (In Transit, for up to 1 server)
Encryption Management
(KMS/RSA at rest)
Other [Insert Here] Encryption Management
Redundancy
Performance Management
Feature In Scope Feature In Scope
Advanced Scorecards (existing source data)
Lesson Management
Scorecards with External Integrations2
Coaching
Mobile Application Intraday
Historical Data Import3 Gadgets 2Requires Scorecards External Integration
Adapter and integration services 3File & data format must meet Verint ASCM
adapter requirements
Desktop and Process Analytics4
Feature In Scope Feature In Scope
Advanced Desktop Analytics Pause & Resume
Triggers Up to 10 Custom Data Tagging 4ADA functionality is reliant on the success of an ADA Validator test, which validates the ability to build triggers off
the target application(s). ADA Validator must be tested on all variations of the Customer’s desktop environment. It is expected that the target application is a consistent application and there is only one version across the enterprise. During the testing of ADA’s ability to monitor the target application, trigger points will need to be identified and validated.
Customer Feedback
Feature In Scope Feature In Scope
Customer Feedback IVR with VVS Customer Feedback IVR Plus Web
with VVS
Customer Feedback IVR with VXML Customer Feedback IVR Plus Web
with VXML
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 6
Speech Analytics
Feature In Scope Feature In Scope
Advance Speech (ENGLISH ONLY)
LAC Tuning
Speech Essentials
Other [Insert Here]
Miscellaneous
Feature In Scope Feature In Scope
SSO LDAP
Verint SDK [Note any service limitations]
Other [Insert Here]
3. Methodology Review Adtech Global will perform the professional services and deliverables as set forth below. These milestones represent the most significant events and provide a basis for tracking implementation progress.
Milestone 1 - Kick-Off & Planning o Project team assembled o Planning documentation introduced o Design and scope confirmed o Review training curriculum o Timeline set and approved
Milestone 2 – Implementation Design o Design workshops scheduled o CFE Guide reviewed o Design documents reviewed –Site Prep Checklist (SPC)
Milestone 3 - Hardware and Software Readiness o Server hardware purchased and provisioned o Avaya software ordered and delivered o License keys obtained and delivered by license provider o Design documents (SPC) completed by Customer o Design documents (SPC) approved by Adtech Global o Pre-Install training course credits provided
Milestone 4 - Readiness Validation o Server validation test completed and report uploaded o Customer readiness assessment completed o Customer provides network accessible location to place Verint software for installation
Milestone 5 - Product(s) Installation o Avaya software installed o Install report is initiated o License keys are activated
• Milestone 6 - Product(s) Integration and Site Testing o Software configuration o Telephony integration o Adapters created
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 7
o Site acceptance testing
Perform Verint’s provided site acceptance test plan for modules in scope. Adtech Global SE will perform and initial SAT to ensure proper system operation. Adtech SE will then perform SAT in witness of Customer (Live or web conference) who
will then approve results. Adtech Global SE will provide approved SAT and Installation Report.
o Knowledge transfer o Install report completed o Confirmation of services signed
Milestone 7 - Training o Training checklist and readiness o Onsite training o Soft copies of the student training portfolio o Self-paced or webinar classes
Milestone 8 - Consulting and Technical Reviews o Application consultant review o Install report and SAT review
Milestone 9 – Project Completion o Project documentation delivery to Customer o Project complete
Milestone 10 - Project Closeout o Project closure
4. Implementation Tasks Overview
The implementation will be accomplished in the following manner with the primary tasks outlined below:
1. Design and Implementation Documentation (Customer and Adtech Global) o SPC documents tailored and delivered by Adtech Global o SPC reviewed by Customer and Adtech Global o Applicable Deployment Reference Guides provide to Customer by Adtech Global o Firewall Ports document tailored and delivered by Adtech Global o DRGs reviewed and utilized for server/VM/SQL commissioning by Customer o SPC completed by Customer
2. Server Hardware and Software Deployment (Customer and Adtech Global) o Physical server(s) racked or virtual server(s) provisioned by Customer o Hardening of Server(s) completed by Customer as specified in the SPC system admin tab o Server(s) added to Customer network domain by Customer o Required firewall ports opened by Customer o Server validation tool completed by Customer and Adtech Global
3. Product Installation(Customer and Adtech Global) o Domain accounts provided by Customer o Update all service packs and patches by Adtech Global o Software installed by Adtech Global o Licensing completed by Adtech Global o Agent and supervisor desktop clients software deployed by Customer o Test equipment (Desktops) configured by Customer and Adtech Global
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 8
4. Product Integration (Customer and Adtech Global) o Enterprise system administration configured o Voice capture mode configured o Extensions to be recorded added by Customer o CTI connectivity confirmed o Screen capture configured
o Customer deployment of screen capture client completed o Playback functionality confirmed o Archive configured o SSL server certs added to ACR o Alarms configured
5. Testing and Knowledge Transfer(Customer and Adtech Global) o Site acceptance testing completed and Confirmation Of Services (COS) signed (Defined below in
Section 7 – Project Scheduling). o Knowledge transfer by Systems Engineer completed
6. Installation Documentation(Customer and Adtech Global) o Install report completed o COS for installation and integration (obtained by Project Manager)
5. Training Overview Adtech Global will, as part of the implementation methodology, coordinate all training that is within the scope of this project. The training milestone includes pre-install and post-install training delivered by Adtech Global. Customer will need to identify training candidates by completion of Milestone 2. Any delay in this identification may cause delays to the project and possible financial penalties. Pre-Install training occurs two weeks prior to Product Integration. Post-install training occurs two weeks after testing is complete. All training credits & courses, whether performed onsite, via University course, remote site, or virtually, will be delivered to US sites during US Business Hours unless otherwise expressly stated in this SOW. Descriptions of all available training courses can be found in Attachment 1 - Training Descriptions. Table 5.1 below identifies the training that is in scope. Table 5.1 Note: Delivery codes – U - University, CS – Customer Site, VPR - Virtual Private and VPU - Virtual Public
Educational Services Summary Pre/Post Participants Duration Credits Delivery
Enterprise – System Administration Pre 1 2 days 2 U
Enterprise – Troubleshooting Post 1 2 days 2 U
Enterprise – Unified User Management Post 1-10* 1 day - CS
Recorder – ACR Knowledge Transfer Post 1 4 hours - CS
QM – Application Administration Post 1-10* 1 day - CS
QM – Forms Designer and Administration Post 1-10* 1 day - CS
QM – Interactions for End Users Post 1-10* 1 day - CS
QM – Enterprise Reporting Post 1-10* 1 day - VPR
QM – Coaching Post 1 1 day 1 VPU
*1 Group of up to 10 participants
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 9
6. Customer Responsibilities
Implementation pre-requisites:
A supported version of Windows™ OS, Internet Explorer™, Java™ and any other third party software is required on each Supervisor machine that is to be used
Adtech Global System Engineer(s) allowed Administrator access to the system where software is being installed
Provide Adtech Global with remote access to Customer equipment in connection with Adtech Global’s performance of its obligations hereunder, specifically the initial installation of the Software
Configure their network, where applicable, per Verint installation manual(s) and Deployment Reference Guides (DRGs). Details to be discussed during the Project Kick-Off-Meeting
Provide adequate power and network connectivity for installed equipment • Prepare and maintain the Site of the equipment in accordance with manufacturer's specifications • Providing backup of all software and data as well as safeguarding all programs, data, and removable
storage media • Providing all licensing and configurations required to properly interface the PBX/ACD environment to the
Verint applications (Please consult your PBX/ACD vendor for clarification) • Providing training facilities for all onsite training • Purchasing and maintaining Security Certificates for SSL Encryption. Certificates must adhere to all
Software manufacturer: Readiness Validation requirements
Modifications Prohibited The Customer should not make any modifications to the system hardware and/or software post Milestone 4 completion without notifying Adtech Global. In such event, Adtech Global will be under no obligation to provide any service until such time as the issue is resolved to the satisfaction of Adtech Global. Any delays caused by such changes may be subject to additional costs and may impact project timelines. Any delay shall extend any agreed-upon deadlines or target dates for Adtech Global.
Security Scans Adtech Global shall have no responsibility or liability whatsoever under this SOW arising or resulting from Customer’s security scans, third party vulnerability scans and/or services related to, or participation in other security related system tests or activities such as server or database hardening. If Adtech Global provides any scans or related security services to Customer specified in this section or otherwise outside the scope of any Services agreed to between the parties, Adtech Global will quote an additional Time and Material services engagement upon the completion of implementation of system, training, acceptance and confirmation of services. All additional services will be set forth in a separate SOW.
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 10
7. Project Scheduling Customer shall request scheduling for Services with reasonable notice. Adtech Global shall use reasonable efforts to meet the requested time schedules and scheduling is dependent upon the allocation and availability of resources. Project success requires that each milestone is met by dates mutually agreed to by both parties. Adtech Global will charge Customer a fee equal to 10% of the total Services for any delay by Customer that impacts an agreed upon milestone. Customer shall reimburse Adtech Global for all expenses Adtech Global cannot reasonably recover due to delays.
In the event the Customer has substantial delays and fails to adhere to the scheduled delivery training dates, Adtech Global will continue to the next scheduled milestones until Milestone 10 (Project Closeout) is completed. Adtech Global will not be held accountable to deliver training at the original agreed upon scheduled time. The remaining deliverable of training will be delivered according to the Customer’s schedule and Adtech Global’s resource availability, however, the Customer agrees that project COS documents must be approved according to the original and agreed upon schedule. Substantial Delays shall be defined as any delay caused by Customer after initial training is scheduled. Notwithstanding the preceding, if after completion of Milestone 6: Product(s) Integration and Site Testing, the solution installed for this project is affected as a result of Customer’s misuse, abuse or negligence, Adtech Global will re-perform SAT Testing and resolve the issue(s) and Customer will be charged appropriate fees.
Time Period of Services – Except as otherwise expressly provided, the services will be performed during normal
Business Hours (9:00 A.M. to 5:00 P.M., Monday through Friday except Adtech Global holidays).
Confirmation of Services – Adtech Global will obtain a signed COS at the completion of each milestone. It is
understood that Customer’s roll out plan is not considered part of this SOW.
Support Turnover & Project Completion Milestone This milestone serves as the transition of the project from
implementation services to support.
8. Change Request Procedures If it is determined that any changes to the SOW are required, the Customer shall submit a Change Request Form provided by your Project Manager. The following procedures will be used to process a Change Request:
• The Customer will complete the top portion of the Change Request Form. The Change Request Form will bear a unique reference number and will outline the requested change and the reason for the request. The client must sign the Change Request Form before sending to Adtech Global.
• Adtech Global will evaluate the request to determine whether or not the requested change(s) are within the scope according to the SOW. Adtech Global will then evaluate potential project impact with regard to the schedule and costs, and complete the middle section of the Change Request Form. Adtech Global will provide a quote for the change and review schedule impact and cost with Customer. The Customer will then inform Adtech Global whether to go forward with, or cancel, the Change Request Form.
• If the Change Request is approved, Adtech Global and the Customer will sign off on a changed order. The customer will then provide a Purchase Order to Adtech Global within ten (10) business days. Adtech Global will then outline and send the Customer notification of any amended completion dates.
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 11
10. Travel & Living Expenses Any out-of-pocket expenses incurred by Adtech Global employees in the course of performing services in this SOW, such as lodging and travel expenses, will be billed to Customer. Customer shall pay the amounts set forth within each invoice within thirty (30) days of receipt of the applicable invoice. Travel will be booked adherent to the Adtech Global travel policy. Adtech Global employees required to travel under this SOW shall travel in business class for any flight over 10 hours in duration (direct flights, non-stop).
Item Guideline
Airfare Flights that would exceed $1,500 round-trip airfare will require approval
Room, Board and Misc. Lodging $250 per day (inclusive of tax)
Meals $50 per day
Car Rental and Gas $100 per day
11. Invoice Schedule
Adtech Global will invoice Customer by the following schedule: 50% upon Milestone 2 –Implementation Design
and the remaining 50% upon completion of Milestone 9 – Project Completion and Support Turnover.
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 12
12. Signatures
Adtech Global and Customer have caused this SOW to be executed by their duly authorized representatives as of
the Effective Date.
TSG, a TeleTech Company Adtech Global Solutions, Inc.
Name:
Date:
Name:
Date:
Signature:
Title: Signature:
Title:
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 13
Attachment 1 - Training Descriptions Training items in scope are identified in ‘Section 5 - Training Overview’ of the SOW. The courses listed below are for reference information only.
Pre- Install Training University Courses
Course Title # of Participants Duration Credits
Enterprise - System Administration This course is designed to provide System Administrators with the theoretical and practical knowledge needed to successfully configure, maintain, and troubleshoot the Enterprise Management suite. Audience: System Administrators
1 2 days 2
Course Title # of Participants Duration Credits
Enterprise – Troubleshooting This course will teach consistent fact gathering concepts to ensure proper information gathering as part of the troubleshooting process. Audience: System Administrators
1 2 days 2
Course Title # of Participants Duration Credits
Recorder – System Administration This course is designed to enable system administrators and other technical professionals to manage and maintain the Recorder(s) in their environment. This course focuses on topics and functions that are specific to Recorder. Audience: System Administrators & Recorder Administrators
1 2 days 2
Course Title # of Participants Duration Credits
Recorder - Archive Administration This course is designed to enable Archive administrators and other technical professionals with the theoretical and practical knowledge needed to successfully configure, maintain, and troubleshoot Archiving in their environment. Audience: Archive Administrators
1 4 hours 0.5
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 14
Post- Install Training
Customer Site Training
Course Title # of Participants Duration Credits
Enterprise – Unified User Management This includes unified user management, user security management, hierarchy structures and group management for all applications. Audience: Application Administrators
1 group (up to 10) 1 day -
Course Title # of Participants Duration Credits
QM - App Administration This includes configuring system, settings, establishing rules, customizing the inbox and managing the application. Audience: Application Administrators
1 group (up to 10) 1 day -
Course Title # of Participants Duration Credits
QM - Forms Designer and Administration This includes the building and designing of evaluation forms in the Forms Designer tools. Audience: Form Administrators
1 group (up to 10) 1 day -
Course Title # of Participants Duration Credits
QM - Interactions for End Users This includes configuring system settings, establishing rules, customizing the inbox and managing the application. Audience: Application Administrators
1 group (up to 10) 1 day -
Course Title # of Participants Duration Credits
WFM - Core Forecasting and Scheduling This course is designed to provide users in the traditional scheduler role with the theoretical and practical knowledge needed to use the Software successfully. Audience: WFM System Administrators, Forecasting workload, Scheduling agents & scheduling publishing
1 group ( up to 10) 3 days -
Course Title # of Participants Duration Credits
WFM Advanced Forecasting and Scheduling This course is targeted towards individuals who are or will be responsible for the hands-on usage of the Workforce Management package for defining shifts, forecasting workload, schedule publishing. Audience: WFM System Administrators, Forecasting workload, Scheduling agents & scheduling publishing
1 group ( up to 10) 1.5 days -
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 15
Course Title # of Participants Duration Credits
WFM - Application Administration The focus of this training is a strong understanding of the Workforce Management package’s capabilities and detailed instruction in its usage. Training provides a blend of theory, process modeling and practice to provide you with an effective hands-on experience. Audience: WFM Administrator
1 group ( up to 10) 1 day -
Course Title # of Participants Duration Credits
WFM - Monitoring and Management An expert trainer will work with you to make necessary modification to this course to include any specific needs based on your organization’s work processes, culture, and optionally purchased components of the Workforce Management package. Audience: WFM users managing and monitoring scheduling request, contact statistics, schedule adherence
1 group ( up to 10) 1.5 days -
Course Title # of Participants Duration Credits
WFM - Strategic Planner Strategic Planner is a strategic decision-making tool that can estimate staff hour requirements, performance, and costs. Strategic Planner helps you to compare what-if scenarios, generate staffing plans, and create long term forecasts. Audience: Schedulers, Managers, directors or vice presidents
1 2 days -
Course Title # of Participants Duration Credits
WFM – Blended Media This course is an add-on component to Workforce Management training and includes non-voice channels such as email and chat. Audience: Schedulers, Managers, directors or vice presidents
1 1 day -
Course Title # of Participants Duration Credits
WFM – Time Off Manager This course is an add-on component to Workforce Management training and includes how to use the Time Off module. Audience: Schedulers, Managers, directors or vice presidents
1 4 hours -
Course Title # of Participants Duration Credits
WFM – Shift Bidding This course is an add-on component to Workforce Management training that explains how to use the Shift Bidding module. Audience: Schedulers, Managers, directors or vice presidents
1 4 hours -
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 16
Course Title # of Participants Duration Credits
WFM – Time Banking This course is an add-on component to Time Off Manager and explains how to use Time Banking. Audience: Schedulers, Managers, directors or vice presidents
1 1 day -
Course Title # of Participants Duration Credits
WFM – Time Accrual This course is an add-on component to Time Off Manager and explains how to use Time Accrual. Audience: Schedulers, Managers, directors or vice presidents
1 2 hours -
Course Title # of Participants Duration Credits
WFM – Outbound Scheduling This course is an add-on component to Workforce Management training and includes how to forecast and schedule for Outbound Calling activities. Audience: Schedulers, Managers, directors or vice presidents
1 1 day -
Course Title # of Participants Duration Credits
WFM – Queue Hoping This course is an add-on component to Workforce Management training and explains how to schedule agents who are scheduled for different work queues throughout the day. Audience: Schedulers, Managers, directors or vice presidents
1 2 hour -
Course Title # of Participants Duration Credits
WFM – Campaign Pooling This course is an add-on component to Workforce Management training and explains how to combine scheduling campaigns in order to optimize the agent schedules. Audience: Schedulers, Managers, directors or vice presidents
1 2 hour -
Course Title # of Participants Duration Credits
Analytics – Adv Desktop Administration Course includes one (1) day of system administration for managing users, administration and management of DPA groups, administering application components, and administration and management of the client (desktop) components; a two (2) day workshop for building, administering and managing triggers for trigger developers. Audience: Application Administrators, Supervisors, End Users, and Business Users
1 3 Days -
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 17
Virtual Classes
Course Title # of Participants Duration Credits
Analytics – Adv Desktop Administration Consulting Audience: Application Administrators, Supervisors, End Users, and Business Users
1 3 Days -
Course Title # of Participants
Duration
Credits
QM Enterprise Reporting This course is designed to refresh and extend your knowledge of Software standard reports, Ad Hoc Reporting, and the reports that can be used to analyze Speech Analytics data. Audience: Data Reporting Analyst
1 1 Day 1
Course Title # of Participants
Duration Credits
QM – Coaching This course is intended for individuals who are or will be responsible for configuring the Coaching functionality in the Software application, setting up coaching sessions for coaches and trainees in the Coaching module, and using the Forecasting and Scheduling functionality to schedule coaching sessions. Audience: QA Specialist, Supervisors, Managers
1 1 day 1
Course Title # of Participants Duration Credits
WFM - Ad Hoc Reporting This course will help you to gain an understanding of the task and processes required for creating and managing Standard and Ad Hoc reports in the Workforce Management package. Audience: Supervisors, Managers & Business Analyst responsible for WFM reporting
1 1.5 days 1.5
Course Title # of Participants
Duration
Credits
PM - Advanced Scorecards The Advanced Scorecards application provides users a view of their individual performance and team performance by presenting a scorecard made of Key Performance Indicators (KPIs). The KPIs on a scorecard track the performance of an individual or group with measures such as Average Handle Time or Service level. Audience: Supervisors, Managers, Schedulers & Administrators utilizing the Advanced Scorecard Application
1 2 days 2
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 18
Course Title # of Participants
Duration
Credits
PM - Advanced Scorecards Ad Hoc Reporting The Advanced Scorecards application provides users a view of their individual performance and team performance by presenting a scorecard made of Key Performance Indicators (KPIs). The KPIs on a scorecard track the performance of an individual or group with measures such as Average Handle Time or Service level. Audience: Supervisors, Managers, Schedulers & Administrators utilizing the Advanced Scorecard Application
1 1 days -
Course Title # of Participants
Duration
Credits
PM - Lesson Management This course is targeted towards individuals who will be using the Lesson Management application to create, upload, and assign lessons to employees and to track employee lesson assignments and results. Audience: Supervisors, and Managers responsible for using the Lesson Management application
1 1 day 1
Course Title # of Participants
Duration
Credits
PM – Coaching This course is intended for individuals who are or will be responsible for configuring the Coaching functionality in the Software application, setting up coaching sessions for coaches and trainees in the Coaching module, and using the Forecasting and Scheduling functionality to schedule coaching sessions. Audience: QA Specialist, Supervisors, Managers
1 1 day 1
Course Title # of Participants
Duration
Credits
Analytics – Adv. Desktop Enterprise Reporting Course includes an overview of Desktop Analytics capabilities and features, creating and managing Desktop Analytics enterprise reports Audience: End Users, Business Users
1 4 hours
Adtech Global____TF_____ CONFIDENTIAL INFORMATION Customer________
P a g e | 19
Schedule A - Definitions This Schedule A is made a part of the Statement of Work signed by the parties on the Signature Page to which this Schedule A is attached. All capitalized terms shall have the meaning ascribed to them, including the following:
1. Definitions. In addition to the terms defined elsewhere in this
SOW, the following terms shall have the meanings set forth below:
1.1 “Business Hours” means hours between 9:00 AM – 5:00 PM, on
Business Days unless otherwise agreed in this Statement of Work.
1.2 “Business Days” means a five (5) day working week, Monday through Friday except Adtech Global holidays.
1.3 “Customer Environment” means the computing environment
(excluding any software and/or hardware expressly provided by
Adtech Global on an Order) separately procured, prepared and
maintained by Customer for the use and operation of Product,
where such computing environment meets Adtech Global’s then-
current minimum Product requirements.
1.4 “Cut-over Support” means engineering support provided during the
process of completing to the new implementation. This includes up
to 8 hours of consecutive engineering time during the period of
cut-over unless otherwise specified in this Statement of Work.
1.5 “Documentation” means Customer documentation describing the
Software and its use in the Customer Environment.
1.6 “End User” means the entity specified on the Statement of Work
that is under the terms of this SOW.
1.7 “Fees” means any fees as specified in this Statement of Work or on
any Order.
1.8 “First Business Day Support” means engineering support provided
for the first operational day of business post cut-over. This includes
up to 8 hours of consecutive engineering time during normal
Business Hours on Business Days if and only if purchased Support
from Adtech Global.
1.9 “Hardware” means computer and related equipment provided by
Adtech Global to Customer hereunder (if any) as specified on an
Order. The term “Hardware” shall not include any hardware that is
required as part of the Customer Environment.
1.10 “Implementation Design” means solution design documents
created by an Adtech Global.
1.11 “Integration” means configuration of the Software to integrate with
Customer Environment (switch, desktops…etc.).
1.12 “Intellectual Property Rights” means any and all tangible and
intangible rights, title and interest in and to: (i) works of
authorship, including but not limited to copyrights, neighboring
rights, moral rights, and mask works, and all derivative works
thereof, (ii) trademarks and trade names, (iii) Confidential
Information, trade secrets and know-how, (iv) patents, designs,
algorithms and other industrial property, (v) all other intellectual
and industrial property rights whether arising by operation of law,
contract, license, or otherwise, and (vi) all registrations, initial
applications, renewals, extensions, continuations, divisions or
reissues thereof now or hereafter in force.
1.13 “Installation” means the process of installing the Software to each
of the validated servers. It does not include other third-party
software (OS, SQL…etc.).
1.14 “Migration” means the process of migrating applicable data from a
customer’s existing Software system to a new implementation.
Specific components to be migrated will be individually scoped in
this SOW, Section 2 - Software Modules to be implemented.
1.15 “Multi-site / Multi-phase Rollout” means Customer’s business
needs or site logistics make it necessary to have multiple phases of
implementation and or training within the single project.
Implementation for all sites and training for all sites will be
scheduled at roughly the same time unless otherwise expressly
stated in this SOW. If this option is required, this SOW will be
customized to identify which site or sites will be implemented or
trained together and milestones and terms adjusted accordingly.
1.16 “Order” means the details of an order by Customer for a Product,
Support and/or Services provided by or through Adtech Global (i)
on an order form or schedule provided by Adtech Global and signed
by Customer, or (ii) on Customer’s purchase order provided to and
accepted by Adtech Global.
1.17 “Personnel” means each employee under obligations of
confidentiality and nondisclosure which Customer authorizes to act
on its behalf in accordance with the terms and conditions of this
SOW.
1.18 “Product” means collectively, the Software and Documentation and
Hardware (if any) that Adtech Global provided to Customer as
identified in an Order or Orders hereunder.
1.19 “Readiness Validation” means assessing the Customer Environment
to validate according to Software specifications and deployment
documentation. A successful validation report from the Server
Validation Tool is required to begin installation.
AG_________ CONFIDENTIAL INFORMATION Customer________
P a g e | 20
1.20 “Server” means each computer server on which the Product is
installed.
1.21 “Services” means the Software installation as detailed in this SOW,
Section 1 Solution Overview.
1.22 “Site” means the physical location of each Server.
1.23 “Site Acceptance Testing” means the activity of verifying the
customer’s successful implementation according to Site Acceptance
Test (SAT) Plan performed by Adtech Global engineer. The SAT Plan
is then reviewed and approved by the customer.
1.24 “Software” means shall mean the Verint proprietary software
licensed to End User.
1.25 "Statement of Work” or “SOW" means a quote, purchase order or
sales order attached hereto that describes the responsibilities,
pricing, and term of the Services for a Customer.
1.26 “Support” means the maintenance and/or support provided for
Product at a Site at the support level specified on an Order and
agreed upon by Adtech Global if and only if purchased from Adtech
Global.
1.27 “Training” means organized activity aimed at imparting information
and/or instructions to improve the recipient's understanding of the
use and best practices of the implemented system or to help him or
her attain a base level of knowledge or skill. Training courses are
conducted via instructor led courses, live or recorded webinars,
and may be delivered onsite or virtually as deemed appropriate by
Adtech Global.
1.28 “UAT Participation” means additional support for Customer’s end-
user acceptance test (UAT) which will be further defined and
scoped in this SOW.
1.29 “Update” means periodic improvements or additions to the
Software, including error corrections and other changes to the
Software.
Adtech Global_________ CONFIDENTIAL INFORMATION Customer_______
P a g e | 21
Schedule B – General Terms and Conditions This Schedule B is made a part of the Statement of Work signed by the parties on the Signature Page to which this Schedule B is attached. The following general terms and conditions shall apply to this SOW:
1. SERVICES TO CUSTOMER. Customer shall obtain all Services from Adtech Global by providing Adtech Global with an Order for such Services, and Adtech Global’s acceptance of such Order.
2. CUSTOMER RESPONSIBILITIES.
2.1. Order Submittal. Customer may submit Orders to Adtech Global, which may be sent via mail, email attachment, electronic procurement systems, and other means as the parties may decide from time to time. Each Order provided by Customer to Adtech Global must reference the name, revision number, and Effective Date of this Statement of Work, and the Adtech Global quote number. 2.2. Customer Environment. Prior to the installation of a Product, Customer shall ensure the establishment of the Customer Environment at each Site for use and operation of the Product. Customer acknowledges that, except as otherwise expressly specified on an Order, Adtech Global is not responsible for obtaining, licensing or selling any hardware, peripherals or third-party software or interfaces needed to prepare or maintain the Customer Environment.
2.3. Services. Any Services provided by Adtech Global hereunder are subject to Customer’s Implementation Design. Customer shall provide and/or acquire for Adtech Global all necessary information, access, workspace, computing resources, and other services and support materials as reasonably required by Adtech Global to perform its duties in a timely manner, including, without limitation, establishing the Customer Environment as specified in Section 2.2. Any development (other than Updates) will only be by written agreement. Adtech Global shall at all times own all Intellectual Property Rights in and to any such development, and such development shall become part of the Services for the purposes of this SOW. Services provided on a time and material basis are per person unless otherwise specified, and charged hourly or daily as indicated for each, and shall be charged in one (1) Day minimum increments. Services purchased on a fixed fee basis shall expire six (6) months from invoice date. “Day” herein shall mean eight (8) hours during any one (1) business day.
2.4. Accurate Records; Audit. Customer shall keep complete and accurate records of all its obligations hereunder. Customer shall allow Adtech Global or its agent reasonable access to audit Customer’s records solely to verify software licenses, inventory of Hardware, and general compliance with the terms and conditions of this SOW; provided Adtech Global shall conduct such audits during Customer’s normal business hours with reasonable notice.
2.5. Compliance with Laws. Customer shall, and shall cause all personnel to comply with all applicable laws and administrative regulations relating to the control of exports of commodities and technical and/or personal data, and all laws directly or indirectly applicable to its activities hereunder or otherwise pursuant to or in connection with this Statement of Work, use of any Product, and the delivery of any Services.
3. ORDERS, SCHEDULING AND SHIPMENTS. 3.1. Order Acceptance. All Orders are subject to Adtech Global’s acceptance, and to the terms and conditions of this SOW. Adtech Global shall acknowledge acceptance of the Order by issuing an invoice in accordance with Section 4. Customer shall, if applicable, be responsible for obtaining all licenses, permissions, or other governmental approvals
necessary for the operation of the Product at each Site. Adtech Global shall have no obligation to deliver any Product, additional licenses, services or technical data, and shall otherwise have the right to withhold performance under this SOW (i) to the extent it has knowledge any licenses, permissions, or other governmental approvals required under then current applicable laws and/or regulations have not been properly obtained by the respective party(ies), or (ii) if Customer is in arrears on any payments rightfully due to Adtech Global or is otherwise in breach of this SOW. 3.2. Scheduling Services. Customer shall request scheduling for Services ordered hereunder with reasonable notice. Adtech Global shall use reasonable efforts to meet the requested time schedule; provided, all scheduling is dependent upon the allocation and availability of resources. If Customer notifies Adtech Global to reschedule or cancel any Services within two (2) weeks prior to the scheduled start date, Customer shall pay Adtech Global a fee equal to twenty-five percent (25%) of the fee that would have been imposed for such Services, plus all expenses Adtech Global cannot reasonably recover.
4. FEES AND PAYMENTS. 4.1. Fees and Expenses. Customer shall pay all Fees and other amounts due to Adtech Global hereunder within thirty (30) days after the date of Adtech Global’s invoice and without deductions, except with respect to any amount disputed in good faith where prior notice is provided to Adtech Global detailing the amount and reason for the dispute. Unless otherwise stated in Section 11 of this SOW, Services are billed 50% upon Milestone 2 –Planning and Design and the remaining 50% upon completion of Milestone 6 – Product Integration and Site Testing. 4.2. Late Payment; Non-Payment; Collections. Time is of the essence in all payment terms. Any amounts not paid to Adtech Global when due shall bear interest at the rate of eighteen percent (18%) per annum, or the maximum legal rate if less, commencing with the payment due date. Customer shall reimburse Adtech Global for all costs of collection, including reasonable attorneys' fees.
4.3. Taxes, Assessments and Other Charges. All amounts due to Adtech Global hereunder are net amounts, exclusive of, and Customer is responsible for paying, all duties, sales or value added taxes, customs duties, GST, tariffs, or other similar taxes, assessments, or excises, however designated or levied. No reduction, deduction or off-set may be made by Customer for any reason whatsoever. Customer is also responsible for all shipping and handling charges for each shipment hereunder.
5. WARRANTIES; DISCLAIMER. 5.1. Joint Warranties. Adtech Global and Customer each warrants and represents to the other that it has full right, power, and authority to enter into and perform under this SOW, and the person signing this SOW is properly authorized and empowered to bind such party. 5.2. Limited Warranty.
Adtech Global_________ CONFIDENTIAL INFORMATION Customer_______
P a g e | 22
5.2.1. Performance Warranty. Adtech Global warrants to Customer that for a period of thirty (30) days after performance, the Services provided by Adtech Global hereunder were performed in a timely and professional manner by qualified personnel. 5.2.2. Exclusions. Notwithstanding the preceding warranties, Adtech Global shall have no responsibility or liability of any kind, whether for breach of warranty or otherwise, arising or resulting from:
5.2.2.1. Customer’s failure to: (i) correctly install any Updates or other modifications to the Product provided by Adtech Global, (ii) prepare a computing environment that meets the specified Customer Environment prior to Product installation or to maintain such Customer Environment and Product thereafter, (iii) grant access and security authorization, or (iv) provide necessary communications mechanisms; 5.2.2.2. Errors resulting from misuse, abuse, negligence, or improper use of all or any part of the Product; or problems to or caused by products or services not provided by Adtech Global; 5.2.2.3. Product modification, amendment, revision, or change by any party other than Adtech Global or Adtech Global’ representative expressly authorized to make such modification, amendment, revision, or change; or 5.2.2.4. Problems, or data or data input, output, integrity, storage, back-up, and other external and/or infrastructure problems, which shall be deemed under the Customer’s and its end user’s exclusive control and sole responsibility.
5.3. Exclusive Remedy. Customer’s exclusive remedy under Section 5.2 shall be for Adtech Global, in its sole discretion, to re-perform the affected Services, or waive or refund (as appropriate) the fee for such Services. Notwithstanding any of the foregoing, Adtech Global shall have no obligations under this Section 5.3 unless Adtech Global receives Customer’s notice during the applicable warranty period. 5.4. Disclaimer of Warranties. THE LIMITED WARRANTY AND EXCLUSIVE REMEDY SET FORTH IN SECTIONS 5.2 AND 5.3 RESPECTIVELY ARE MADE FOR THE BENEFIT OF CUSTOMER ONLY, AND ARE EXPRESSLY SUBJECT TO CUSTOMER’S PAYMENT OBLIGATIONS TO ADTECH GLOBAL. ADTECH GLOBAL MAKES NO AND DISCLAIMS ALL OTHER WARRANTIES, REPRESENTATIONS, OR CONDITIONS, WRITTEN OR ORAL, OR EXPRESS, IMPLIED, OR STATUTORY, INCLUDING ANY IMPLIED WARRANTIES OF MERCHANTABILITY, TITLE, INTEROPERABILITY, DATA ACCURACY, OR FITNESS FOR A PARTICULAR PURPOSE WITH RESPECT TO ANY PRODUCT, SERVICES, SUPPORT, OR ANY COMPONENTS THEREOF, AND ANY OTHER PRODUCTS OR SERVICES PROVIDED BY ADTECH GLOBAL. WITHOUT LIMITING THE FOREGOING, ADTECH GLOBAL DOES NOT WARRANT THAT ALL ERRORS CAN BE CORRECTED, OR THAT OPERATION OF ANY PRODUCT SHALL BE UNINTERRUPTED OR ERROR-FREE.
5.5. Additional Services. If Adtech Global provides any services as a result of any conditions or exclusions specified in Section 5.2.2, regardless whether under warranty or otherwise outside the scope of any services agreed to between the parties, Adtech Global may charge Customer for such services at Adtech Global’s then current service fee rate.
6. LIMITATION OF LIABILITY. ADTECH GLOBAL’S MAXIMUM LIABILITY ARISING OUT OF OR IN ANY WAY CONNECTED TO THIS SOW SHALL NOT BE FOR ANY AMOUNT IN EXCESS OF THE SERVICES FEE UNDER THE THIS CURRENT SOW FOR THE SIX (6) MONTH PERIOD IMMEDIATELY PRECEDING THE ACTION THAT GIVES RISE TO THE CLAIM. IN NO EVENT SHALL ADTECH GLOBAL, ANY PARENT, SUBSIDIARY, AFFILIATE OR LICENSOR, OR ANY OF THEIR OFFICERS, DIRECTORS, EMPLOYEES, SHAREHOLDERS, OR REPRESENTATIVES, BE LIABLE (I) TO ANY THIRD PARTY FOR DAMAGES OF ANY KIND OR NATURE OR IN ANY MANNER WHATSOEVER, OR (II) TO END USER FOR ANY CONSEQUENTIAL, INDIRECT, EXEMPLARY, INCIDENTAL, OR
SPECIAL DAMAGES OR COSTS (INCLUDING ATTORNEYS’ FEES OR LOST PROFITS, TIME, SAVINGS, PROPERTY, DATA OR GOODWILL) REGARDING THIS SOW OR RESULTING FROM OR IN CONNECTION WITH THE USE, MISUSE, OR INABILITY TO USE ANY PRODUCT, SERVICES, SUPPORT, OR OTHER PRODUCTS OR SERVICES, REGARDLESS OF THE CAUSE OF ACTION, EVEN IF ADTECH GLOBAL HAS BEEN ADVISED OF THE POSSIBILITY THEREOF. WITHOUT LIMITING THE FOREGOING, IN NO EVENT SHALL ADTECH GLOBAL BE LIABLE FOR PROCUREMENT COSTS OF SUBSTITUTE PRODUCTS OR SERVICES. THIS SECTION 5 SHALL SURVIVE AND CONTINUE IN FULL FORCE AND EFFECT DESPITE ANY FAILURE OF ESSENTIAL PURPOSE, CONSIDERATION, OR OF AN EXCLUSIVE REMEDY. 7. INDEMNIFICATION.
7.1. Indemnity by Parties. Each party shall indemnify, defend, and hold harmless the other party, and its officers, directors, employees, shareholders, and representatives, from and against any and all liabilities, losses, damages, causes of action or injuries, costs and expenses, including court costs and reasonable attorneys’ fees, of any nature whatsoever in connection with claims of third parties arising from: (i) Party’s breach of Section 2.5 or Section 8 or (ii) Customer’s failure to pay any Fees or other amounts due hereunder, or to pay any taxes, duties, etc., as specified in Section 4. 8. INTELLECTUAL PROPERTY; CONFIDENTIALITY.
8.1. Ownership. Customer acknowledges Adtech Global owns all Intellectual Property Rights in and to the Adtech Global Intellectual Property, and derivatives thereto are and shall remain vested in Adtech Global. Customer shall not assert or cause any other party (including, without limitation, any End User) to assert any right, title, or interest in or to the Adtech Global Intellectual Property, or make any misrepresentations about the same. 8.2. Use of Marks; Proprietary Notices. Any combination of the Adtech Global trademarks, service marks, logos, and trade names of third parties must be approved in writing by Adtech Global prior to their actual use by Customer.
8.3. Adtech Global Intellectual Property Protection. In no event shall this SOW, or any rights or privileges hereunder, be an asset of Customer under any bankruptcy, insolvency, or reorganization proceedings, or in any other manner whatsoever; however, this SOW and transactions hereunder shall be binding upon and inure to the benefit of the parties, their legal representatives, and permitted transferees, successors, and assigns. Except as otherwise specified in this SOW, expressly permitted in writing by Adtech Global or Customer, or otherwise cannot be precluded under mandatory applicable law, Customer shall not, and shall not permit any other party (including, without limitation, any End User) to:
8.3.1. Adapt, modify, or prepare derivative works based on any of the Adtech Global Intellectual Property; or use any of the Adtech Global Intellectual Property to create material that performs, replicates, or utilizes the same or substantially similar functions as Adtech Global Intellectual Property; 8.3.2. Alter, remove, or suppress any copyright, confidentiality, or other proprietary notices, marks or any legends placed on, embedded or otherwise appearing in or on any Adtech Global Intellectual Property; or fail to ensure that all such notices and legends appear on all full or partial copies of Adtech Global Intellectual Property or any related material; 8.3.3. Sell, sublicense, lease, assign, delegate, transfer, distribute, encumber or otherwise transform any Adtech Global Intellectual
Adtech Global_________ CONFIDENTIAL INFORMATION Customer_______
P a g e | 23
Property or any of the rights or obligations granted to or imposed on Customer hereunder.
8.4. Confidentiality. The unauthorized disclosure or use of Confidential Information of a disclosing party or of a disclosing party’s third party licensors, and all information and services related thereto, would cause great injury and harm to the owner thereof. Therefore, each party agrees to take all appropriate action to ensure the confidentiality and security of the other party’s Confidential Information, but in any event no less than the same standard of care it uses to protect its own Confidential Information of like kind and value. Without limiting the generality of the foregoing, and in addition to each party’s obligations in this Section, each party agrees that it: (i) shall maintain the other’s Confidential Information in the strictest confidence, including compliance with reasonable remote access security requirements; (ii) shall not disclose, display, publish, transmit, or otherwise make available such Confidential Information or take the benefit thereof, in whole or in part, except in confidence to its own employees (subject to obligations of nondisclosure) on a need-to-know basis; and (iii) except as expressly permitted hereunder, shall not copy, duplicate, replicate, transform, or reproduce such Confidential Information. Notwithstanding anything in this Section, neither party shall be liable to the other for damages resulting from disclosure of any Confidential Information required by law, regulation or valid court order; provided prior written notice is provided to the other party sufficiently in advance of such required disclosure to allow the other party to respond and take reasonable and lawful action to avoid and/or minimize the degree of such disclosure or seek appropriate protective orders. 9. TERMINATION.
9.1. This SOW and Order may be terminated as follows:
9.1.1. By either party for material breach hereof which has not been cured within ninety (90) days after written notice of such breach; or 9.1.2. By either party at any time if the other party makes an assignment for the benefit of creditors, or commences or has commenced against it any proceeding in bankruptcy or insolvency; or
9.2. Effects of Termination. Upon termination of this SOW and Order: (i) All Fees due to Adtech Global shall be paid, (ii) Each party shall immediately return to the other party or destroy all Confidential Information and all other material received from the other party, and provide the other party with a signed written statement certifying that it has compiled with the foregoing obligations. 10. Miscellaneous.
10.1. Assignment. Neither party shall assign or transfer this SOW nor delegate any of its rights or obligations hereunder, without the prior written consent of the other party. Notwithstanding the foregoing, either party shall have the right to assign or transfer this SOW to a successor in connection with the sale of all or substantially all of the assets of such party (whether by merger, operation of law or otherwise), by providing written notice of such to the other party. 10.2. Compliance with Laws. Each Party shall comply with all applicable laws and administrative regulations directly or indirectly applicable to its activities hereunder or otherwise pursuant to or in connection with this SOW
and the delivery of any Services.
10.3. Survival. Sections 4, 5, 6, 7, 8, and 10 of these General Terms and Conditions shall survive the expiration or termination of this SOW or any Schedule.
10.4. Notices. Any notice, consent, or other communication permitted or required under this SOW shall be in writing and may be delivered in person, or by mail. If hand delivered, the notice shall be deemed received upon delivery. If sent by mail, the notice shall be deemed received three business days after being deposited with the United States Postal Service by certified mail, return receipt requested, addressed appropriately to the intended recipient. Notice shall be sent as follows:
If to ADTECH GLOBAL:
Adtech Global Solutions, Inc. Attn: In-House Legal Department 1880 McFarland Parkway, Suite 100 Alpharetta, GA 30005 If to Customer Name Attn: Address
10.5. No Third Party Beneficiaries. Except as expressly set forth herein, nothing in this SOW shall confer any rights upon any person or entity other than the parties hereto and their respective successors and permitted assigns. 10.6. Amendments. No amendment, modification, or supplement of any provision of this SOW will be valid or effective unless made in writing and signed by a duly authorized representative of each party.
10.7. Governing Law. This SOW shall be governed by and construed in accordance with the laws of the State of Georgia, without regard to its provisions governing conflicts of law. The parties agree that the United Nations Convention on Contracts for the International Sale of Goods shall not apply to this SOW or any Software, Services, or other items or information licensed or provided to the other Party hereunder.
10.8. Non-Solicitation. Customer will have access to key Adtech Global personnel in the capacity of project management, implementation, consulting and training services. Therefore, Customer agrees during the term of this SOW and for a period of two (2) years following completion or termination of this SOW, Customer will not permit any of their representatives or any of its subsidiaries to solicit for employment, employ or contract any of Adtech Global’s personnel without the prior written consent of Adtech Global.
10.9. Independent Contractors. In making and performing under this SOW, the parties are acting and shall act as independent contractors. Neither party is, nor will be deemed to be, an agent, legal representative, joint venture, or partner of the other party for any purpose. Neither party shall have any authority to act for or to bind the other party in any respect. Each Party’s personnel shall not be considered employees of the other Party, and shall not be entitled to participate in or receive any benefits or rights as employees of the other Party, under any employee benefit and welfare plans, including employee insurance, pension, savings, and security plans.
10.10. Interpretation. Unless the context of this SOW clearly requires otherwise, (i) references to the plural include the singular, the singular the plural, the part the whole, (ii) references to any gender include all genders, (iii) “or” has the inclusive meaning frequently identified with the phrase “and/or,” (iv) “including” has the inclusive meaning frequently identified with the phrase “but not limited to” and (v) references to “hereunder” or “herein” relate to this SOW.
10.11. Severability. Any provision of this SOW determined to be invalid or unenforceable by a competent tribunal shall be ineffective to the extent of
Adtech Global_________ CONFIDENTIAL INFORMATION Customer_______
P a g e | 24
such invalidity or unenforceability, without rendering invalid or unenforceable the remaining provisions of this SOW.
10.12. Waivers. A waiver by either party of a breach or violation of any provision of any of this SOW shall not constitute or be construed as a waiver of any subsequent breach or violation of that provision, or as a waiver of any breach or violation of any other provision of any of this SOW.
10.13. Counterparts. This SOW may be executed in two or more counterparts, each of which shall be deemed an original and all of which together shall constitute one and the same instrument. This SOW shall become binding when any two or more counterparts thereof, individually or taken together, bear the signatures of both parties hereto.
10.14. Force Majeure. Adtech Global shall not be liable to Customer for any delay in performance or any failure in performance hereunder caused in whole or in part by reason of force majeure, which shall be deemed to include the occurrence of any event beyond the control of Adtech Global that renders performance impossible and shall include Customer's failure to furnish necessary information with respect to details of performance on the part of the Customer, war (whether an actual declaration thereof is made or
not), sabotage, terrorism, insurrection, riot and other acts of civil disobedience, action of a public enemy, failure or delays in transportation, laws, regulations or acts of any national, state or local government (or any agency, subdivision or instrumentality thereof), judicial action, labor dispute, accident, fire, explosion, flood, storm or other act of God, shortage of labor, fuel, raw materials, machinery or technical failures.
10.15. Entire Statement of Work. This SOW and the exhibits, appendices and schedules attached hereto set forth the entire understanding between the parties concerning the subject matter hereof and supersede all contemporaneous and prior negotiations, understandings, and agreements with respect to such subject matter. There are no covenants, promises, agreements, conditions or understandings, whether oral or written, among the parties hereto relating to the subject matter of this SOW other than those set forth herein. No shrink-wrap, click-wrap, browse-wrap or other terms and conditions or agreements (“Additional Terms”) provided shall be binding on the other Party, even if use thereof requires an affirmative “acceptance” of those Additional Terms before use or access is permitted. All such Additional Terms shall be of no force or effect and are hereby rejected by affected Party in their entirety.