11-2010-K-G-SPC-2210-TOC_Rev-B

2x600 MW Long Phu 1 EPC RFP Document

EPC REQUEST FOR PROPOSAL11/2010-K-G-SPC-2210

GENERAL TABLE OF CONTENTS:

VOLUME-I [1 BOOK]

: BIDDING PROCEDURE

VOLUME-II[11 BOOKS]

: TECHNICAL SPECIFICATION / SCOPE OF WORK

VOLUME-III[1 BOOK]

: CONDITIONS OF CONTRACT

VOLUME-IV[3 BOOK]

: BID PROPOSAL SHEETS / BIDDING FORMS [TECHNICAL & GENERAL]

VOLUME-V[1 BOOK]

: BID PROPOSAL SHEETS / BIDDING FORMS [PRICE]

(document.doc) TOC : 1


CONTENTS

VOLUME-I : BIDDING PROCEDURE

SECTION-I : INVITATION FOR BID

SECTION-II : BIDDING PROCEDURE

II.1 INSTRUCTION TO BIDDER

II.2 BID DATA SHEET

II.3 EVALUATION AND QUALIFICATION CRITERIA

II.4 BIDDING FORMS

ANNEXURES DESCRIPTION

ANNEXURE-1 TASK ALLOCATION IN CONSORTIUM

ANNEXURE-2 TECHNICAL EVALUATION TABLE



DETAILED TABLE OF CONTENTS

VOLUME-I


SUB-SECTION II.1 INSTRUCTION TO BIDDER

PART NO. DESCRIPTION

DEFINITIONS AND ABBREVIATIONA. GENERAL

1. Introduction

2. Eligibility and Qualification of Bidders

3. Eligible Plant, Equipment and Services

4. Bidding Cost

5. Request for Proposal Documents and clarification

6. Amendment of Request for Proposal Document

B. PREPARATION OF PROPOSAL

7. Language used in Proposal

8. Document comprising the Proposal

9. Bid Application Form

10. Alternative Proposal

11. Document establishing the eligibility of Plant and Services

12. Documents establishing the Eligibility and Qualification of the Bidder

13. Document establishing the Conformity of the Plant and Services

14. Technical Proposal, Subcontractors

15. Financing arrangement Proposal

16. Proposal Price and Discount

17. Currencies of Proposal

18. Period of validity of Proposal

19. Bid Bond: N/A

20. Format and signing of Proposal

C. SUBMISSION OF PROPOSAL

21. Submission, sealing and marking of the Proposal




VOLUME-I




C. SUBMISSION OF PROPOSAL (CONT’D)

22. Deadline for Submission of Proposal

23. Late Proposal Error: Reference source not found

24. Withdrawal, Substitution, and Modification of Proposal

D. PROPOSAL OPENING AND EVALUATION

25. Proposal opening

26. Confidentiality

27. Clarification of Proposal

28. Deviation, Reservation, and Omission

29. Preliminary examination of Proposal

30. Determination of Responsiveness of the Proposal

31. Eligibility and Qualification of the Bidder

32. Correction of arithmetical errors

33. Nonmaterial Nonconformities

34. Conversion to single currency

35. Margin of preference

36. Technical evaluation

37. Financing arrangement evaluation

38. Commercial evaluation

39. Adjustment of Deviation

E. CONTRACT AWARD

40. Contract negotiation and Award Criteria

41. Owner’s right to accept and reject Proposal

42. Contract negotiation and finalization

43. Signing of contract




VOLUME-I




E. CONTRACT AWARD (CONT’D)

44. Performance bond

45. Bidding petitions

46. Handling of violation in bidding process

47. Changing the Bidder Participoation Status/Name




VOLUME-I


SUB-SECTION II.2 BID DATA SHEET

CLAUSE NO. DESCRIPTION

A GENERAL

B PREPARATION OF BID

C SUBMISSION OF PROPOSAL

D PROPOSAL OPENING AND EVALUATION

E CONTRACT AWARD




VOLUME-I


SUB-SECTION II.3 EVALUATION AND QUALIFICATION CRITERIA

CLAUSE NO. DESCRIPTION

1.0 INTRODUCTION

2.0 DETAILS OF TENDER

3.0 THE PROJECT

4.0 THE SITE

5.0 SCOPE OF WORK

6.0 COMPLETION SCHEDULE

7.0 QUALIFICATION OF BIDDER

8.0 GENERAL INSTRUCTIONS AND ADDRESS OF CORRESPONDENCES




VOLUME-I


SUB-SECTION II.4 BIDDING FORMS

FORM NO. DESCRIPTION

Form No 1 Bid Application Form

Form No 2 Power of Attorney

Form No 3 Consortium Agreement

Form No 4 Breakdown Price of Plant to be Supplied from within Vietnam

Form No 5 Breakdown Price of Plant to be Supplied from Abroad

Form No 6 Breakdown Price of Plant Imported from Abroad and are Selling in Vietnam

Form No 7 List of Main Construction Machine and Equipment

Form No 8 List of Equipment, Testing Laboratory at Site

Form No 9 Organization chart and List of Foreign Expert and Technical Engineers in Project Team

Form No 10 Current Contracts in Implementation of the Bidder

Form No 11 List of Similar Contracts done by the Bidder

Form No 12 List of Main Subcontractors/Suppliers

Form No 13 Plant Performance Guarantees

Form No 14 Financial Data

Form No 15 Bid Bond

Form No 16 List of Mandatory Spare Parts

Form No 17 List of Recommended Spare Parts

Form No 18 Commercial Deviations

Form No 19 Technical Deviations

Form No 20 List of ECA-Backed Projects executed in Period 2005-2009

Form No 21 General Summary of Total Debt Financing



CONTENTS

VOLUME-II TECHNICAL SPECIFICATION / SCOPE OF WORK

[BOOK-1]

VOLUME II-A : LEAD SPECIFICATION

VOLUME II-B : SPECIFICATIONS FOR STEAM GENERATOR & AUXILIARIES

VOLUME II-C : SPECIFICATIONS FOR TURBINE-GENERATOR, AUXILIARIES & OTHER FEED CYCLE EQUIPMENT

VOLUME II-D : SPECIFICATIONS FOR POWER CYCLE & OTHER PIPING, VALVES & SPECIALTIES

[BOOK-2]

VOLUME II-E : SPECIFICATIONS FOR CONTROLS & INSTRUMENTATION

VOLUME II-F/1 : SPECIFICATIONS FOR ELECTRICAL EQUIPMENT & (UPTO SEC-1) ACCESSORIES

[BOOK-3]

VOLUME II-F/1 & : SPECIFICATIONS FOR ELECTRICAL EQUIPMENT & VOLUME II-F/2 ACCESSORIES

[BOOK-4]

VOLUME II-G/1 : GENERAL SPECIFICATION AND DESIGN CRITERIA FOR CIVIL AND STRUCTURAL WORK

VOLUME II-G/2 GENERAL SPECIFICATION AND DESIGN CRITERIA FOR ARCHITECTURAL WORK

VOLUME II-G/3 TECHNICAL SPECIFICATION FOR CIVIL, STRUCTURAL AND ARCHITECTURAL WORK

VOLUME II-G/4 ANNEXURES (UPTO SOIL RESISTIVITY TEST)

[BOOK-5]

VOLUME II-G/4 ANNEXURES (POWER BLOCK ONWARDS)

[BOOK-6]



VOLUME II-H : SPECIFICATIONS FOR MAIN & AUXILIARY COOLING WATER SYSTEMS & ACCESSORIES

VOLUME II-I : SPECIFICATIONS FOR AUXILIARY SYSTEMS VIZ., PLANT WATER SYSTEM, FGD SYSTEM, COMPRESSED AIR SYSTEM, FIRE PROTECTION SYSTEM, LP PIPING & VALVES ETC.

VOLUME II-J : SPECIFICATIONS FOR SUMP PUMPS, MISCELLANEOUS CRANES & HOISTS, ELEVATORS AND LABORATORY EQUIPMENT

VOLUME : II-K : SPECIFICATIONS FOR COAL HANDLING, ASH HANDLING, WATER & EFFLUENT TREATMENT, VENTILATION & AIR-CONDITIONING SYSTEM

VOLUME II-K/1 SPECIFICATIONS FOR COAL HANDLING SYSTEM

VOLUME II-K/2 SPECIFICATIONS FOR ASH HANDLING SYSTEM

VOLUME II-K/3 SPECIFICATIONS FOR LIMESTONE HANDLING SYSTEM AND ACCESSORIES (GENERAL & MECHANICAL WORKS)

VOLUME II-K/4 SPECIFICATIONS FOR WATER & EFFLUENT TREATMENT SYSTEM

VOLUME II-K/5 SPECIFICATIONS FOR HEATING, VENTILATION & AIR-CONDITIONING SYSTEM

VOLUME II-K/6 SPECIFICATION FOR MILL REJECTS HANDLING SYSTEM

[BOOK-7, BOOK-8 & BOOK-9]

VOLUME II-L : TENDER DRAWINGS

[BOOK-7] MECHANICAL

[BOOK-7] INSTRUMENTATION & CONTROL

[BOOK-8] ELECTRICAL

[BOOK-9] CIVIL, STRUCTURAL AND ARCHITECTURAL

[BOOK-10]VOLUME-II-N : PORT FACILITY




VOLUME-II [BOOK-1]

VOLUME : II-A LEAD SPECIFICATION

SECTIONS DESCRIPTION

SECTION-I : INTENT OF SPECIFICATION

SECTION-II : PROJECT SYNOPSIS AND GENERAL INFORMATION

SECTION-III : SCOPE OF SUPPLY & SERVICES

SECTION-IV : GENERAL TECHNICAL REQUIREMENTS

SECTION-V : PROJECT MANAGEMENT & SITE SERVICES

SECTION-VI : ENGINEERING SERVICES

SECTION-VII : QUALITY ASSURANCE REQUIREMENTS

SECTION-VIII : REQUIREMENT OF SPARES, TOOLS & TACKLE, LUBRICANTS / OIL / CONSUMABLES

SECTION-IX : SALIENT DESIGN DATA

SECTION-X : PERFORMANCE GUARANTEE AND TESTS

SECTION-XI : LONG TERM MAINTENANCE SERVICE


Rev-B



VOLUME-II [BOOK-1]

VOLUME : II-B SPECIFICATIONS FOR STEAM GENERATOR & AUXILIARIES


SECTION-I : STEAM GENERATOR AND ACCESSORIES

SECTION-II : ELECTROSTATIC PRECIPITATOR

SECTION-IIIA : FUEL OIL TRANSFERING SYSTEM

SECTION-IIIB : FUEL OIL PRESSURISING SYSTEM

SECTION-IV : CHEMICAL DOSING SYSTEM

SECTION-V : FGD SYSTEM

SECTION-VI : AUXILIARY BOILER – REV. A


Rev-B



VOLUME-II [BOOK-1]

VOLUME : II-C SPECIFICATIONS FOR TURBINE-GENERATOR, AUXILIARIES & OTHER FEED CYCLE EQUIPMENT


SECTION-IA : STEAM TURBINE

SECTION-IB : GENERATORS AND GENERATOR SYSTEMS

SECTION-II : FEED WATER HEATERS & DEAERATOR

SECTION-III : POWER CYCLE PUMPS, DRIVES & ACCESSORIES

SECTION-IV : CONDENSERS & AUXILIARIES

SECTION-V : TURBINE OIL PURIFICATION SYSTEM

SECTION-VI : CONDENSATE POLISHING SYSTEM

SECTION-VII : CONDENSER ONLINE TUBE CLEANING SYSTEM


Rev-B



VOLUME-II [BOOK-1]

VOLUME : II-D SPECIFICATIONS FOR POWER CYCLE PIPING, VALVES, SPECIALTIES & THERMAL INSULATION


SECTION-I : POWER CYCLE PIPING, VALVES & SPECIALTIES

SECTION-II : THERMAL INSULATION




VOLUME-II [BOOK-2]

VOLUME : II-E TECHNICAL SPECIFICATIONS FOR INSTRUMENTATION AND CONTROL


SECTION-I : GENERAL TECHNICAL REQUIREMENTS

SECTION-II : SCOPE OF WORK

SECTION-III : INSTRUMENTATION AND CONTROL FOR STEAM GENERATING UNIT & AUXILIARIES

SECTION-IV : INSTRUMENTATION AND CONTROL FOR TURBINE GENERATOR, AUXILIARIES & FEED CYCLE EQUIPMENT

SECTION-V : INSTRUMENTATION & CONTROL FOR PLANT AUXILIARIES AND OFF-SITE PLANTS

SECTION-VI : TECHNICAL SPECIFICATION - INSTRUMENTS AND CONTROL SYSTEMS (DCS)

SECTION-VII : STEAM AND WATER ANALYSIS SYSTEM (SWAS)

SECTION-VIII : ERECTION AND COMMISSIONING

SECTION-IX : LABORATORY INSTRUMENTS




VOLUME-II [BOOK-2]

VOLUME : II-F/1 TECHNICAL SPECIFICATIONS FOR ELECTRICAL EQUIPMENT & ACCESSORIES


SECTION-I : GENERAL ELECTRICAL SPECIFICATION

VOLUME-II [BOOK-3]



SECTION-II : A.C. & D.C. MOTORS

SECTION-III : ELECTRICAL MOTOR ACTUATORS

SECTION-IV : GENERATOR BUS DUCT

SECTION-V : MV SWITCHGEARS

SECTION-VI : 10 KV & 3 KV SEGREGATED PHASE BUS DUCT

SECTION-VII : PCC/MCC, ACDB AND DCDB

SECTION-VIII : MISCELLANEOUS LOCAL PANELS

SECTION-IX : GENERATOR TRANSFORMER

SECTION-X : UNIT TRANSFORMER

SECTION-XI : STATION TRANSFORMER

SECTION-XII : VARIABLE FREQUENCY DRIVES

SECTION-XIII : NON-SEGREGATED PHASE BUS DUCT

SECTION-XIV : GENERATOR CIRCUIT BREAKER




VOLUME-II [BOOK-3]



SECTION-I : NEUTRAL GROUNDING RESISTOR

SECTION-II : L.V. AUX. TRANSFORMERS

SECTION-III : BATTERIES AND BATTERY CHARGERS

SECTION-IV : CABLES

SECTION-V : PROTECTION & RELAY PANELS AND SYNCHRONISING PANEL

SECTION-VI : 10/3.15 KV AUXILIARY POWER TRANSFORMER

SECTION-VII : ILLUMINATION SYSTEM

SECTION-VIII : EHV LIGHTNING ARRESTORS

SECTION-IX : INSTALLATION OF CABLING, EARTHING AND LIGHTNING PROTECTION SYSTEMS

SECTION-X : ERECTION OF ELECTRICAL EQUIPMENT

SECTION-XI : PLANT COMMUNICATION SYSTEM

SECTION-XII : EMERGENCY DIESEL GENERATOR SET

SECTION-XIII : ELECTRICAL LABORATORY INSTRUMENTS

SECTION-XIV : UNINTERRUPTIBLE POWER SUPPLY SYSTEM

SECTION-XV : EHV CURRENT TRANSFORMERS

SECTION-XVI : EHV VOLTAGE TRANSFORMERS




VOLUME-II [BOOK-4]

VOLUME : II-G/1 GENERAL SPECIFICATION AND DESIGN CRITERIA FOR CIVIL AND STRUCTURAL WORK

VOLUME : II-G/2 GENERAL SPECIFICATION AND DESIGN CRITERIA FOR ARCHITECTURAL WORK




VOLUME-II [BOOK-4]

VOLUME : II-G/3 TECHNICAL SPECIFICATION FOR CIVIL, STRUCTURAL AND ARCHITECTURAL WORK


SECTION-I : TOPOGRAPHIC SURVEY

SECTION-II : GEOTECHNICAL INVESTIGATION

SECTION-III : CLEARING AND GRADING

SECTION-IV : SOIL IMPROVEMENT WORK

SECTION-V : EARTH WORK

SECTION-VI : CAST IN PLACE CONCRETE

SECTION-VII : CONCRETE PILING

SECTION-VIII : STRUCTURAL STEEL

SECTION-IX : MISCELLANEOUS METAL

SECTION-X : ROADS AND PAVEMENT

SECTION-XI : MASONRY AND ALLIED WORK

SECTION-XII : FINISH TO MASONRY AND CONCRETE

SECTION-XIII : CAULKING AND SEALING

SECTION-XIV : PREFORMED SINGLE AND SANDWICH INSULATED METAL SIDING

SECTION-XV : CARPENTRY AND MILL WORK

SECTION-XVI : HOLLOW METAL DOORS, WINDOWS, VENTILATORS AND LOUVERS

SECTION-XVII : ALUMINIUM FRAMED GLAZED CURTAIN WALLS AND STRUCTURAL GLAZING

SECTION-XVIII : ROLLING STEEL DOORS

SECTION-XIX : FINISH HARDWARE

SECTION-XX : GLASS AND GLAZING




VOLUME-II : VOLUME : II-G/3 (CONT’D.)


SECTION-XXI : FINISH AND ALLIED WORK

SECTION-XXII : ACCESS FLOORING

SECTION-XXIII : PAINTING

SECTION-XXIV : SUSPENDED ACOUSTIC CEILING

SECTION-XXV : SHEET WORK IN ROOF AND SIDING

SECTION-XXVI : ROOF WATER PROOFING, INSULATION AND ALLIED WORK

SECTION-XXVII : DRAINAGE AND PLUMBING

SECTION-XXVIII : LANDSCAPING WORK

SECTION-XXIX : HEALTH, SAFETY AND ENVIRONMENTAL (HSE) REQUIREMENTS

SECTION-XXX : PROJECT DISPLAY MODEL




VOLUME-II [BOOK-4]

VOLUME : II-G/4 ANNEXURES


ANNEXURE-A GEO-TECHNICAL INVESTIGATION REPORT (DOC NO. 11/2010-PMC2-C-RPT-2000) [UPTO SOIL RESISTIVITY TEST]

VOLUME-II [BOOK-5]

VOLUME : II-G/4 ANNEXURES


ANNEXURE-A GEO-TECHNICAL INVESTIGATION REPORT (DOC NO. 11/2010-PMC2-C-RPT-2000)[POWER BLOCK ONWARDS]

ANNEXURE-B BOREHOLE LOCATION PLAN

ANNEXURE-C BORELOGS FROM SOIL INVESTIGATION CARRIED OUT DURING FS REPORT

ANNEXURE-D PLANT AREA MAPING

ANNEXURE-E HAU RIVER CROSS SECTION




VOLUME-II [BOOK-6]

VOLUME : II-H SPECIFICATIONS FOR MAIN & AUXILIARY COOLING WATER SYSTEMS & ACCESSORIES


SECTION-I : GENERAL DESIGN REQUIREMENTS FOR MAIN AND AUXILIARY COOLING WATER SYSTEMS

SECTION-II : HORIZONTAL CENTRIFUGAL PUMPS

SECTION-IIIA : VERTICAL PUMPS

SECTION-IIIB : CONDENSER COOLING WATER PUMPS

SECTION-IV : COOLING WATER HEAT EXCHANGERS

SECTION-V : INTAKE CHLORINATION SYSTEM




VOLUME-II [BOOK-6]

VOLUME : II-I SPECIFICATIONS FOR AUXILIARY SYSTEMS VIZ. PLANT WATER SYSTEM, COMPRESSED AIR SYSTEM, FIRE PROTECTION SYSTEM, LP PIPING & VALVES ETC.


SECTION-I : PLANT WATER SYSTEM

SECTION-II : COMPRESSED AIR SYSTEM

SECTION-III : FIRE PROTECTION & DETECTION SYSTEM

SECTION-III : FIRE FIGHTING AND FIRE PROTECTION TECHNICAL ANNEXURE-VIII DESIGN REPORTS # 11/2010-PMC2-G-RPT-2000 REV. F

SECTION-IV : CO2 AND N2 GAS CYLINDERS

SECTION-V : LARGE DIAMETER LOW PRESSURE PIPING, VALVES AND FABRICATED TANKS

SECTION-VI : LOW PRESSURE PIPING, VALVES AND SPECIALTIES

SECTION-VII : HYDROGEN GENERATION PLANT


Rev-B



VOLUME-II [BOOK-6]

VOLUME : II-J SPECIFICATIONS FOR SUMP PUMPS, MISCELLANEOUS CRANES & HOISTS, ELEVATORS AND LABORATORY EQUIPMENT


SECTION-I : SUMP PUMPS, DRIVES AND ACCESSORIES

SECTION-IIA : TG HALL EOT CRANE

SECTION-IIB : MISCELLANEOUS CRANES

SECTION-III : MISCELLANEOUS HOISTS

SECTION-IV : ELEVATORS

SECTION-V : STACK ELEVATOR

SECTION-VI : CHEMICAL LABORATORY EQUIPMENT

SECTION-VII : WORKSHOP EQUIPMENT – REV. A


Rev-B



VOLUME-II [BOOK-6]

VOLUME : II-K SPECIFICATIONS FOR COAL HANDLING, ASH HANDLING, WATER & EFFLUENT TREATMENT, VENTILATION & AIR-CONDITIONING SYSTEM

VOLUME II-K/1 : SPECIFICATIONS FOR COAL HANDLING SYSTEM

VOLUME II-K/2 : SPECIFICATIONS FOR ASH HANDLING SYSTEM

VOLUME II-K/3 : SPECIFICATIONS FOR LIMESTONE HANDLING SYSTEM AND ACCESSORIES (GENERAL & MECHANICAL WORKS)




VOLUME-II [BOOK-6]

VOLUME II-K/4 : SPECIFICATIONS FOR WATER & EFFLUENT TREATMENT SYSTEM


SECTION-I : RIVER WATER PRE-TREATMENT SYSTEM

SECTION-II : DESALINATION RO POTABLE WATER TREATMENT AND DEMINERALIZATION RO SYSTEMS

SECTION-III : WASTE WATER TREATMENT SYSTEM

SECTION-III : EIA REPORTANNEXURE-IX


Rev-B



VOLUME-II [BOOK-6]

VOLUME II-K/5 : SPECIFICATION FOR HEATING, VENTILATION & AIR-CONDITIONING SYSTEM

VOLUME II-K/6 : SPECIFICATION FOR MILL REJECTS HANDLING SYSTEM




VOLUME-II [BOOK-7, BOOK-8 & BOOK-9]

VOLUME : II-L TENDER DRAWINGS

[BOOK-7] MECHANICAL

[BOOK-7] INSTRUMENTATION & CONTROL

[BOOK-8] ELECTRICAL

[BOOK-9] CIVIL, STRUCTURAL AND ARCHITECTURAL




VOLUME-II [BOOK-10]

VOLUME : II-N PORT FACILITY

SECTION 1 GENERAL INFORMATION

SECTION 2 SCOPE OF WORK

SECTION 3 DESIGN REQUIREMENTS

SECTION 4 CONSTRUCTION REQUIREMENTS



CONTENTS

VOLUME-III : CONDITIONS OF CONTRACT

SECTION-1 : CONTRACT AGREEMENT

SECTION-2 : CONDITIONS OF CONTRACT




VOLUME-III

SECTION-1 : CONTRACT AGREEMENT

ARTICLE NO. DESCRIPTION

1.0 DEFINITIONS

2.0 CONTRACT DOCUMENTS

3.0 CONTRACT PRICE AND PRIMARY COVENANTS

4.0 TIME FOR COMPLETION

5.0 PERFORMANCE GUARANTEES

6.0 DEFECT NOTIFICATION PERIOD

7.0 COMMUNICATIONS

8.0 EFFECTIVE DATE

9.0 COMMENCEMENT DATE

10.0 BASIC PRINCIPLE FOR SUCCESSFUL IMPLEMENTATION




VOLUME-III

SECTION-2 : CONDITIONS OF CONTRACT


1.0 GENERAL PROVISIONS

1.1 Definitions

1.2 Interpretation

1.3 Communications

1.4 Law and Language

1.5 Priority of documents

1.6 Contract effectiveness

1.7 Assignment

1.8 Care and supply of documents

1.9 Confidentiality

1.10 Owner’s use of contractor’s documents

1.11 Contractor’s use of owner’s documents

1.12 Not used

1.13 Compliance with laws

1.14 Joint and several liability

1.15 Prior work

2.0 THE OWNER

2.1 Right of access to the site

2.2 Permits, licences or approvals

2.3 Owner’s personnel

2.4 Financing arrangement

2.5 Owner’s claims

3.0 THE OWNER’S ADMINISTRATION

3.1 The Owner’s representative

3.2 Other Owner’s personnel

3.3 Delegated persons

3.4 Instructions




VOLUME-III

SECTION-2 (CONT’D)


3.0 THE OWNER’S ADMINISTRATION (CONT’D)

3.5 Determinations

4.0 THE CONTRACTOR

4.1 Contractor’s General Obligations

4.2 Bonds

4.3 Contractor’s Representative

4.4 Subcontractors

4.5 [Not Used]

4.6 Co-operation

4.7 Setting Out

4.8 Safety Procedures

4.9 Quality Assurance

4.10 Site Data

4.11 Sufficiency of the Contract Price

4.12 Unforeseeable Difficulties

4.13 Rights of Way and Facilities

4.14 Avoidance of Interference

4.15 Access Route

4.16 Transport of Goods

4.17 Contractor’s Equipment

4.18 Protection of the Environment

4.19 Electricity, Water and other Consumables

4.20 Not Used

4.21 Progress Reports

4.22 Security of the Site

4.23 Contractor’s Operations on Site

4.24 Fossils

4.25 Contractor’s Specific Warranties




VOLUME-III



3.0 THE CONTRACTOR (CONT’D)

4.26 Coordination Meetings

4.27 Tropical Serviceability

4.28 Old Materials

5.0 DESIGN

5.1 General Design Obligations

5.2 Contractor’s Documents

5.3 Contractor’s Undertaking

5.4 Technical Standards and Regulations

5.5 Training

5.6 As-Built Documents

5.7 Operation and Maintenance Manuals

5.8 Design Error

5.9 Warranties Unaffected

5.10 No Duty of Care or Liability Imposed on the Owner

6.0 STAFT AND LABOUR

6.1 Engagement of Staff and Labour

6.2 Rates of Wages and Conditions of Labour

6.3 Persons in the Service of Others

6.4 Labour Laws

6.5 Working Hours

6.6 Facilities for Staff and Labour

6.7 Health and Safety

6.8 Contractor’s Superintendence

6.9 Contractor’s Personnel




VOLUME-III



6.0 STAFT AND LABOUR (CONT’D)

6.10 Records of Contractor’s Personnel and Equipment

6.11 Disorderly Conduct

7.0 PLANT, MATERIALS AND WORKMANSHIP

7.1 Manner of Execution

7.2 Samples

7.3 Inspection

7.4 Testing

7.5 Rejection

7.6 Remedial Work

7.7 Ownership of Plant and Materials

7.8 Royalties

7.9 Liens

7.10 Spare Parts Prior to Taking Over

7.11 Spare Parts After Taking Over

8.0 COMMENCEMENT, DELAYS AND SUSPENSION

8.1 Commencement of Works

8.2 Date for Completion

8.3 Programme

8.4 Extension of Time for Completion

8.5 Delays caused by Authorities

8.6 Rate of Progress

8.7 Delay Damages

8.8 Suspension of Work

8.9 Consequences of Suspension




VOLUME-III



8.0 COMMENCEMENT, DELAYS AND SUSPENSION (CONT’D)

8.10 Payment for Plant and Materials in Event of Suspension

8.11 Prolonged Suspension

8.12 Resumption of Work

9.0 TESTS ON COMPLETION

9.1 Contractor’s Obligations

9.2 Delayed Tests

9.3 Retesting

9.4 Failure to Pass Tests on Completion

9.5 Guaranteed Performance Levels

9.6 Minimum Performance Levels

9.7 Exceeding the Limits of Other Plant Performance

9.8 Creation of Punch List

10.0 OWNER’S TAKING OVER

10.1 Taking Over of the Works and Unit

10.2 Taking Over of Parts of the Works

10.3 Interference with Test on Completion

10.4 Clearance of Site upon Taking-over

11.0 DEFECTS LIABILITY

11.1 Completion of Outstanding Work and Remedying Defects

11.2 Cost of Remedying Defects

11.3 Extension of Defects Notification Period

11.4 Failure to Remedy Defects

11.5 Removal of Defective Work




VOLUME-III



11.0 DEFECTS LIABILITY (CONT’D)

11.6 Further Tests

11.7 Right of Access

11.8 Contractor to Search

11.9 Performance Certificate

11.10 Unfulfilled Obligations

11.11 Clearance of Site

12.0 NOT USED

13.0 VARIATIONS AND ADJUSTMENTS

13.1 Right to Vary

13.2 Contractor’s Right to Submit Proposal

13.3 Variation Procedure

13.4 Payment in Applicable Currencies

13.5 Not used

13.6 Daywork

13.7 Adjustments for Changes in Legislation

13.8 Adjustments for changes in Cost

14.0 CONTRACT PRICE AND PAYMENT

14.1 The Contract Price

14.2 Not Used

14.3 Advance Payment

14.4 Application for Interim Payments

14.5 Payment Procedures

14.6 Plant and Material Intended for the worked

14.7 Interim Payments




VOLUME-III



14.0 DEFECTS LIABILITY (CONT’D)

14.8 Timing of Interim Payments

14.9 Delayed Payment

14.10 Payment Withheld and Retention

14.11 Statement at Completion

14.12 Cessation of Owner’s Liability

14.13 Currencies of Payment

14.14 Taxes and Duties

14.15 Payment Disputes

15.0 TERMINATION BY OWNER

15.1 Notice to Correct

15.2 Termination by Owner

15.3 Valuation at date of Termination

15.4 Payment after Termination

15.5 Owner’s Entitlement to Termination

16.0 SUSPENSION AND TERMINATION BY CONTRACTOR

16.1 Contractor’s Entitlement to Suspend Work

16.2 Termination by Contractor

16.3 Cessation of Work and Removal of Contractor’s Equipment

16.4 Payment on Termination

17.0 RISK AND RESPONSIBILITY

17.1 Indemnities

17.2 Contractor’s Care of the Works

17.3 Owner’s Risks




VOLUME-III



17.0 RISK AND RESPONSIBILITY (CONT’D)

17.4 Consequences of Owner’s Risks

17.5 Intellectual and Industrial Property Rights

17.6 Limitation of Liability

18.0 INSURANCE

18.1. General Requirements for Insurance

18.2. Cargo Insurance

18.3. Construction All Risk Insurance

18.4. Construction Equipment Insurance

18.5. Third Party Liability Insurance

18.6. Insurance for Contractor’s Personnel

18.7. Professional Indemnity Insurance for Contractor’s Consultants / Engineers

18.8. Approval of Insurance Policies

19.0 FORCE MAJEURE

19.1 Definition of Force Majeure

19.2 Notice of Force Majeure

19.3 Duty to Minimise Delay

19.4 Consequences of Force Majeure

19.5 Force Majeure Affecting Subcontractor

19.6 Optional Termination, Payment and Release

19.7 Release from Performance under the Law




VOLUME-III



20.0 CLAIMS, DISPUTES AND ARBITRATION

20.1 Contractor’s Claims

20.2 Amicable Settlement

20.3 Arbitration

20.4 Works to Continue

20.5 Time Limit for Arbitration



CONTENTS

[BOOK 1, BOOK 2]

VOLUME-IV : BID PROPOSAL SHEETS / BIDDING FORMS [TECHNICAL & GENERAL]

VOLUME-IVA : TECHNICAL PROPOSAL PARTICULARS FOR STEAM GENERATOR, TURBINE-GENERATOR, PIPING AND AUXILIARIES

VOLUME-IVB : TECHNICAL PROPOSAL PARTICULARS FOR AUXILIARY SYSTEM AND EQUIPMENT

VOLUME-IVC : TECHNICAL PROPOSAL PARTICULARS FOR ELECTRICAL WORKS

VOLUME-IVD : TECHNICAL PROPOSAL PARTICULARS FOR CONTROL AND INSTRUMENTATION

VOLUME-VIE : GENERAL PROPOSAL EXHIBIT SHEETS

SCHEDULE-IVE/1 : PROGRESS SCHEDULE

SCHEDULE-IVE/2 : DRAWING AND DOCUMENT SUBMISSION SCHEDULE

SCHEDULE-IVE/3 : DEVIATION FROM SPECIFICATION (PART-A)

SCHEDULE-IVE/4 : DEVIATION FROM SPECIFICATION (PART-B)

SCHEDULE-IVE/5 : EXPERIENCE LIST

[BOOK 3] : PORT TECHNICAL SCHEDULE


Rev-B


CONTENTS

VOLUME-V : BID PROPOSAL SHEETS / BIDDING FORMS [PRICE]


11-2010-K-G-SPC-2210-TOC_Rev-B

Documents

Transcript of 11-2010-K-G-SPC-2210-TOC_Rev-B